Loading...
HomeMy WebLinkAboutKueny Architects LLC-9/13/2010Init. Document 8102' - 2007 Standard Form of Agreement Between Owner and Architect without a Predefined Scope of Architect's Services AGREEMENT made as of the TWENTIETH day of AUGUST in the year TWO THOUSAND TEN (In words, indicate day, month and year) BETWEEN the Owner: (Name, legal status, address and other information) CITY OF WATERLOO IOWA NEW PUBLIC WORKS COMPLEX 1314 BLACK HAWK STREET WATERLOO, IOWA 50702 and the Architect (Name, legal status, address and other information) KUENY ARCHITECTS LLC 10505 CORPORATE DRIVE SUITE 100 PLEASANT PRAIRIE, WI 53158 for the following Project (Name, location and detailed description) ARCHITECTURAL AND ENGINEERING SERVICES FOR THE REMODEL OF THE EXISTING 27,000 SQ. FT. CONCRETE STRUCTURE LOCATED ON THE EXISTING SITE. THE SERVICES WILL INCLUDE THE DESIGN OF THE NEW CENTRAL GARAGE, STREETS DEPARTMENT, SIGN AND TRAFFIC AND TRAFFIC ENGINEERING WITH TRAFFIC SIGNALIZATION EQUIPMENT SECURITY. THE CITY WILL DETERMINE AFTER THE MASTER DESIGN IS COMPLETE WHAT SECTIONS OF THE FACILITY CAN BE CONSTRUCTED BASED ON THE ESTIMATED COST AND BUDGET. IT IS ASSUMED THAT THE MASTER PLAN DESIGN WILL BE BETWEEN 100,000 —150,000 SQUARE FEET. The Owner and Architect agree as follows. ADDITIONS AND DELETIONS: The author of this document has added information needed for its completion. The author may also have revised the text of the original AIA standard form. An Additions and Deletions Report that notes added information as well as revisions to the standard form text is available from the author and should be reviewed. A vertical line in the left margin of this document indicates where the author has added necessary information and where the author has added to or deleted from the original AIA text. This document has important legal consequences. Consultation with an attorney is encouraged with respect to its completion or modification. AIA Document B102Th — 2007 (formerly B141T" —1997 Part 1). Copyright m 1917, 1926, 1948, 1951, 1953, 1958, 1961, 1963, 1966, 1967, 1970, 1974, 1977, 1987, 1997 and 2007 by The American Institute of Architects. All rights reserved. WARNING: This AIA® Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA® Document, or any portion of it, may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:57:36 on 09/07/2010 under Order No.5077229677_1 which expires on 10/13/2010, and is not for resale. User Notes: (1298672465) Init TABLE OF ARTICLES 1 ARCHITECT'S RESPONSIBILITIES 2 OWNER'S RESPONSIBILITIES 3 COPYRIGHTS AND LICENSES 4 CLAIMS AND DISPUTES 5 TERMINATION OR SUSPENSION 6 COMPENSATION 7 MISCELLANEOUS PROVISIONS 8 SPECIAL TERMS AND CONDITIONS 9 SCOPE OF THE AGREEMENT ARTICLE 1 ARCHITECT'S RESPONSIBILITIES § 1.1 The Architect shall provide the following professional services: (Describe the scope of the Architect's services or identify an exhibit or scope of service,s document setting forth the Architect's services and incorporated into this document in Section 9.2) ARCHITECTURAL AND ENGINEERING SERVICES FOR THE REMODEL OF THE EXISTING 27,000 SQ. FT. CONCRETE STRUCTURE LOCATED ON THE EXISTING SITE. THE SERVICES WILL INCLUDE THE DESIGN OF THE NEW CENTRAL GARAGE, STREETS DEPARTMENT, SIGN AND TRAFFIC AND TRAFFIC ENGINEERING WITH TRAFFIC SIGNALIZATION EQUIPMENT SECURITY. THE CITY WILL DETERMINE AFTER THE MASTER DESIGN IS COMPLETE WHAT SECTIONS OF THE FACILITY CAN BE CONSTRUCTED BASED ON THE ESTIMATED COST AND BUDGET. IT IS ASSUMED THAT THE MASTER PLAN DESIGN WILL BE BETWEEN 100,000 —150,000 SQUARE FEET. § 1.2 The Architect shall perform its services consistent with the professional skill and care ordinarily provided by architects practicing in the same or similar locality under the same or similar circumstances. The Architect shall perform its services as expeditiously as is consistent with such professional skill and care and the orderly progress of the Project. § 1.3 The Architect shall identify a representative authorized to act on behalf of the Architect with respect to the Project § 1.4 Except with the Owner's knowledge and consent, the Architect shall not engage in any activity, or accept any employment, interest or contribution that would reasonably appear to compromise the Architect's professional judgment with respect to this Project. § 1.5 The Architect shall maintain the following insurance for the duration of this Agreement If any of the requirements set forth below exceed the types and limits the Architect normally maintains, the Owner shall reimburse the Architect for any additional cost: (Identify types and limits of insurance coverage, and other insurance requirements applicable to the Agreement, if (Paragraphs deleted) Any.) 1 General Liability 1,000,000 EACH OCCURANCE 300,000 DAMAGE TO RENTED PREMISES (EACH OCCURANCE) 5,000 MEDICAL EXPENSE (ANY ONE PERSON) AIA Document B102T" — 2007 (formerly B141 T" 1997 Part 1). Copyright O 1917, 1926, 1948, 1951, 1953, 1958, 1961, 1963, 1966, 1967, 1970, 1974, 1977, 1987, 1997 and 2007 by The American Institute of Architects. All rights reserved. WARNING: This AIA® Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA® Document, or any portion of it, may result In severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:57:36 on 09/07/2010 under Order No.5077229677_1 which expires on 10/13/2010, and is not for resale. User Notes: (1298672465) Init. 1,000,000 PERSONAL & ADV. INJURY 2,000,000 GENERAL AGGREGATE 2,000,000 PRODUCTS — COMP/OP AGG .2 Automobile Liability 1,000,000 COMBINED SINGLE LIMIT (EACH ACCIDENT) .3 Workers' Compensation 100,000 E.L. EACH ACCIDENT 100,000 E.L. DISEASE — EACH EMPLOYEE 500,000 E.L. DISEASE — POLICY LIMITS .4 Professional Liability 1,000,000 EACH CLAIM 2000,000 AGGREGATE ARTICLE 2 OWNER'S RESPONSIBILITIES § 2.1 Unless otherwise provided for under this Agreement, the Owner shall provide information in a timely manner regarding requirements for and limitations on the Project, including a written program which shall set forth the Owner's objectives, schedule, constraints and criteria, including space requirements and relationships, flexibility, expandability, special equipment, systems and site requirements. Within 15 days after receipt of a written request from the Architect, the Owner shall furnish the requested information as necessary and relevant for the Architect to evaluate, give notice of or enforce lien rights. § 2.2 The Owner shall identify a representative authorized to act on the Owner's behalf with respect to the Project. The Owner shall render decisions and approve the Architect's submittals in a timely manner in order to avoid unreasonable delay in the orderly and sequential progress of the Architect's services. § 2.3 The Owner shall coordinate the services of its own consultants with those services provided by the Architect. Upon the Architect's request, the Owner shall furnish copies of the scope of consulting services in the contracts between the Owner and the Owner's consultants. The Owner shall furnish the services of consultants other than those designated in this Agreement, or authorize the Architect to furnish them as an Additional Service, when the Architect requests such services and demonstrates that they are reasonably required by the scope of the Project. The Owner shall require that its consultants maintain professional liability insurance as appropriate to the services provided. § 2A The Owner shall furnish all legal, insurance and accounting services, including auditing services, that may be reasonably necessary at any time for the Project to meet the Owner's needs and interests. § 2.5 The Owner shall provide prompt written notice to the Architect if the Owner becomes aware of any fault or defect in the Project, including errors, omissions or inconsistencies in the Architect's Instruments of Service. ARTICLE 3 COPYRIGHTS AND LICENSES § 3.1 The Architect and the Owner warrant that in transmitting Instruments of Service, or any other information, the transmitting party is the copyright owner of such information or has permission from the copyright owner to transmit such information for its use on the Project. If the Owner and Architect intend to transmit Instruments of Service or any other information or documentation in digital form, they shall endeavor to establish necessary protocols governing such transmissions. § 3.2 The Architect and the Architect's consultants shall be deemed the authors and owners of their respective Instruments of Service, including the Drawings and Specifications, and shall retain all common law, statutory and other reserved rights, including copyrights. Submission or distribution of Instruments of Service to meet official regulatory requirements or for similar purposes in connection with the Project is not to be construed as publication in derogation of the reserved rights of the Architect and the Architect's consultants. AIA Document B102TM — 2007 (formerly B141' —1997 Part 1). Copyright ©1917, 1926, 1948, 1951, 1953, 1958, 1961, 1963, 1966, 1967, 1970, 1974, 1977, 1987, 1997 and 2007 by The American Institute of Architects. All rights reserved. WARNING: This AIA® Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA® Document, or any portion of it, may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:57:36 on 09/07/2010 under Order No.5077229677_1 which expires on 10/13/2010, and is not for resale. User Notes: (1298672465) Init. § 3.3 Upon execution of this Agreement, the Architect grants to the Owner a nonexclusive license to use the Architect's Instruments of Service solely and exclusively for the Project, provided that the Owner substantially performs its obligations, including prompt payment of all sums when due, under this Agreement The Architect shall obtain similar nonexclusive licenses from the Architect's consultants consistent with this Agreement. The license granted under this section permits the Owner to authorize the Contractor, Subcontractors, Sub -subcontractors, and material or equipment suppliers, as well as the Owner's consultants and separate contractors, to reproduce applicable portions of the Instruments of Service solely and exclusively for use in performing services for the Project If the Architect rightfully terminates this Agreement for cause as provided in Sections 5.3 and 5.4, the license granted in this Section 3.3 shall terminate. § 3.3.1 In the event the Owner uses the Instruments of Service without retaining the author of the Instruments of Service, the Owner releases the Architect and Architect's consultant(s) from all claims and causes of action arising from such uses. The Owner, to the extent permitted by law, further agrees to indemnify and hold harmless the Architect and its consultants from all costs and expenses, including the cost of defense, related to claims and causes of action asserted by any third person or entity to the extent such costs and expenses arise from the Owner's use of the Instruments of Service under this Section 3.3.1. § 3.4 Except for the licenses granted in this Article 3, no other license or right shall be deemed granted or implied under this Agreement The Owner shall not assign, delegate, sublicense, pledge or otherwise transfer any license granted herein to another party without the prior written agreement of the Architect. Any unauthorized use of the Instruments of Service shall be at the Owner's sole risk and without liability to the Architect and the Architect's consultants. ARTICLE 4 CLAIMS AND DISPUTES § 4.1 GENERAL § 4.1.1 The Owner and Architect shall commence all claims and causes of action, whether in contract, tort, or otherwise, against the other arising out of or related to this Agreement in accordance with the requirements of the method of binding dispute resolution selected in this Agreement within the period specified by applicable law, but in any case not more than 10 years after the date of Substantial Completion of the Work. The Owner and Architect waive all claims and causes of action not commenced in accordance with this Section 4.1.1. § 4.1.2 To the extent damages are covered by property insurance, the Owner and Architect waive all rights against each other and against the contractors, consultants, agents and employees of the other for damages, except such rights as they may have to the proceeds of such insurance as set forth in AIA Document A201-2007, General Conditions of the Contract for Construction, if applicable. The Owner or the Architect, as appropriate, shall require of the contractors, consultants, agents and employees of any of them similar waivers in favor of the other parties enumerated herein. § 4.1.3 The Architect and Owner waive consequential damages for claims, disputes or other matters in question arising out of or relating to this Agreement. This mutual waiver is applicable, without limitation, to all consequential damages due to either party's termination of this Agreement, except as specifically provided in Section 5.7. § 4.2 MEDIATION § 4.2.1 Any claim, dispute or other matter in question arising out of or related to this Agreement shall be subject to mediation as a condition precedent to binding dispute resolution. If such matter relates to or is the subject of a lien arising out of the Architect's services, the Architect may proceed in accordance with applicable law to comply with the lien notice or filing deadlines prior to resolution of the matter by mediation or by binding dispute resolution. § 4.2.2 The Owner and Architect shall endeavor to resolve claims, disputes and other matters in question between them by mediation which, unless the parties mutually agree otherwise, shall be administered by the American Arbitration Association in accordance with its Construction Industry Mediation Procedures in effect on the date of the Agreement A request for mediation shall be made in writing, delivered to the other party to the Agreement, and filed with the person or entity administering the mediation. The request may be made concurrently with the filing of a complaint or other appropriate demand for binding dispute resolution but, in such event, mediation shall proceed in advance of binding dispute resolution proceedings, which shall be stayed pending mediation for a period of 60 days from the date of filing, unless stayed for a longer period by agreement of the parties or court order. If an arbitration AIA Document B10211, — 2007 (formerly 8141 N —1997 Part 1). Copyright © 1917, 1926, 1948, 1951, 1953, 1958, 1961, 1963, 1966,1967, 1970, 1974, 1977, 1987, 1997 and 2007 by The American Institute of Architects. All rights reserved. WARNING: This AIA® Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA® Document, or any portion of it, may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:57:36 on 09/07/2010 under Order No.5077229677_1 which expires on 10/13/2010, and is not for resale. User Notes: (1298672465) Init. proceeding is stayed pursuant to this Section, the parties may nonetheless proceed to the selection of the arbitrator(s) and agree upon a schedule for later proceedings. § 4.2.3 The parties shall share the mediator's fee and any filing fees equally. The mediation shall be held in the place where the Project is located, unless another location is mutually agreed upon. Agreements reached in mediation shall be enforceable as settlement agreements in any court having jurisdiction thereof § 42.4 If the parties do not resolve a dispute through mediation pursuant to this Section 4.2, the method of binding dispute resolution shall be the following: (Check the appropriate box. If the Owner and Architect do not select a method of binding dispute resolution below, or do not subsequently agree in writing to a binding dispute resolution method other than litigation, the dispute will be resolved in a court of competent jurisdiction) (x] Arbitration pursuant to Section 4.3 of this Agreement [ ] Litigation in a court of competent jurisdiction [ ] Other (SPecify) § 4.3 ARBITRATION § 4.3.1 If the parties have selected arbitration as the method for binding dispute resolution in this Agreement, any claim, dispute or other matter in question arising out of or related to this Agreement subject to, but not resolved by, mediation shall be subject to arbitration, which unless the parties mutually agree otherwise, shall be administered by the American Arbitration Association in accordance with its Construction Industry Arbitration Rules in effect on the date of this Agreement A demand for arbitration shall be made in writing, delivered to the other party to this Agreement, and filed with the person or entity administering the arbitration. § 4.3.1.1 A demand for arbitration shall be made no earlier than concurrently with the filing of a request for mediation, but in no event shall it be made after the date when the institution of legal or equitable proceedings based on the claim, dispute or other matter in question would be barred by the applicable statute of limitations. For statute of limitations purposes, receipt of a written demand for arbitration by the person or entity administering the arbitration shall constitute the institution of legal or equitable proceedings based on the claim, dispute or other matter in question. § 4.32 The foregoing agreement to arbitrate and other agreements to arbitrate with an additional person or entity duly consented to by parties to this Agreement shall be specifically enforceable in accordance with applicable law in any court having jurisdiction thereof § 4.3.3 The award rendered by the arbitrator(s) shall be final, and judgment may be entered upon it in accordance with applicable law in any court having jurisdiction thereof § 4.3.4 CONSOLIDATION OR JOINDER § 4.3.4.1 Either party, at its sole discretion, may consolidate an arbitration conducted under this Agreement with any other arbitration to which it is a party provided that (1) the arbitration agreement governing the other arbitration permits consolidation; (2) the arbitrations to be consolidated substantially involve common questions of law or fact; and (3) the arbitrations employ materially similar procedural rules and methods for selecting arbitrator(s). § 4.3.42 Either party, at its sole discretion, may include by joinder persons or entities substantially involved in a common question of law or fact whose presence is required if complete relief is to be accorded in arbitration, provided that the party sought to be joined consents in writing to such joinder. Consent to arbitration involving an additional person or entity shall not constitute consent to arbitration of any claim, dispute or other matter in question not described in the written consent. § 4.3.4.3 The Owner and Architect grant to any person or entity made a party to an arbitration conducted under this Section 4.3, whether by joinder or consolidation, the same rights of joinder and consolidation as the Owner and Architect under this Agreement. AIA Document B102TM — 2007 (formerly 13141 TM -1997 Part 1). Copyright © 1917, 1926, 1948, 1951, 1953, 1958, 1961, 1963, 1966, 1967, 1970, 1974, 1977, 1987, 1997 and 2007 by The American Institute of Architects. All rights reserved. WARNING: This AIA® Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA® Document, or any portion of it, may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:57:36 on 09/07/2010 under Order No.5077229677_1 which expires on 10/13/2010, and is not for resale. User Notes: (1298672465) Init. ARTICLE 5 TERMINATION OR SUSPENSION § 5.1 If the Owner fails to make payments to the Architect in accordance with this Agreement, such failure shall be camsrde�ed substantial nonperformance and cause for termination or, at the Architect's option, cause for suspension of "penance of services under this Agreement If the Architect elects to suspend services, the Architect shall give seven days' written notice to the Owner before suspending services. In the event of a suspension of services, the Architect shall have no liability to the Owner for delay or damage caused the Owner because of such suspension of services. Before resuming services, the Architect shall be paid all sums due prior to suspension and any expenses incurred in the interruption and resumption of the Architect's services. The Architect's fees for the remaining services and the time schedules shall be equitably adjusted. § 52 If the Owner suspends the Project, the Architect shall be compensated for services performed prior to notice of such suspension. When the Project is resumed, the Architect shall be compensated for expenses incurred in the inte ruption'andi resumption of the Architect's services. The Architect's fees for the remaining services and the time schedules sball be equitably adjusted. § 5 3 If* Owner suspends the Project for more than 90 cumulative days for reasons other than the fault of the Architect,the Architect may terminate this Agreement by giving not less than seven days' written notice. § MEI—the: party may terminate this Agreement upon not less than seven days' written notice should the other party fail substantially to perform in accordance with the terms •of this Agreement through no fault of the party initiating the termination. 151 5 The IOW= may terminate this Agreement upon not less than seven days' written notice to the Architect for the Owner's convenience and without cause. The Architect will suspend further work upon receipt of notice of termination, unless the City has requested in writing the Architect to complete a particular task during such time.. § 5.61n the event of termination not the fault of the Architect, the Architect shall be compensated for services performed prior to termination, together with Reimbursable Expenses then due and all Termination Expenses as defined',* Section 5.7. The Architect will suspend further work upon receipt of notice of termination, unless the Cityibas requested hi writing the Architect to complete a particular task during such time. /5.7' 7 Termination Expenses are m a ditton to compensation for the Architect's services and include expenses directlyatt iibutable'to termination for Which the Architect is not otherwise compensated, plus an amount for the Architectls�autiicipatedprofit on the value of the services not performed by the Architect. § 5.8 The Owner's rights to use the Architect's Instruments of Service in the event of a termination of this Agreement are set forth in Article 3 and Section 6.3. ARTICLE 6 COMPENSATION § 6.1 The Owner shall compensate the Architect for services described in Section 1.1 as set forth below, or in the attached exhibit or scope document incorporated into this Agreement in Section 9.2. (Insert amount of or basis for, compensation or indicate the exhibit or scope document in which compensation is provided, fors) SEE ATTACHED COST DETAIL SHEET DATED 8-3-2010 PHASE I SCHEMATIC PHASE — DESIGN PHASE 530,199 $45,089 PHASE II 'CONSTRUCTION DOCUMENT and BIDDING PHASE $230,060 QNSTRUCTION OBSERVATION AGREEMENT TO BE REVIEWED UPON COMPLETION OF PHASE L AIA Document B102Tm — 2007 (formerly B1417a —1997 Part 1). Copyright @ 1917, 1926, 1948,1951, 1953, 1958, 1961, 1963, 1966,1967, 1970, 1974, 1977, 1987, 1997 and 2007 by The American Institute of Architects. All rights reserved. WARNING: This AIA® Document is protected by U.S. Copyright Law and Intemational Treaties. Unauthorized reproduction or distribution of this AIA® Document, or any portion of it, may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 12:56:55 on 09/09/2010 under Order No.5077229677 1 which expires on 10/13/2010, and is not for resale. User Notes: (1212953684) § 6 2 Reimbursable Expenses are in addition to compensation for the Architect's professional services and include expenses incurred by the Architect and the Architect's consultants directly related to the Project, as follows: .3 Fees paid for securing approval of authorities having jurisdiction over the Project .4 Printing, reproductions, plots, standard form documents; (FOR BIDDING) .6 Expense of overtime work requiring higher than regular rates, if authorized in advance by the Owner, .7 (Paragraphs deleted) § 6.2.1 For Reimbursable Expenses the compensation shall be the expenses incurred by the Architect and the Architect's consultants plus an administrative fee of ZERO percent (0 %) of the expenses incurred § 6.3 COMPENSATION FOR USE OF ARCHITECT'S INSTRUMENTS OF SERVICE If the Owner terminates the Architect for its convenience under Section 5.5, or the Architect terminates this Agreement under Section 5.3, the Owner chart pay a licensing fee as compensation for the Owner's continued use of the Architect's Instruments of Service solely for purposes of the Project as follows: N/A § 6.4 PAYMENTS TO THE ARCHITECT § 6.4.1 An initial payment of ZERO ($ 0 ) shall be made upon execution of this Agreement and is the minimum payment under this Agreement. It shall be credited to the Owner's account in the final invoice. § 6.4.2 Unless otherwise agreed, payments for services shall be made monthly in proportion to services performed. Payments are due and payable upon presentation of the Architect's invoice. Amounts unpaid N/A (0) days after the invoice date shall bear interest at the rate entered below, (Insert rate of month4, or annual interest agreed upon) N/A § 6.4.3 The Owner shall not withhold amounts from the Architect's compensation to impose a penalty or liquidated damages on the Architect, or to offset sums requested by or paid to contractors for the cost of changes in the Work unless the Architect agrees or has been found liable for the amounts in a binding dispute resolution proceeding. § 6.4 .4 Records of Reimbursable Expenses and services performed on the basis of hourly rates shall be available to the Owner at mutually convenient times. ARTICLE 7 MISCELLANEOUS PROVISIONS § 7.1 This Agreement shall be governed by the law of the place where the Project is located, except that if the parties have selected arbitration as the method of binding dispute resolution, the Federal Arbitration Act shall govern Section 4.3. § 7.2 Terms in this Agreement shall have the same meaning as those in AIA Document A201-2007, General Conditions of the Contract for Construction. § 7.3 The Owner and Architect, respectively, bind themselves, their agents, successors, assigns and legal representatives to this Agreement. Neither the Owner nor the Architect shall assign this Agreement without the Init. AIA Document B102T" — 2007 (formerly B141"' —1997 Part 1). Copyright © 1917, 1926, 1948, 1951, 1953, 1958, 1961, 1963, 1966, 1967, 1970, 1974, 1977, 1987, 1997 and 2007 by The American Institute of Architects. All rights reserved. WARNING: This AIA® Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA® Document, or any portion of it, may result in severe civil and criminal / penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:57:36 on 09/07/2010 under Order No.5077229677_1 which expires on 10/13/2010, and is not for resale. User Notes: (1298672465) written consent of the other, except that the Owner may assign this Agreement to a lender providing financing for the Project if the lender agrees to assume the Owner's rights and obligations under this Agreement. e Owner requests the Architect to execute certificates, the proposed language of such certificates shall be to the Architect for review at least 14 days prior to the requested dates of execution. If the Owner requests the Architect to execute consents reasonably required to facilitate assignment to a lender, the Architect shall execute all such consents that are consistent with this Agreement, provided the proposed consent is submitted to the Architect for review at least 14 days prior to execution. The Architect shall not be required to execute certificates or consents that would require knowledge, services or responsibilities beyond the scope of this Agreement. .7 .5 Nothing contained in this Agreement shall create a contractual relationship with or a cause of action in favor of third party against either the Owner or Architect. 1^.6 Unless ;otherwiselrequired in this Agreement, the Architect shall have no responsibility for the discovery, removal' or disposal o1 or exposure of persons to, hazardous materials or toxic substances in any form at the Projectsite. have the right to include photographic or artistic representations of the design of the Project °motional and professional materials. The Architect shall be given reasonable access to the make such representations. However, the Architect's materials shall not include the Owner's ocpmpr>!.etary reformation if the Owner has previously advised the Architect in writing of the specific ormatron consideredlby the, Owner to be confidential or proprietary. The Owner shall provide professional credit far the Ardliitectin the Owner'spromotional materials for the Project. 7.8 If the Architects or:;Owner receives information specifically designated by the other party as "confidential" or "business proprieta y," the receiving party shall keep such information strictly confidential and shall not disclose it toany other person exzceptto:(1) its employees, (2) those who need to know the content of such information in order to perforin services or construction solely and exclusively for the Project, or (3) its consultants and contractors whose contracts include similar restrictions on the use of confidential information. 1RTICLE'8 SPECIAL TERMSAND CONDITIONS Special terms and condittens that modify this Agreement are as follows: ARTICLE 8.1 PROJECTED TIMELINE PHASE I 1. PROGRAMMING, MASTER Si'ri PLAN AND PRE -DESIGN: 80% COMPLETE TO DATE SCHEMATIC,DESIGN PHASE: PROJECTED COMPLETION SEPTEMBER 30, 2010 DESIGN DEVELOPMENT PHASE: PROJECTED COMPLETION NOVEMBER 15, 2010 PHASE II 4. CONSTRU0I N DOCUMENTS PHASE: PROJECTED COMPLETION FEBRUARY 15, 2011 PERMITS;' APPROVALS AND FUNDING ADMINISTRATION PHASE: PROJEC 1 EI) COMPLETION MARCH 15, 2011 6. BIDDING AND NEGOTIATION PHASE: PROJECTED COMPLETION APRIL 15, 2011 7. CONSTRUCTION COMPLETION PHASE: DICTATED BY GENERAL CONTRACTOR 8. PROJECT CLOSE-OUT PHASE: DICTATED BY GENERAL CONTRACTOR 9. POST CONSTRUCTION THRU WARRANTY: DICTATED BY GENERAL CONTRACTOR ARTICLE 9 SCOPE OF THE AGREEMENT This ,Agreement represents the entire and integrated agreement between the Owner and the Architect and supersedes!all,',prior negotiations, mentations or agreements, either written or oral. This Agreement may be amended only by written instrument signed by both Owner and Architect § 9.2 This Agreement is comprised of the following documents listed below: .1 AIA Document B102-2007, Standard Form Agreement Between Owner and Architect Inst. AIA Document B102T1° — 2007 (formerly B141 TM -1997 Part 1). Copyright © 1917, 1926, 1948,1951, 1953, 1958, 1961, 1963, 1966, 1967, 1970, 1974, 1977, 1987, 1997 and 2007 by The American Institute of Architects. All rights reserved. WARNING: This AIA® Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA® Document, or any portion of it, may result In severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 12:56:55 on 09/09/2010 under Order No.5077229677 1 which expires on 10/13/2010, and is not for resale. User Notes: (1212953684) Init. .3 Other documents: (List other documents, including the Architect's scope of services document, hereby incorporated into the Agreement.) SEE ATTACHED COST DATA SHEET DATED 8-3-2010 This Agreement entered into as of the day and year first written above. ignature) MAYOR ERNEST G. CLARK (Printed name and title) ARC e) N P. WALLENKAMP, LENKAMP, AIA PARTNER (Printed name and title) AIA Document B102T■ — 2007 (formerly B141 -1997 Part 1). Copyright ©1917, 1926, 1948, 1951, 1953, 1958, 1961, 1963, 1966, 1967, 1970, 1974, 1977, 1987, 1997 and 2007 by The American institute of Architects. Ali rights reserved. WARNING: This AIA® Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA® Document, or any portion of it, may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 12:09:00 on 09/07/2010 under Order No.5077229677_1 which expires on 10/13/2010, and is not for resale. User Notes: (1147822697) PROFESSIONAL SERVICES ESTIMATE I w v. M m % 1 i K N N _m p O O g 1 AS V mV 1 1 apD VU . 4' i s 1 1 1 I I l Total Project Cost with Engineering ai U N Q1 m ea ik q m o a o& os .2 IP -a = tgN ai m mN M Oa -ass O $ IR OM ER ij Z2 !mg 1 i ea M ea O w O w O O (m� RI M H N Mechanical om MN a �y l� N m N i X§ p F2 p 2 m . {y p N P m N m m k N w a N 1 u 11 E os os os OSi t .$ a m J os w os os .2 '§ R,y NmmN q w U NPm gV. a mHmgmgi k R Ak 2t4.2 gg f a §wF 1 aM g a w m P A L1 T. y N w P ` w I r 1 mx w g i3 PROFESSIONAL SERVICES ESTIMATE I w v. M aj y i K N N O g AS V mV VU m iPI ai ea o a o& os .2 IP -a = m mN Oa -ass IR OM ER ij Z2 !mg 1 i ea M ea O w O w O O (m� RI M H N N om MN a �y l� N m N i X§ p F2 p 2 m al {y p N P m N m m k N mm M a N 1 os os os os OSi t .$ os os os .2 '§ R,y NmmN S! NPm gV. a mHmgmgi Ak 2t4.2 §wF 1 aM m P m w T. m N w P ` N 1 I r 1 ow 32 g m 1 G $i SCHEMATIC DESIGN Coordination Meetings --- NI DESIGN DEVELOPMENT 'Mil II 111111 lid' 811118E i i ZF .1 Ofpf nil Total Hops Total Architectural Cod — Tii; i d 3 uppuna ogmmamm o�7Vf V$0 °f °°51 °v1FFi°! Il GI �1 N m P m m r m a o m n m m m R N 2 R H 2 I PROFESSIONAL SERVICES ESTIMATE Prepared By: Wallenkamp Approved By: Project Title: Waterloo 813!2010 Description: Architectural Management Team Design Team c 1 1- cc 1 c P7 P6 P5 P4 P3 P2 T4 T3 Cleri I $121 8121 8114 8105 898 587 $85 878 $61' Task Description % Complete HRS HRS HRS HRS HRS HRS HRS HRS HRS 1 0 SCHEMATIC DESIGN 2 40 Coordination Meetings 16 24 3 6 Calculations 6 4 18 Equipment Selection 12 6 5 58 Preliminary Layout 4 24 241 6 6 3 Outline Specifications 2 1 7 3 Design narrative 2 - 1 32 60 0 0 28 0 6 0 2 $3,872 87,260 $0 $0 $2,688 $0 $510 $0 $122, $14,452 8 0 DESIGN DEVELOPMENT 9 32 Coordination Meetings 16 16 i 10 12 Revise Calculations 12 11 72 Revise Schematic Design 16 24 32 12 12 Revise Equipment Selection 8 4 13 44 Sections, Details, Schedules 4 16 24 14 0 Outline Specifications 44 72 0 0 56 0 0 0 0 $5,324 $8,712 $0 $0 $5,376 $0 $0 $0 $0 $19,412 15 0 CONSTRUCTION DOCUMENTS 16 72 Coordination Meetings 4 36 24 8 17 690 Finalize Plans 210 320 160 18 264 Complete Sections, Details, Schedules 60 140 40 24 19 220 Complete Specifications 40 60 60 60 20 8 QC Review 8 21 50 Bid Assistance,30 8 12 4 384 0 0 552 0 268 0 96 $484 $46,464 $0 $0 $52,992 $0 822,780 $0 $5,856 $128,576 22 0 CONSTRUCTION ADMINISTRATION 23 52 Shop Drawing Review 30 22 24 160 Site Observations 120 40 25 33 Final Punch Ust 8 20 5 26 38 Record drawings 24 12 I 8 170 0 0 91 0 0 0 12 $968 $20,570 $0 $0 $8,736 $0 $0 $0 $732 $31,006 Total Hours 1,885 88 686 0 0 727 0 274 0 110 Total Architectural Cost $193,446 $10,648 $83,006 $0 $0 $69,792 $0 $23,290 $0 $6,710 Structural Civil Landscape Fire/plumb Mechanical Electrical Survey Geotechnical Phase of Contract 80 $3,296 $1,901 $0 $0 $4,250 $6,300 Schematic Design Total $30,199 $1,210 $9,430 $2,231 $3,798 $1,686 $3,322 $4,000 Design Development Total $45,089 $15,178 $10,090 $2,986 $20,264 $25,772 $27,194 Construction Document Total $230,060 $4,604 $3,169 $1,452 $4,128 $3,072 $4,840 Construction Phase Total $52,271 $20,992 $25,985 $8,570 $28,190 $30,530 $35,356 $343,069 Total Protect Cost with Engineering $357,619