Loading...
HomeMy WebLinkAboutFairfield Inn & Suites-9/16/2013Preparer Informations Noel Anderson 111 Doc ID: 005346380011 Type GEN Kind: AGREEMENT Recorded: 11/26/2013 at 04:26:03 PM Fee Amt: $57.00 Pape 1 of 11 Black Hawk County Iowa JUDITH A MCCARTHY RECORDER F11e2014-00011100 111; 715 Mulberry Street Waterloo, Iowa 50703 (319) 291-4366 Name Address City Phone SPACE ABOVE THIS UNE FOR RECORDER DEVELOPMENT AGREEMENT Thi Development Agreement (the "Agreement") is entered into as of // , 2013, by and between SHRI GANAPATI & BAJRANGBALI, INC D/B/A FAIRFIELDINN & SUITES (the "Company") and the City of Waterloo, Iowa (the "City"). RECITALS A. City considers economic development within the City a benefit to the community and is willing for the overall good and welfare of the community to provide financial incentives so as to encourage that goal. B. Company is willing and able to finance and construct a building and related improvements on property located in the Crossroads Urban Renewal and Redevelopment Plan. AGREEMENT NOW, THEREFORE, in consideration of the mutual covenants set forth herein, the parties agree as follows: 1. Acquisition of Property. On or before December 31, 2013, Company shall acquire real property described in Exhibit "A" hereto (the "Property") for the development of a $2.65 million hotel project. 2. Improvements by Company.. Company shall construct a commercial hotel building consisting of approximately 81 rooms, and related parking and landscaping (the "Improvements"), all of which shall be located on the Property. The Improvements shall be constructed in accordance with all applicable City, state, and 1.1 DEVELOPMENT AGREEMENT Page 2 federal building codes and shall comply with all applicable City ordinances and other applicable law. It is contemplated that the Improvements will have a total project cost of approximately $4,000,000.00. The Property, the Improvements, and all site preparation and development -related work to make the Property usable for Company's purposes as contemplated by this Agreement are collectively referred to as the "Project". 3. Timeliness of Construction. The parties agree that Company's commitment to undertake the Project and to construct the Improvements in a timely manner constitutes a material inducement for the City to convey the Property, or to cause the Property to be conveyed, to Company and that without said commitment City would not done so. Company must obtain a building permit and begin construction within four (4) months from the date the Development Agreement is approved, and construction shall be completed within twelve (12) months. If, after the expiration of four (4) months from the date of the executed agreement, Company has not, good faith, begun the construction of the Improvements upon the Property, the agreement shall become void; provided, however, that if construction has not begun at the end of said four-month period, but the development of the Project is still imminent, the City Council may, but shall not be required to, consent to an extension of time for the construction of the Improvements, and if an extension is granted but construction of the Improvements has not begun within such extended period, then the agreement shall become void after the end of said extended period. If development has commenced within the four-month period or any extended period and is stopped and/or delayed as a result of an act of God, war, civil disturbance, court order, labor dispute, fire, or other cause beyond the reasonable control of Company, the requirement that construction is to be completed within twelve (12) months shall be tolled for a period of time equal to the period of such stoppage or delay, and thereafter if construction is not completed within the allowed period of extension the agreement shall become void after the end of said period. 4. Water and Sewer. Company will be responsible for extending water and sewer service to any location on the Property and for payment of any associated connection fees. 5. Minimum Assessment Agreement. Company acknowledges and agrees that it will pay when due all taxes and assessments, general or special, and all other lawful charges whatsoever levied upon or assessed or placed against the Property. Company further agrees that, prior to the date set forth in Section 2 of Exhibit "B", it will not seek or cause a reduction in the taxable valuation for the Property, which shall be fixed for assessment purposes, below the aggregate amount of $2,640,440.00 ("Minimum Actual Value"), through: (i) willful destruction of the Property, Improvements, or any part of either; (ii) a request to the assessor of Black Hawk County; or DEVELOPMENT AGREEMENT Page 3 (iii) any proceedings, whether administrative, legal, or equitable, with any administrative body or court within the City, Black Hawk County, the State of Iowa, or the federal government. Company agrees to sign the agreement attached as Exhibit "B" at closing. 6. Property Tax Rebates. Provided that Developer has completed the Improvements as set forth in Sections 2 and 3 and has executed the Minimum Assessment Agreement as set forth in Section 5, the City agrees to rebate property taxes (with the exceptions noted below) as follows: a. Year One - 50% rebate b. Year Two - 50% rebate c. Year Three - 50% rebate d. Year Four - 50% rebate e. Year Five - 50% rebate f. Year Six - 50% rebate g. Year Seven 50% rebate h. Year Eight 50% rebate for any taxable value over the January 1, 2013 taxable value of $3,540.00 (calculated on a $2,211.82 price per acre basis from split of parcel number 8813-02-427-015). Rebates are payable in respect of a given year only to the extent that Developer has actually paid general property taxes due and owing for such year. Rebates are to be paid to Developer within 30 days of any tax payment made by Developer. This rebate program is not applicable to any special assessment levy, debt service levy, or any other levy that is exempted from treatment as tax increment financing under the provisions of applicable law. The first year in which a rebate may be given ("Year One") shall be the first full year for which the assessment is based upon the completed value of the Improvements and not a prior year for which the assessment is based solely upon the value of the land or upon the value of the land and a partial value of the Improvements, due to partial completion of the Improvements or a partial tax year. 7. Representations and Warranties of City. City hereby represents and warrants as follows: A. City is not prohibited from consummating the transaction contemplated in this Agreement by any law, regulation, agreement, instrument, restriction, order or judgment. B. Each person who executes and delivers this Agreement and all documents to be delivered hereunder is and shall be authorized to do so on behalf of City. 8. Representations and Warranties of Company. Company hereby represents and warrants as follows: DEVELOPMENT AGREEMENT Page 4 A. Company is not prohibited from consummating the transaction contemplated in this Agreement by any law, regulation, agreement, instrument, restriction, order or judgment. B. Company is duly organized, validly existing, and in good standing under the laws of the state of its organization and is duly qualified and in good standing under the laws of the State of Iowa. C. Company has full right, title, and authority to execute and perform this Agreement and to consummate all of the transactions contemplated herein, and each person who executes and delivers this Agreement and all documents to be delivered to City hereunder is and shall be authorized to do so on behalf of Company. 9. Notices. Any notice under this Agreement shall be in writing and shall be delivered in person, by overnight air courier service, by United States registered or certified mail, postage prepaid, or by facsimile (with an additional copy delivered by one of the foregoing means), and addressed: (a) if to City, at 715 Mulberry Street, Waterloo, Iowa 50703, facsimile number 319-291-4571, Attention: Mayor, with copies to the City Attorney and the Community Planning and Development Director. (b) if to Company, to SHRI GANAPATI & BAJRANGBALI, INC D/B/A FAIRFIELDINN & SUITES, facsimile number Attention: Atul Patel. Delivery of notice shall be deemed to occur (i) on the date of delivery when delivered in person, (ii) one (1) business day following deposit for overnight delivery to an overnight air courier service which guarantees next day delivery, (iii) three (3) business days following the date of deposit if mailed by United States registered or certified mail, postage prepaid, or (iv) when transmitted by facsimile so long as the sender obtains written electronic confirmation from the sending facsimile machine that such transmission was successful. 10. No Joint Venture. Nothing in this Agreement shall, or shall be deemed or construed to, create or constitute any joint venture, partnership, agency, employment, or any other relationship between the City and Company nor to create any liability for one party with respect to the liabilities or obligations of the other party or any other person. 11. Amendment, Modification, and Waiver. No amendment, modification, or waiver of any condition, provision, or term of this Agreement shall be valid or of any effect unless made in writing, signed by the party or parties to be bound or by the duly authorized representative of same, and specifying with particularity the extent and nature of the amendment, modification, or waiver. Any waiver by any party of any default by another party shall not affect or impair any rights arising from any subsequent default. DEVELOPMENT AGREEMENT Page 5 12. Severability. Each provision, section, sentence, clause, phrase, and word of this Agreement is intended to be severable. If any portion of this Agreement shall be deemed invalid or unenforceable, whether in whole or in part, the offending provision or part thereof shall be deemed severed from this Agreement and the remaining provisions of this Agreement shall not be affected thereby and shall continue in full force and effect. If, for any reason, a court finds that any portion of this Agreement is invalid or unenforceable as written, but that by limiting such provision or portion thereof it would become valid and enforceable, then such provision or portion thereof shall be deemed to be written, and shall be construed and enforced, as so limited. 13. Captions. All captions, headings, or titles in the paragraphs or sections of this Agreement are inserted only as a matter of convenience and/or reference, and they shall in no way be construed as limiting, extending, or describing either the scope or intent of this Agreement or of any provisions hereof. 14. Binding Effect. This Agreement shall be binding and shall inure to the benefit of the parties and their respective successors, assigns, and legal representatives. 15. Counterparts. This Agreement may be executed in one or more counterparts, each of which shall be deemed an original and all of which, taken together, shall constitute one and the same instrument. 16. Entire Agreement. This Agreement, together with the Minimum Assessment Agreement attached hereto as Exhibit "B", constitutes the entire agreement of the parties and supersedes all prior or contemporaneous negotiations, discussions, understandings, or agreements, whether oral or written, with respect to the subject matter hereof. 17. Time of Essence. Time is of the essence of this Agreement. IN WITNESS WHEREOF, the parties have executed this Development Agreement as of the date first set forth above. [signatures on next page] DEVELOPMENT AGREEMENT Page 6 CITY OF WATERLOO, IOWA SHRI GANAPATI & BAJRANGBALI, INC D/B/A FAIRFIELDINN & SUITES By:edi dL( Ernest G. Clark, Mayor Attest Suzy Sc I ares, City Clerk By: Atul Patel EXHIBIT "A" Lot 2, Crossroads Plat No. 10, City of Waterloo, Black Hawk County, Iowa. EXHIBIT "B" MINIMUM ASSESSMENT AGREEMENT This Minimum Assessment Agreement (the "Agreement") is entered into as of this ®/p day of ,7n13- , 2013, by and among the CITY OF WATERLOO, IOWA ("City"), SHRI GANAPATI & BAJRANGBALI, INC D/B/A FAIRFIELDINN & SUITES ("Developer"), and the COUNTY ASSESSOR of the City of Waterloo, Iowa ("Assessor"). WITNESSETH: WHEREAS, on or before the date hereof the City and Developer have entered into a development agreement (the "Development Agreement") regarding certain real property, described in Exhibit "A" thereto, located in the City; and WHEREAS, it is contemplated that pursuant to the Development Agreement, the Developer will undertake the development of an area ("Project") within the City and within the "Crossroads Waterloo Urban Renewal and Redevelopment Plan "; and WHEREAS, pursuant to Iowa Code § 403.6, as amended, the City and the Developer desire to establish a minimum actual value for the land and the building(s) pursuant to this Agreement and applicable only to the Project, which shall be effective upon substantial completion of the Project and from then until this Agreement is terminated pursuant to the terms herein and which is intended to reflect the minimum actual value of the land and buildings as to the Project only; and WHEREAS, the City and the Assessor have reviewed the preliminary plans and specifications for the improvements (the "Improvements") which the parties contemplate will be erected as a part of the Project. NOW, THEREFORE, the parties hereto, in consideration of the promises, covenants, and agreements made by each other, do hereby agree as follows: 1. Upon substantial completion of construction of the Improvements by the Developer, the minimum actual taxable value which shall be fixed for assessment purposes for the land and Improvements to be constructed thereon by the Developer as a part of the Project shall not be Tess than $2,640,440.00 ("Minimum Actual Value") until termination of this Agreement. The parties hereto agree that construction of the Improvements will be substantially completed on or before December 31, 2014. 2. The Minimum Actual Value herein established shall be of no further force and effect, and this Minimum Assessment Agreement shall terminate, on December 31, 2025. Nothing herein shall be deemed to waive the Developer's rights under Iowa Code § 403.6, as amended, to contest that portion of any actual value assignment made by the Assessor in excess of the Minimum Actual Value established herein. In no event, however, shall the Developer seek or cause the reduction of the actual value assigned below the Minimum Actual Value established herein during the term of this Agreement. The City shall not unreasonably withhold its consent to permit the Developer to contest its taxable valuations in full, commencing with the assessment of January 1, 2026. 3. This Agreement shall be promptly recorded by the City with the Recorder of Black Hawk County, Iowa. The City shall pay all costs of recording. 4. Neither the preambles nor provisions of this Agreement are intended to, or shall be construed as, modifying the terms of the Development Agreement. 5. This Agreement shall inure to the benefit of and be binding upon the successors and assigns of the parties. CITY OF WATERLOO, IOWA By: .,,e44,4/ ,,e44Epp Ernest G. Clark, Mayor ATTEST: res, City Clerk SHRI GANAPATI & BAJRANGBALI, INC D/B/A FAIRFIELDINN & SUITES By: Atul Pat STATE OF IOWA ) ) ss. COUNTY OF BLACK HAWK ) • On this ///, day of, . , 2013, before me, a Notary Public in and for the State of Iowa, Pers nally appeared Ernest G. Clark and Suzy Schares, to me personally known; who being duly sworn, did say that they are the Mayor and City Clerk, respectively, of the City of Waterloo, Iowa, a municipal corporation, created and existing under the laws of the State of Iowa, and that the seal affixed to the foregoing instrument is the seal of said municipal corporation, and that said instrument was signed and sealed on behalf of said municipal corporation by authority and resolution of its City Council, and said Mayor and City Clerk acknowledged said instrument to be the free act and deed of said municipal corporation by it and by them voluntarily executed. UNNEA MARTINEZ COMMISSION NOT/9524 MY COMMISSION BORES STATE OF kw4 ) ss. COUNTY OF Acknowledged before me onrcein7,4502. / 3 , 2013 by Atul Patel as for SHRI GANAPATI & BAJRANGBALI, INC D/B/A FAIRFIELDINN & SUITES. '•IAL 4 '0 W TIM ANDERA COMMISSION NO. 772518 MY COMMISSION EXPIRES April 11, 2015 Nota Public CERTIFICATION OF ASSESSOR The undersigned, having reviewed the plans and specifications for the improvements to be constructed and the market value assigned to the land upon which the improvements are to be constructed for the development, and being of the opinion that the minimum market value contained in the foregoing Minimum Assessment Agreement appears reasonable, hereby certifies as follows: The undersigned Assessor, being legally responsible for the assessment of the property subject to the development, upon completion of improvements to be made on it and in accordance with the Minimum Assessment Agreement, certifies that the actual value assigned to such land, building and equipment upon completion of the development shall not be Tess than Two Million Six Hundred Forty Thousand Four Hundred Forty Dollars ($2,640,440.00). STATE OF IOWA ) ss. COUNTY OF BLACK HAWK ��ri\CXOt Assessor for Black Hawk County, Iowa ` \()\ q\\ Date Subscribed ands orn to be,, re me on OCJ% , 2013, by lam ' , Assessor for Black Hawk County, Iowa. Nota Public DEBORAH L. BOECKMANN MY MY COMMISSION JNO. IRES Preparer Information: Noel Anderson Name 715 Mulberry Street Address Waterloo, Iowa 50703 (319) 291-4366 City Phone SPACE ABOVE THIS LINE FOR RECORDER DEVELOPMENT AGREEMENT Thi Development Agreement (the "Agreement") is entered into as of ✓4 , 2013, by and between SHRI GANAPATI & BAJRANGBALI, INC D/B/A FAIRFIELDINN & SUITES (the "Company") and the City of Waterloo, Iowa (the "City"). RECITALS A. City considers economic development within the City a benefit to the community and is willing for the overall good and welfare of the community to provide financial incentives so as to encourage that goal. B. Company is willing and able to finance and construct a building and related improvements on property located in the Crossroads Urban Renewal and Redevelopment Plan. AGREEMENT NOW, THEREFORE, in consideration of the mutual covenants set forth herein, the parties agree as follows: 1 Acquisition of Property. On or before December 31, 2013, Company shall acquire real property described in Exhibit "A" hereto (the "Property") for the development of a $2.65 million hotel project. 2. Improvements by Company. Company shall construct a commercial hotel building consisting of approximately 81 rooms, and related parking and landscaping (the "Improvements"), all of which shall be located on the Property. The. Improvements shall be constructed in accordance with all applicable City, state, and DEVELOPMENT AGREEMENT Page 2 federal building codes and shall comply with all applicable City ordinances and other applicable law. Itis contemplated that the Improvements will have a total project cost of. approximately $4,000,000.00. The Property, the Improvements, and all site preparation and development -related work to make the Property usable for Company's purposes as contemplated by this Agreement are collectively referred to as the "Project". 3. Timeliness of Construction. The parties agree that Company's commitment to undertake the Project and to construct the Improvements in a timely manner constitutes a material inducement for the City to convey the Property, or to cause the Property to be conveyed, to Company and that without said commitment City would not done so. Company must obtain a building permit and begin construction within four (4) months from the date the Development Agreement is approved, and construction shall be completed within twelve (12) months. If, after the expiration of four (4) months from the date of the executed agreement, Company has not, good faith, begun the construction of the Improvements upon the Property, the agreement shall become void; provided, however, that if construction has not begun at the end of said four-month period, but the development of the Project is still imminent, the City Council may, but shall not be required to, consent to an extension of time for the construction of the Improvements, and if an extension is granted but construction of the Improvements has not begun within such extended period, then the agreement shall become void after the end of said extended period. If development has commenced within the four-month period or any extended period and is stopped and/or delayed as a result of an act of God, war, civil disturbance, court order, labor dispute, fire, or other cause beyond the reasonable control of Company, the requirement that construction is to be completed within twelve (12) months shall be tolled for a period of time equal to the period of such stoppage or delay, and thereafter if construction is not completed within the allowed period of extension the agreement shall become void after the end of said period. 4. Water and Sewer. Company will be responsible for extending water and sewer service to any location on the Property and for payment of any associated connection fees. 5. Minimum Assessment Agreement. Company acknowledges and agrees that it will pay when due all taxes and assessments, general or special, and all other lawful charges whatsoever levied upon or assessed or placed against the Property. Company further agrees that, prior to the date set forth in Section 2 of Exhibit "B", it will not seek or cause a reduction in the taxable valuation for the Property, which shall be fixed for assessment purposes, below the aggregate amount of $2,640,440.00 ("Minimum Actual Value"), through: (i) willful destruction of the Property, Improvements, or any part of either; (ii) a request to the assessor of Black Hawk County; or DEVELOPMENT AGREEMENT Page 3 (iii) any proceedings, whether administrative, legal, or equitable, with any administrative body or court within the City, Black Hawk County, the State of Iowa, or the federal government. Company agrees to sign the agreement attached as Exhibit "B" at closing. 6. Property Tax Rebates. Provided that Developer has completed the Improvements as set forth in Sections 2 and 3 and has executed the Minimum Assessment Agreement as set forth in Section 5, the City agrees to rebate property taxes (with the exceptions noted below) as follows: a. Year One - 50% rebate b. Year Two - 50% rebate c. Year Three - 50% rebate d. Year Four - 50% rebate e. Year Five - 50% rebate f. Year Six - 50% rebate g. Year Seven 50% rebate h. Year Eight 50% rebate for any taxable value over the January 1, 2013 taxable value of $3,540.00 (calculated on a $2,211.82 price per acre basis from split of parcel number 8813-02-427-015). Rebates are payable in respect of a given year only to the extent that Developer has actually paid general property taxes due and owing for such year. Rebates are to be paid to Developer within 30 days of any tax payment made by Developer. This rebate program is not applicable to any special assessment levy, debt service levy, or any other levy that is exempted from treatment as tax increment financing under the provisions of applicable law. The first year in which a rebate may be given ("Year One") shall be the first full year for which the assessment is based upon the completed value of the Improvements and not a prior year for which the assessment is based solely upon the value of the land or upon the value of the land and a partial value of the Improvements, due to partial completion of the Improvements or a partial tax year. 7. Representations and Warranties of City. City hereby represents and warrants as follows: A. City is not prohibited from consummating the transaction contemplated in this Agreement by any law, regulation, agreement, instrument, restriction, order or judgment. B. Each person who executes and delivers this Agreement and all documents to be delivered hereunder is and shall be authorized to do so on behalf of City. 8. Representations and Warranties of Company. Company hereby represents and warrants as follows: DEVELOPMENT AGREEMENT Page 4 A. Company is not prohibited from consummating the transaction contemplated in this Agreement by any law, regulation, agreement, instrument, restriction, order or judgment. B. Company is duly organized, validly existing, and in good standing under the laws of the state of its organization and is duly qualified and in good standing under the laws of the State of Iowa. C. Company has full right, title, and authority to execute and perform this Agreement and to consummate all of the transactions contemplated herein, and each person who executes and delivers this Agreement and all documents to be delivered to City hereunder is and shall be authorized to do so on behalf of Company. 9. Notices. Any notice under this Agreement shall be in writing and shall be delivered in person, by overnight air courier service, by United States registered or certified mail, postage prepaid, or by facsimile (with an additional copy delivered by one of the foregoing means), and addressed: (a) if to City, at 715 Mulberry Street, Waterloo, Iowa 50703, facsimile number 319-291-4571, Attention: Mayor, with copies to the City Attorney and the Community Planning and Development Director. (b) if to Company, to SHRI GANAPATI & BAJRANGBALI, INC D/B/A FAIRFIELDINN & SUITES, facsimile number Attention: Atul Patel. Delivery of notice shall be deemed to occur (i) on the date of delivery when delivered in person, (ii) one (1) business day following deposit for overnight delivery to an overnight air courier service which guarantees next day delivery, (iii) three (3) business days following the date of deposit if mailed by United States registered or certified mail, postage prepaid, or (iv) when transmitted by facsimile so long as the sender obtains written electronic confirmation from the sending facsimile machine that such transmission was successful. 10. No Joint Venture. Nothing in this Agreement shall, or shall be deemed or construed to, create or constitute any joint venture, partnership, agency, employment, or any other relationship between the City and Company nor to create any liability for one party with respect to the liabilities or obligations of the other party or any other person. 11. Amendment, Modification, and Waiver. No amendment, modification, or waiver of any condition, provision, or term of this Agreement shall be valid or of any effect unless made in writing, signed by the party or parties to be bound or by the duly authorized representative of same, and specifying with particularity the extent and nature of the amendment, modification, or waiver. Any waiver by any party of any default by another party shall not affect or impair any rights arising from any subsequent default. y97 DEVELOPMENT AGREEMENT Page 5 12. Severability. Each provision, section, sentence, clause, phrase, and word of this Agreement is intended to be severable. If any portion of this Agreement shall be deemed invalid or unenforceable, whether in whole or in part, the offending provision or part thereof shall be deemed severed from this Agreement and the remaining provisions of this Agreement shall not be affected thereby and shall continue in full force and effect. If, for any reason, a court finds that any portion of this Agreement is invalid or unenforceable as written, but that by limiting such provision or portion thereof it would become valid and enforceable, then such provision or portion thereof shall be deemed to be written, and shall be construed and enforced, as so limited. 13. Captions. All captions, headings, or titles in the paragraphs or sections of this Agreement are inserted only as a matter of convenience and/or reference, and they shall in no way be construed as limiting, extending, or describing either the scope or intent of this Agreement or of any provisions hereof. 14. Binding Effect. This Agreement shall be binding and shall inure to the benefit of the parties and their respective successors, assigns, and legal representatives. 15. Counterparts. This Agreement may be executed in one or more counterparts, each of which shall be deemed an original and all of which, taken together, shall constitute one and the same instrument. 16. Entire Agreement. This Agreement, together with the Minimum Assessment Agreement attached hereto as Exhibit "B", constitutes the entire agreement of the parties and supersedes all prior or contemporaneous negotiations, discussions, understandings, or agreements, whether oral or written, with respect to the subject matter hereof. 17. Time of Essence. Time is of the essence of this Agreement. IN WITNESS WHEREOF, the parties have executed this Development Agreement as of the date first set forth above. [signatures on next page] )1/ DEVELOPMENT AGREEMENT Page 6 CITY OF WATERLOO, IOWA By: 7, ai.,.// Ernest G. Clark, Mayor I Atte Suzy Schaes, City Clerk SHRI GANAPATI & BAJRANGBALI, INC D/B/A FAIRFIELDINN & SUITES By: Atul Patel �,d EXHIBIT "A" Lot 2, Crossroads Plat No. 10, City of Waterloo, Black Hawk County, Iowa. EXHIBIT "B" MINIMUM ASSESSMENT AGREEMENT This Minimum Assessment Agreement (the "Agreement") is entered into as of this day of , 2013, by and among the CITY OF WATERLOO, IOWA ("City"), SHRI GANAPATI & BAJRANGBALI, INC D/B/A FAIRFIELDINN & SUITES ("Developer"), and the COUNTY ASSESSOR of the City of Waterloo, Iowa ("Assessor"). WITNESSETH: WHEREAS, on or before the date hereof the City and Developer have entered into a development agreement (the "Development Agreement") regarding certain real property, described in Exhibit "A" thereto, located in the City; and WHEREAS, it is contemplated that pursuant to the Development Agreement, the Developer will undertake the development of an area ("Project") within the City and within the "Crossroads Waterloo Urban Renewal and Redevelopment Plan "; and WHEREAS, pursuant to Iowa Code § 403.6, as amended, the City and the Developer desire to establish a minimum actual value for the land and the building(s) pursuant to this Agreement and applicable only to the Project, which shall be effective upon substantial completion of the Project and from then until this Agreement is terminated pursuant to the terms herein and which is intended to reflect the minimum actual value of the land and buildings as to the Project only; and WHEREAS, the City and the Assessor have reviewed the preliminary plans and specifications for the improvements (the "Improvements") which the parties contemplate will be erected as a part of the Project. NOW, THEREFORE, the parties hereto, in consideration of the promises, covenants, and agreements made by each other, do hereby agree as follows: 1. Upon substantial completion of construction of the Improvements by the Developer, the minimum actual taxable value which shall be fixed for assessment purposes for the land and Improvements to be constructed thereon by the Developer as a part of the Project shall not be less than $2,640,440.00 ("Minimum Actual Value") until termination of this Agreement. The parties hereto agree that construction of the Improvements will be substantially completed on or before December 31, 2014. 2. The Minimum Actual Value herein established shall be of no further force and effect, and this Minimum Assessment Agreement shall terminate, on December 31, 2025. Nothing herein shall be deemed to waive the Developer's rights under Iowa Code § 403.6, as amended, to contest that portion of any actual value assignment made by the Assessor in excess of the Minimum Actual Value established herein. In no event, however, shall the Developer seek or cause the reduction of the actual value assigned below the Minimum Actual Value established herein during the term of this Agreement. The City shall not unreasonably withhold its consent to permit the Developer to contest its taxable valuations in full, commencing with the assessment of January 1, 2026. 3. This Agreement shall be promptly recorded by the City with the Recorder of Black Hawk County, Iowa. The City shall pay all costs of recording. 4. Neither the preambles nor provisions of this Agreement are intended to, or shall be construed as, modifying the terms of the Development Agreement. 5. This Agreement shall inure to the benefit of and be binding upon the successors and assigns of the parties. ATTEST: Suzy Tchares, City Clerk CITY OF,WATERLOO, IOWA By:_,1441-11 Ernest G. Clark, Mayor SHRI GANAPATI & BAJRANGBALI, INC D/B/A FAIRFIELDINN & SUITES By: STATE OF IOWA ) ss. COUNTY OF BLACK HAWK ) On this 4' day of , 2013, before me, a Notary Public in and for the State of Iowa, personally appeared Ernest G. Clark and Suzy Schares, to me personally known, who being duly sworn, did say that they are the Mayor and City Clerk, respectively, of the City of Waterloo, Iowa, a municipal corporation, created and existing under the laws of the State of Iowa, and that the seal affixed to the foregoing instrument is the seal of said municipal corporation, and that said instrument was signed and sealed on behalf of said municipal corporation by authority and resolution of its City Council, and said Mayor and City Clerk acknowledged said instrument to be the free act and deed of said municipal corporation by it and by them voluntarily executed. A��w��a �i • UNNEA MARTINEZ: COMMISSION NO.779524 STATE OF k.,,4 ) ss. COUNTY OF ' ) Acknowledged before me on,5--rraArg /3 , 2013 by Atul Patel as for SHRI GANAPATI & BAJRANGBALI, INC D/B/A FAIRFIELDINN & SUITES. Notary Public 4ww��t e 4 TIM ANDERA COMMISSION NO. 772518 MY COMMISSION EXPIRES April 11, 2018 c Notary Public CERTIFICATION OF ASSESSOR The undersigned, having reviewed the plans and specifications for the improvements to be constructed and the market value assigned to the land upon which the improvements are to be constructed for the development, and being of the opinion that the minimum market value contained in the foregoing Minimum Assessment Agreement appears reasonable, hereby certifies as follows: The undersigned Assessor, being legally responsible for the assessment of the property subject to the development, upon completion of improvements to be made on it and in accordance with the Minimum Assessment Agreement, certifies that the actual value assigned to such land, building and equipment upon completion of the development shall not be less than Two Million Six Hundred Forty Thousand Four Hundred Forty Dollars ($2,640,440.00). STATE OF IOWA COUNTY OF BLACK HAWK —46u\.., \m°�.��..�. Assessor for Black Hawk County, Iowa \6 \ a�\2 Date ) ss. Subscribed and sworn to befre me on ("9 , 2013, by la 7 Ci e z' , Assessor for Black Hawk County, Iowa. Notary Public ""' `` 0 4 �,. : a DEBORAH L. BOECKMANN MY COMMISSION NO. 195788 MY COM ON 4 IBES