Loading...
HomeMy WebLinkAboutBoland Recreation-9/23/2013CITY OF WATERLOO, IOWA WATERLOO LEISURE SERVICES COMMISSION CONTRACT for FY2014 GATES PARK PLAYGROUND PROJECT This Contract made and entered into this 23'd day of September, 2013, by and between the City of Waterloo, Iowa, a Municipal Corporation, hereinafter referred to as City, and Boland recreation, hereinafter referred to as Contractor, WITNESSETH: Par. 1: The Contractor shall furnish all supervision, technical personnel, labor, materials, and equipment to perform all work required for the FY2014 Gates Park Playground Project, described in the specifications and shown on the plans. Par. 2: The Contract Documents shall consist of the following: a. This Agreement b. Notice of Hearing c. Signed Copy of Bid d. Specifications e. Davis Bacon and Related Acts Requirements 1. Federal Clauses 2. Davis Bacon Poster 3. Wage Rates for operators, carpenters and labors 4. Wage Reporting form (submitted weekly) 5. Performance Bond 6. Payment Bond 7. Section 3 These documents form the Contract and are all fully a part of the Contract as if attached to this Contract or repeated herein. Par. 3: The Contractor agrees to commence the work within forty-five (45) days after the issuance of "Notice to Proceed" and complete the work within the given time frame. Par. 4: The Contractor agrees to comply with and obey all ordinances of the City of Waterloo, Iowa, relating to the obstruction of streets and alleys, keeping open passageways for water, traffic and protecting any excavation in any street or alley and maintaining proper and sufficient barricades with lights and signals during all hours of darkness and agrees to see that the backfilling is properly done and agrees to keep the City whole and defend any suits that may be brought against it by reason of any injuries that may be sustained by any person on account of doing this work by the Contractor and any agents of the Contractor. CONTRACT page 1 of 2 Par. 5: The Contractor agrees that in case a suit is brought against the City for damages sustained by reason of any act, omission or negligence of the Contractor or its agents or on account of any injuries sustained by reason of any obstruction, hole, depression or barrier placed or dug by the defendant or its agents in the doing of the work herein contracted for, that it will defend said suit and save the City harmless therein and in case judgment is rendered against the City, the Contractor agrees to pay the same promptly and agrees to carry public liability insurance in a solvent company in a sufficient amount to protect the City and any and all persons who may use the project. Par. 6: The Contractor shall have no cause of action against the City on account of delays and prosecution of work, but if the work is delayed by the City, the Contractor may have extra time for the completion of the job as was lost by reason of the delay caused by the City. Par. 7: The Contractor agrees to pay punctually all just claims of labor, material, men or Subcontractors, who perform labor or fiarnish materials entering into this improvement. It is agreed that the City need not pay the Contractor until all such claims are paid by the Contractor and lien waivers are received. It is agreed that the City shall bear no liability for payments due for labor or materials under this contract. Par. 8: In consideration of the full compliance on the part of the Contractor with all the provisions, stipulations and conditions hereof, or contained in the various instruments made a part of this Contract by reference, and upon completion and acceptance of the work, the City agrees to pay the Contractor: Sum of Fifty -Four Thousand, Nine Hundred Twenty -Five Dollar and 00/100 ($54,925.00) City of Waterloo, Iowa, 02ai Frnest G. Clark, Mayor d Contractor: Boland Recreation Mark Boland/Owner Approved by the City Council of the City of Waterloo, Iowa, this 23i1 day of September, 2013. CONTRACT page 2 of 2 ACORD CERTIFICATE OF LIABILITY INSURANCE Tm DATE(Mf01DD1YYYY) 09/24/2013 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(les) must be endorsed. If SUBROGATION 1S WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder In lieu of such endorsement(s). PRODUCER Shomo-Madsen Insurance 22 E Main St BOX 129 MARSHALLTOWN, IA 50158 CONTACT NAME: i No, : (641)753-6691tig {,luck (641)752-5360 E-MAIL ADDRESS: INSURERS) AFFORDING COVERAGE NAIC # INSURERA: Cincinnati Ins Co - AM Best: A+ X Daum() Gazaway & Associates dba Boland Recreation 2347 Oak Park Road Marshalltown, IA 50158 INSURERB: 01/01/2013 INSURER C : EACH OCCURRENCE INSURER D: PREMISES (Ea occurrrrence) INSURE: INSURER F : CLAIMS -MADE COVERAGES CERTIFICATE NUMBER: Gazawavl3 REVISION NI NIRFR- THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. LTR TYPE OF INSURANCE INSR �WVDD POLICY NUMBER POLICYBR IDDEFF (b1 JYYYY) POLICY EXP (64MfDDJYYYY) UNITS A GENERAL X LIABILITY COMMERCIAL GENERAL LIABILITY X EPP 011 72 18 01/01/2013 01/01/2014 EACH OCCURRENCE $ 1, 000, 000 PREMISES (Ea occurrrrence) $ 500,000 CLAIMS -MADE X OCCUR MED EXP (My one person) $ 5 000 PERSONAL & ADV INJURY $ 1,000,000 GENERAL AGGREGATE $ 2,000,000 $ 2,000,000 $ GEM. AGGREGATE LIMIT APPLIES PER: —1 POLICY n !ECT I LOC PRODUCTS - COMP/OP AGG A AUTOMOBILE X X X LIABILITY ANY AUTO AI�JTOS MED HIRED AUTOS X )( AUTOSULED 1;‘10N -OWNED EBA 011 72 18 01/01/2013 01/01/2014 (E roils idLe iu, 'MOLL LIMIT $ 1,000,000 BODILY INJURY (Per person) $ BODILY INJURY (Per accident) $ PROPERTY DAMAGE (Per accident) $ $ A UMBRELLA LIAB EXCESS UAB X OCCUR CLAIMS -MADE EPP 011 72 18 01/01/2013 01/0112014 EACH OCCURRENCE $ 1,000,000 AGGREGATE $ DED X RETENTION $ 0 $ - A WORKERS ON AND EMPLOYERSELIABIJTY Y f N ANY PROPRIETOR/PARTNER/FJCECUTIVEri OFFICERIMEMBER EXCLUDED? (Mandatory le NH) If yea describe under DESCRIPTION OF OPERATIONS below Ni A WC 2108764 01/0112013 01/01/2014 X TO RY UA��TS ER EL EACH ACCIDENT $ 100,000 EL DISEASE - EA EMPLOYEE $ 100,000 E.L DISEASE - POLICY LIMIT $ 500,000 DESCRIPTION OF OPERATIONS 1 LOCATIONS /VEHICLES (Attach ACORD 101, Additional Remarks Schedule If more space Is required) RE: Any and all jobs contracted to City of Waterloo Leisure Services. Additional Insured: City of Waterloo Leisure Services on Commercial General Liability, if required by written contract or agreement, per GA277 that is endorsed to EPP0117218. CERTIFICATE HOLDER CANCELLATION City of Waterloo Leisure Services 1101 Campbell Avenue Watrerloo, IA 50703 SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. AUTHORIZED REPRESENTATIVE Bobby Shomo/MICHEL ACORD 25 (2010/05) © 1988-2010 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD