Loading...
HomeMy WebLinkAboutPeterson Contr - FY17 Site Grading for NEIP, Cont. # 926-3/27/2017-3'7o` cj FORM OF CONTRACT CONTRACT FOR THE CONSTRUCTION OF F.Y. 2017 SITE GRADING FOR NORTHEAST INDUSTRIAL PARK CITY OF WATERLOO, IOWA CONTRACT NO. 926 This contract made and entered into this <- ') day of , 20 (1, by and between the City of Waterloo, Iowa, a Municipal Corporation, (hereinafter referred to as City), and --eCO"rxG10113, \ , oC-- nct t.("" referred to as Contractor), WITNESSETH: PAR. 1 PAR. 2 PAR. 3 Contractor agrees to build and construct the F.Y.2017 SITE GRADING FOR NORTHEAST INDUSTRIAL PARK - CONTRACT. 926 and furnish all necessary tools, equipment, materials, and labor necessary to do all the work called for in the plans and specifications in a workmanship •like manner and for the prices set forth in Contractor's proposal, which was accepted by the City, and which is understood and agreed to be a part of this contract. It is understood and agreed that the resolution adopted by the City Council ordering the construction of the improvement, the Notice to Contractors as published, the Instruction to Bidders, the Form of Proposal, the Construction and Maintenance Bonds, the Council Proceedings relating to this matter, and the Plans and Specifications shall all be considered as forming a part of the contract the same as though they were each set out in said contract. The Contractor agrees to furnish at its own cost and expense, all necessary materials and labor for said work and to construct said improvements in a thorough, substantial, and workmanlike manner, and in strict accordance with the requirements of this contract, and of the plans and specifications made a part hereof by reference, and to the satisfaction and approval of the City and its engineer. FORM OF CONTRACT PAGE 1 OF 5 PAGES PAR. 4 PAR. 5 The Contractor agrees to perform said work and install said improvements on the terms set out in bid or proposal to the City which has been accepted by the City and which is by reference made a part of this contract. The Contractor agrees to commence said work within ten (10) working days after receipt of "Notice to Proceed" and complete it on or before August 4, 2017 unless an extension of time is granted in writing by the Council of the City. PAR. 6 Should the Contractor fail to complete said improvements in strict accordance with the terms and conditions of this contract, or the plans and specifications therefore promptly by the date herein specified, the City may pay such additional sums as it may be required to pay by reason of the failure of said contractor and deduct any and all such sums from any amount then due the Contractor. PAR. 7 PAR. 8 PAR. 9 The Contractor agrees to comply with and obey all ordinances of the City of Waterloo, Iowa, relating to the obstruction of streets and alleys, keeping open passage ways for water, traffic, and protecting any excavations in any street or alley, and maintaining proper and sufficient barricades with lights and signals during all hours of darkness, to see that the backfilling is properly done, and agrees to keep the City whole and defend any and all suits that may be brought against the City by reason of any injuries that may be sustained by any person or property allegedly caused by the Contractor, or his agents, while work is done pursuant to this agreement. The Contractor agrees that in the event a law suit is brought against the City for damages allegedly sustained by reason of any act, omission or negligence of the Contractor or its agents, or on account of any injuries allegedly sustained by reason of any obstruction, hole, depression or barrier placed or dug by the defendant or its agents, in the doing of the work herein contracted for, that it will defend said suit and save the City harmless therein, and in case judgment is rendered against the City, the Contractor agrees to pay the same promptly. The Contractor agrees to carry public liability insurance in a solvent company in a sufficient amount to protect the City and those who use the streets of the City. The City shall have the right to appoint one or more construction reviewers who shall review the progress of the work in detail; also, to make any test or any material to be used in such work. No material shall be used in any work until the same has first been approved by the construction reviewer. Such construction reviewer shall have full authority to pass judgment upon all materials and upon the manner of doing the work, and their judgment on rejecting any materials, substance, or manner of work shall be final unless it is revoked or modified by the City Engineer. FORM OF CONTRACT PAGE 2 OF 5 PAGES PAR. 10 PAR. 11 PAR. 12 PAR. 13 PAR. 14 PAR. 15 Any material, which has been rejected by the construction reviewer, shall be at once removed from the line of work and shall not be again taken thereon or placed with the material proposed to be used without the written consent of the City Engineer. The Contractor shall maintain no cause of action against the City on account of delays and prosecution of work, but if said work is delayed by the City, the Contractor shall have such extra time for completion of the job as was lost by reason of the delay caused by the City. The Contractor agrees to pay punctually all just claims of labor, material, men, or subcontractors who shall perform labor or furnish materials entering into this improvement. It is agreed that the City need not pay the Contractor until all such claims are paid by the Contractor. It is agreed that the City shall not be liable for said labor, material, or men under this contract. The Contractor agrees to furnish the City, simultaneously with this contract, a bond on a form to be provided by the City in the amount provided by law as stated in the Notice to Bidders, which shall be for the benefit of the City, and any and all persons injured by the breach of any of the terms of this contract. Said bond shall be filed with the City Clerk and shall be subject to the approval of the City Council, and is by reference made a part of this contract. The Contractor agrees that should it abandon work under this contract or cease the prosecution thereof for a period of thirty (30) consecutive days without reasonable cause, and should it fail to proceed with said work within ten (10) days after a notice to continue or carry it on has been mailed to it at the address given herein by the City, or after such notice has been served on it, then the City may proceed to complete said work, using any material, tools, or machinery found along said line of work, doing the work either by contract or as it may elect, and the Contractor and the sureties on its bond shall be liable to the City for the costs and expenses so paid out. Said costs shall be retained by the City from any compensation due, or to become due the Contractor, and may be recovered by the City in an action upon Contractor's bond. In consideration of the full compliance on the part of the Contractor with all the provisions, stipulations, and conditions hereof, or contained in the various instruments made a part of this contract by reference, and upon completion and acceptance of said work, the City agrees to pay to the Contractor, in the manner set out in the Notice to Contractors, the amount of money due the Contractor for work performed and accepted, at the unit FORM OF CONTRACT PAGE 3 OF 5 PAGES PAR. 16 PAR. 17 PAR. 18 PAR. 19 PAR. 20 PAR. 21 prices set out in the Contractor's proposal, which has been accepted by the City. The total amount of the contract, based on the Engineer's estimates of quantities and the Contractor's unit bid prices, and for which 100% surety bond is required is $ 966,707.20. After the completion of said work, the Contractor agrees to remove all debris and clean up said streets, and to save the City harmless from any damage allegedly resulting from a failure to clean up and remove the debris or put the street back in a proper condition for travel. This contract is not divisible, but in the event of a conflict between this contract and the various instruments incorporated by reference, this contract shall govern. Before the Contractor shall be entitled to receive final payment for work done under this contract, it shall execute and file a bond in the penal sum of not less than 100% of the total amount of the contract, same to be known as "Maintenance Bond," and which bond must be approved by the City Council, and which bond is in addition to the bond given by the Contractor to guarantee the completion of the work. The Contractor shall maintain all work done hereunder in good order for the period of two (2) years from and after the date it is accepted by the Council of the City of Waterloo, Iowa. Said maintenance shall be made without expense to the City or the abutting property. In the event of the failure or default of the Contractor to remedy any or all defects appearing in said work within a period of two (2) years from the date of its acceptance by said Council, and after having been given ten (10) days notice so to do by registered letter deposited in the United States Post Office in said town, addressed to said contractor at the address herein given, then the City may proceed to remedy such defects. The costs and expenses thereof to be recovered from the Contractor and the sureties on its maintenance bond by an action brought in any court of competent jurisdiction. The Contractor shall give notice to said City by registered letter directed to the Mayor or City Clerk/Auditor thereof not more than four (4) and not less than three (3) months prior to the expiration of the term during which the Contractor is required to maintain said improvements, in good repair by the terms of its Contract. The liability of the Contractor and of the sureties on its bond for maintenance of the said improvements shall continue until three (3) months after such notice has been given to the City, and, in any event, until two (2) years after the acceptance of the work. FORM OF CONTRACT PAGE 4 OF 5 PAGES CITY OF WATERLOO, IOWA Mayor lo(oll,,PP) City Clerk c--Q.+trsor, �a�n�ngc orS� .�anc. Contractor C ,, Title: ro' E C 'r ', Approved by the City Council of the City of Waterloo, Iowa, this day of , 20 11 ATTEST:\ Waterloo, Iowa , City Clerk FORM OF CONTRACT PAGE 5 OF 5 PAGES GI, HOLMES MURPHY IMPORTANT Enclosed bond and power of attorney forms are not dated. Date of the bond cannot be prior to the date of the Contract. Please be sure to complete the forms using the date of the Contract when that is determined. PfJ1' 31039 IVMAX Thank you. Bond No. 106649309 eck, IA any of America of and unto the City of ixly Six Thousand, Seven tiorrey of tiie United (the "Contract") dated on . 2017 Site Grading for Northeast Industrial Park, Waterloo, IA, Contract No. 926 The Contract is incorporated herein by reference as though fully set forth herein. Whenever the Principal shall be and is declared by the Obligee to bo in default under the Contract, with the Obligee having performed its obligations in the Contract, then the Surety, acknowledging that time is of the essence, may promptly remedy the default, or shall promptly undertake to; Complete the Contract in accordance with its terms and conditions; or 2. Obtain one or more bids for completing the Contract in accordance with its terms and conditions, and upon detemiination by the Surety of the lowest responsible bidder, or negotiated proposal, or, if the Obligee elects, upon determination by the Obligee and the Surety jointly of the lowest responsible bidder, or negotiated proposal, arrange for a contract between such party and the Obligee. The Surety will make available as work progresses sufficient funds to pay the cost of completion less the balance of the Contract price. The cost of completion includes responsibilities of the Principal for correction of defective work and completion of the Contract, the Obligee's legal and design professional costs resulting directly from the Principal's default, and liquidated damages or actual damages if no liquidated damages are specified in the Contract. The term "balance of the Contract price" means the total amount payable by the Obligee to the Principal under the Contract and any amendments thereto, less the amount. properly paid by the Obligee to the Principal; or 3, Determine the amount for which it is liable to the Obligee and pay The Obligee that amount as soon as practicable, In the event this bond is enforced, Principal and Surety agree to indemnify Obligee and hold Obligee harmless from and against any and all costs of enforcement, including but not limited to reasonable attorneys' fees and expenses. Every Surety on this bond shall be deemed and held, any contract to the contrary notwithstanding, to consent to each and all of the following matters, without notice: • Performance Bond Page 1 of 2 1. To any extension of time to the Contract in which to perform the Contract. 2. To any change in the plans, specifications, or Contract when such change does not involve an increase of more than tvventy percent (20%) of the total Contract price, and shall then be released only as to such excess increase. 3. That no provision of this bond or of any other contract shall be valid which limits to less than one (1) year from the time of the acceptance of the work the right to sue on this bond for defect in workmanship or material not discovered or known to the Obligee at the time such work was accepted. If the Principal performs the Contract, then this bond shall be null and void; otherwise it shall remain in full force and effect. In no event shall the Surety's total obligation exceed the penal amount of this bond, Terms used herein shall include, as appropriate, the singular or plural number, or the masculine, feminine or neuter gender. IN WITNESS WHEREOF, the undersigned Principal and Surety have executed this Performance Bond as of V.4-).‹.-1-1... 'r 2017 . PRINCIPAL Peterson Contractors, Inc. Name By. Title: ''e---.- SUSURETY Travelers .r ualt and Surety Company of America Name Title: Anne Crowner, Attorney -in -Fact [attach Power of Attorney] NOTE: Date of BOND rrtust not be prior to date of Contract_ If CONTRACTOR is Partnership, all partners should execute (BOND. irth kjAjecf ihclude`s'F dera 12:unEi .th e following app ies•tb-the; iayment bcind) IMPORTANT: Surety companies executing bonds must appear on the Treasury Department's most current list (Circular 570 as amended) and be authorized to transact business in the State where the project is located. Performance Bond Page 2 of 2 PAYIVIIrNT BOND KNOVV ALL MEN BY THESE PRESENTS: that Peterson Contractors, Inc. P.O. Box A, Reinbeck, IA 50669-0155 Bond No. 106649309 (Name of Contractor) (Address of Contractor) a Corporation , hereinafter called Principal, (Corporation, Partnership or Individual) ali, Travelers Casualty and Surety Company of America (Mame of Surety) One Tower Square, Hartford, CT 06183 (Mdress of Surety) hereinafter called Surety, are held and firmly bound unto City of Waterloo (Name of Owner) 715 Mulberry Street, Waterloo, IA 50703 (Address of Owner) hereinafter called OWNER, in the penal sum of * IJollars,($ 966,707.20 ) *Nine Hundred Sixty Six Thousand, Seven Hundred Seven and 20/100 in lawful money of the United States, for the payment of which sura well and truly to be made, we bind ourselves, successors, and assigns, jointly and severally, firmly by these presents, THE CONDITION OF TI ltS OBLIGATION is such that whereas, the Principal entered into a certain contract with the OWNER, dated the day of Ma -P -r - t--$ 2017_, a copy of which is hereto attached and made a part hereof for the construction of: F.Y. 2017 Site Grading for Northeast Industrial Park, Waterloo, IA - Contract No. 926 NOW, THEREFORE, if the Principal shall promptly make payment to all persons, firms, SUBCONTRACTORS, and corporations furnishing materials. for or performing labor in the prosecution of the WORK provided for in such contract, and any authorized extension or modification thereof, including all amounts due for materials, lubricants, oil, gasoline, coat and coke, repairs on machinery, equipment and tools, consumed or used in connection with the construction of such WORK, and all insurance premiums on said WORK, and for all labor, performed in such WORK whether by SUBCONTRACTOR or otherwise, then this obligation shall be void; otherwise to remain in full force and effect. PROVIDED, FURTHER, that the said Surety for value received hereby stipulates and agrees that no change, extension of time, alteration or addition to Ulu' 101111s of the contract or to the WORK to be performed thereunder or the SPECIFICATIONS accompanying the same shall in any wise affect its obligation on this BOND, and it does hereby waive notice of any such change, extension of tinge, alteration or addition to the teens of the contract or to the WORK or to the SPECIFICATIONS. PROVIDED, FURTHER, that no final settlement between the OWNER and the CONTRACTOR shall abridge the right of any beneficiary hereunder, whose claim may be unsatisfied. IN WITNESS HEREOF, this instrument is executed in Three (3) counterparts, each one of (number) which shall be deemed an original, this the day of -1-\ 2017. ATTEST: Peterson Contractors, Inc. (Principal) secretary C2� E �/ P.O. Box A, Reinbeck, IA 50669-0155 (Address) Principal *cut W.s ss as to P ncipal - '' ex- R. Loeklr.cr�c P. • Box A, Reinbeck, IA 50669-0155 (Address) AT 4ides Casu- and Surety Company of America iurety r �' «+* nne Crowner P.O. Box 9207 Witness as lo Surely / 1 lone R. Young (Addrovs) P.O. Box 9207 (Address) Des Moines, IA 50306-9207 Des Moines, IA 50306-9207 NOTE: Date of BOND must not be prior to date of Contract If CONTRACTOR Is Partnership, all partners should execute BOND. If this pio)CSI,r.Ia4ludes,:l?,nedaral l ynds, tla °#ell �wi.rig;applies'to;th ;;la iy�:rr r;'tt f�onrJ IMPORTANT: Surety companies executing bonds must appear on the Treasury Department's most current list (Circular 570 as amended) and be authorized to transact business in the State where the project is located. TRAVELERS J Farmington Casualty Company Fidelity and Guaranty Insurance Company Fidelity and Guaranty Insurance Underwriters, Inc. St. Paul Fire and Marine Insurance Company St. Paul Guardian Insurance Company Attorney -In -Fact No. 231471 POWER OF ATTORNEY St. Paul Mercury Insurance Company Travelers Casualty and Surety Company Travelers Casualty and Surety Company of America United States Fidelity and Guaranty Company Surety Bond No. or Project Description: Principal: Peterson Contractors, Inc. 106649309 Obligee: City of Waterloo KNOW ALL MEN BY THESE PRESENTS: That Farmington Casualty Company, St. Paul Fire and Marine Insurance Company, St. Paul Guardian Insurance Company, St. Paul Mercury Insurance Company, Travelers Casualty and Surety Company, Travelers Casualty and Surety Company of America, and United States Fidelity and Guaranty Company are corporations duly organized under the laws of the State of Connecticut, that Fidelity and Guaranty Insurance Company is a corporation duly organized under the laws of the State of Iowa, and that Fidelity and Guaranty Insurance Underwriters, Inc. is a corporation duly organized under the laws of the State of Wisconsin (herein collectively called the "Companies"), and that the Companies do hereby make, constitute and appoint Craig E. Hansen, lay D. Freiermuth, Brian M. Deimerly, Cindy Bennett, Anne Crowner, Tim McCulloh, Stacy Venn, Shirley S. Bartenhagen, and Dione R. Young of the City of West Des Moines State of Iowa, their true and lawful Attorney(s)-in-Fact, each in their separate capacity if more than one is named above, to sign, execute, seal and acknowledge any and all bonds, recognizances, conditional undertakings and other writings obligatory in the nature thereof on behalf of the Companies in their business of guaranteeing the fidelity of persons, guaranteeing the performance of contracts and executing or guaranteeing bonds and undertakings required or permitted in any actions or proceedings allowed by law. IN WITNESS WHEREOF, the Companies have caused this instrument to be signed and their corporate seals to be hereto affixed, this 24th day of October, 2016. Farmington Casualty Company Fidelity and Guaranty Insurance Company Fidelity and Guaranty Insurance Underwriters, Inc. 5t. Paul Fire and Marine Insurance Company St. Paul Guardian Insurance Company St. Paul Mercury Insurance Company Travelers Casualty and Surety Company Travelers Casualty and Surety Company of America United States Fidelity and Guaranty Company State of Connecticut City of Hartford ss. By: Robert L. Raney, Senior Vice President On this the 24th day of October, 2016, before me personally appeared Robert L. Raney, who acknowledged himself to be the Senior Vice President of Farmington Casualty Company, Fidelity and Guaranty Insurance Company, Fidelity and Guaranty Insurance Underwriters, Inc., St. Paul Fire and Marine Insurance Company, St. Paul Guardian Insurance Company, St. Paul Mercury Insurance Company, Travelers Casualty and Surety Company, Travelers Casualty and Surety Company of America, and United States Fidelity and Guaranty Company, and that he, as such, being authorized so to do, executed the foregoing instrument for the purposes therein contained by signing on behalf of the corporations by himself as a duly authorized officer. In Witness Whereof, I hereunto set my hand and official seal. My Commission expires the 30th day of June, 2021. mQ.R NC .IAJARl1A1.7..� Marie C. Tetreault, Notary Public PETER -3 OP ID: SHDE .4C0RL7` CERTIFICATE OF LIABILITY INSURANCE DA03/22/2017Y) 03/22/2017 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(les) must be endorsed. 0 SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER LSB Insurance 242 Tower Park Waterloo, IA 50701 Kevin Boyle CONTACT PHON: PHONE FAX INC No Ext): (NC, No): POLICY EXPMI (MMIDDIYYYY) E-MAIL ADDRESS: INSURER(S) AFFORDING COVERAGE NAIC N INSURER A: Hartford Fire Insuranc Co 19682 INSURED Peterson Contractors, Inc. Reinbeck Motor Inc. PO Box AI104 Blackhawk St Reinbeck, IA 50669 INSURER B: Trumbull Insurance Co 27120 INSURER c: Berkshire Hathaway Ins Co 22276 INSURER D :Zurich American Ins Co 16535 INSURER E: MED EXP (Any one person) INSURER F: COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR TYPE OF INSURANCE ADDL INRR SUBR WVD POLICY NUMBER POLICY EFF (MDDNVYY) POLICY EXPMI (MMIDDIYYYY) LIMITS A GENERAL X LIABILITY COMMERCIAL GENERAL LIABILITY X 41CSEQU2151 07/01/2016 07/01/2017 EACH OCCURRENCE S 1,000,000 DAMAGETO RENTED PREMISES (Ea occurrencej 5 300,000 MED EXP (Any one person) $ 10,000 CLAIMS -MADE X OCCUR PERSONAL &ADV INJURY $ 1,000,000 X Blnkt Contractual GENERAL AGGREGATE S 2,000,000 X XCU Coverage PRODUCTS - COMP/OP AGG S 2,000,000 GE 'L AGGREGATE POLICY X LIMIT APPLIES Fin PER: LOC $ A AUTOMOBILE X X LIABILITY ANY AUTO ALL OWNED HIRED SAUTOS X SCHEDULED AUTOS NON -OWNED AUTOS 41UENQU2152 07/01/2016 07/01/2017 COMBINED SINGLE LIMIT (Ea accident S 2,000,000 BODILY INJURY (Per person) $ BODILY INJURY (Per accident) $ PROPERTY DAMAGE (PER ACCIDENT) S C X UMBRELLA MB EXCESS MEI X OCCUR CLAIMS -MADE 47-XSF-100514-01 07/01/2016 07/01/2017 EACH OCCURRENCE $ 1,000,000 AGGREGATE $ 1,000,000 $ DEDSRETENT ON B WORKERS COMPENSATION AND EMPLOYERS' LIABILITY ANY PROPRIETOR/PARTNER/EXECUTIVE OFFICER/MEMBER EXCLUDED? (Mandatory in NH) If yes, describe under DESCRIPTION OF OPERATIONS below Y/N N NIA 41WNQU2150 07/01/2016 07/01/2017 X WC STATU- TORY LIMITS OTH- ER E.L. EACH ACCIDENT $ 1,000,000 E.L. DISEASE - EA EMPLOYEE 1,000,000 Et DISEASE - POLICY LIMIT $ 1,000,000 D D Cargo Rent/Lease Equip. CPP9267064-06 CPP9267064-06 07/01/2016 07/01/2016 07/01/2017 07/01/2017 Cargo 1,000,000 Rent/Leas 5,000,000 DESCRIPTION OF OPERATIONS I LOCATIONS I VEHICLES (Attach ACORD 101, Additional Remarks Schedule, If more space I required) RE: J7039 / NE Industrial Park Contract #926 The City of Waterloo, Iowa is named as an additional insured per contract requirements. WATER -1 City of Waterloo 715 Mulberry St. Waterloo, IA 50701 SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. AUTHORIZED REPRESENTATIVE ACORD 25 (2010/05) ©1988.2010 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD