Loading...
HomeMy WebLinkAboutPeterson Contractors - FY18 Boathouse Enhancements Cont 940-10/2/2017Please return this copy to: City Clerk & Finance Dept. 715 Mulberry St. Waterloo, IA 50703 FORM OF CONTRACT CONTRACT FOR THE CONSTRUCTION OF F.Y. 2018 WATERLOO BOATHOUSE ENHANCEMENTS CITY OF WATERLOO, IOWA CONTRACT NO. 940 This contract made and entered into this i day of Oji , 20!7, by and between the City of Waterloo, Iowa, a Municipal Corporation, (hereinafter referred to PETERSCI CONTRACTORS !MC. as City), and - _-- - - _ _ , _ of Reinbeck, Iowa, (hereinafter referred to as Contractor), WITNESSETH: PAR. 1 PAR. 2 PAR. 3 Contractor agrees to build and construct the Base Bid, Alternate 'A' and Alternate `B' items of the F.Y. 2018 WATERLOO BOATHOUSE ENHACEMENTS, CITY OF WATERLOO, IOWA, CONTRACT NO. 940 and furnish all necessary tools, equipment, materials, and labor necessary to do all the work called for in the plans and specifications in a workmanshiplike manner and for the prices set forth in Contractor's proposal, which was accepted by the City, and which is understood and agreed to be a part of this contract. It is understood and agreed that the resolution adopted by the City Council ordering the construction of the improvement, the Notice to Contractors as published, the Instruction to Bidders, the Form of Proposal, the Construction and Maintenance Bonds, the Council Proceedings relating to this matter, and the Plans and Specifications shall all be considered as forming a part of the contract the same as though they were each set out in said contract. The Contractor agrees to furnish at its own cost and expense, all necessary materials and labor for said work and to construct said improvements in a thorough, substantial, and workmanlike manner, and in strict accordance with the requirements of this contract, and FORM OF CONTRACT PAGE 1 OF 5 PAGES 33q of the plans and specifications made a part hereof by reference, and to the satisfaction and approval of the City and its engineer. PAR. 4 The Contractor agrees to perform said work and install said improvements on the terms set out in bid or proposal to the City which has been accepted by the City and which is by reference made a part of this contract. PAR. 5 PAR. 6 PAR. 7 PAR. 8 The Contractor agrees to commence said work within ten (10) working days after receipt of "Notice to Proceed" and complete it within Fifty (50) working days thereafter unless an extension of time is granted in writing by the Council of the City. Should the Contractor fail to complete said improvements in strict accordance with the terms and conditions of this contract, or the plans and specifications therefor promptly by the date herein specified, the City may pay such additional sums as it may be required to pay by reason of the failure of said contractor and deduct any and all such sums from any amount then due the Contractor. The Contractor agrees to comply with and obey all ordinances of the City of Waterloo, Iowa, relating to the obstruction of streets and alleys, keeping open passage ways for water, traffic, and protecting any excavations in any street or alley, and maintaining proper and sufficient barricades with lights and signals during all hours of darkness, to see that the backfilling is properly done, and agrees to keep the City whole and defend any and all suits that may be brought against the City by reason of any injuries that may be sustained by any person or property allegedly caused by the Contractor, or his agents, while work is done pursuant to this agreement. The Contractor agrees that in the event a law suit is brought against the City for damages allegedly sustained by reason of any act, omission or negligence of the Contractor or its agents, or on account of any injuries allegedly sustained by reason of any obstruction, hole, depression or barrier placed or dug by the defendant or its agents, in the doing of the work herein contracted for, that it will defend said suit and save the City harmless therein, and in case judgment is rendered against the City, the Contractor agrees to pay the same promptly. The Contractor agrees to carry public liability insurance in a solvent company in a sufficient amount to protect the City and those who use the streets of the City. FORM OF CONTRACT PAGE 2 OF 5 PAGES PAR. 9 PAR, 10 The City shall have the right to appoint one or more construction reviewers who shall review the progress of the work in detail; also, to make any test or any material to be used in such work. No material shall be used in any work until the same has first been approved by the construction reviewer. Such construction reviewer shall have full authority to pass judgment upon all materials and upon the manner of doing the work, and their judgment on rejecting any materials, substance, or manner of work shall be final unless it is revoked or modified by the City Engineer. Any material, which has been rejected by the construction reviewer, shall be at once removed from the line of work and shall not be again taken thereon or placed with the material proposed to be used without the written consent of the City Engineer. PAR. 11 The Contractor shall maintain no cause of action against the City on account of delays and prosecution of work, but if said work is delayed by the City, the Contractor shall have such extra time for completion of the job as was lost by reason of the delay caused by the City. PAR. 12 The Contractor agrees to pay punctually all just claims of labor, material, men, or subcontractors who shall perform labor or furnish materials entering into this improvement. It is agreed that the City need not pay the Contractor until all such claims are paid by the Contractor. It is agreed that the City shall not be liable for said labor, material, or men under this contract. PAR. 13 The Contractor agrees to furnish the City, simultaneously with this contract, a bond on a form to be provided by the City in the amount provided by law as stated in the Notice to Bidders, which shall be for the benefit of the City, and any and all persons injured by the breach of any of the terms of this contract. Said bond shall be filed with the City Clerk and shall be subject to the approval of the City Council, and is by reference made a part of this contract. PAR. 14 The Contractor agrees that should it abandon work under this contract or cease the prosecution thereof for a period of thirty (30) consecutive days without reasonable cause, and should it fail to proceed with said work within ten (10) days after a notice to continue or carry it on has been mailed to it at the address given herein by the City, or after such notice has been served on it, then the City may proceed to complete said work, using any material, tools, or machinery found along said line of work, doing the work either by contract or as it may elect, and the Contractor and the sureties on its FORM OF CONTRACT PAGE 3 OF 5 PAGES PAR. 15 PAR. 16 PAR. 17 PAR. 18 PAR. 19 PAR. 20 bond shall be liable to the City for the costs and expenses so paid out. Said costs shall be retained by the City from any compensation due, or to become due the Contractor, and may be recovered by the City in an action upon Contractor's bond. In consideration of the full compliance on the part of the Contractor with all the provisions, stipulations, and conditions hereof, or contained in the various instruments made a part of this contract by reference, and upon completion and acceptance of said work, the City agrees to pay to the Contractor, in the manner set out in the Notice to Contractors, the amount of money due the Contractor for work performed and accepted, at the unit prices set out in the Contractor's proposal, which has been accepted by the City. The total amount of the contract, based on the Engineer's estimates of quantities and the Contractor's unit bid prices, and for which 100% surety bond is required is $787,364.75 . After the completion of said work, the Contractor agrees to remove all debris and clean up said streets, and to save the City harmless from any damage allegedly resulting from a failure to clean up and remove the debris or put the street back in a proper condition for travel. This contract is not divisible, but in the event of a conflict between this contract and the various instruments incorporated by reference, this contract shall govern. Before the Contractor shall be entitled to receive final payment for work done under this contract, it shall execute and file a bond in the penal sum of not less than 100% of the total amount of the contract, same to be known as "Maintenance Bond," and which bond must be approved by the City Council, and which bond is in addition to the bond given by the Contractor to guarantee the completion of the work. The Contractor shall maintain all work done hereunder in good order for the period of two (2) years from and after the date it is accepted by the Council of the City of Waterloo, Iowa. Said maintenance shall be made without expense to the City or the abutting property. In the event of the failure or default of the Contractor to remedy any or all defects appearing in said work within a period of two (2) years from the date of its acceptance by said Council, and after having been given ten (10) days' notice so to do by registered letter deposited in the United States Post Office in said town, addressed to said contractor at the address herein given, then the City may proceed to FORM OF CONTRACT PAGE 4 OF 5 PAGES remedy such defects. The costs and expenses thereof to be recovered from the Contractor and the sureties on its maintenance bond by an action brought in any court of competent jurisdiction. PAR. 21 The Contractor shall give notice to said City by registered letter directed to the Mayor or City Clerk/Auditor thereof not more than four (4) and not less than three (3) months prior to the expiration of the term during which the Contractor is required to maintain said improvements, in good repair by the terms of its Contract. The liability of the Contractor and of the sureties on its bond for maintenance of the said improvements shall continue until three (3) months after such notice has been given to the City, and, in any event, until two (2) years after the acceptance of the work. CITY OF WATERLOO, IOWA a -L -Q AA-ZIA' Mayor president Title: Approved by the City Council of the City of Waterloo, Iowa, this day of 0 , 20L. FORM OF CONTRACT PAGE 5 OF 5 PAGES ATTEST: , City Clerk Waterloo, Iowa FORM OF CONTRACT PAGE 6 OF 5 PAGES PERFO[ MAS' KNOW ALL MEN BY THESE PRESENTS: That we, Peterson Contractors, Inc. of Rei Travelers Casualty and Surety Corr Hartford, CT (the "Surety"), Waterloo, Iowa (the "Obligee"), in the pe' Thousand Three Hundred Sixty-four and lawful money of the United States, for the contract (the "Contract") dated on or about \-"(-z / r purpose of constructing the Base Bid, Alternate 'A' and Alternate 'B' of the F.Y. 2018 Waterloo Boathouse Enhancements, City of Waterloo, IA, Contract No. 940. The Contract is incorporated herein by reference as though fully set forth herein. `'M HOLM M IMPORTANT Enclosed bond and not dated. Date the bond cannot bewer of attorney the date of the forms are Contract.prior to Please be sure to complete forms using the of the Contract when that is determined. Thank you. Whenever the Principal shall be and is declared by the Obligee to be in default under the Contract, with the Obligee having performed its obligations in the Contract, then the Surety, acknowledging that time is of the essence, may promptly remedy the default, or shall promptly undertake to: 1. Complete the Contract in accordance with its terms and conditions; or 2. Obtain one or more bids for completing the Contract in accordance with its terms and conditions, and upon determination by the Surety of the lowest responsible bidder, or negotiated proposal, or, if the Obligee elects, upon determination by the Obligee and the Surety jointly of the lowest responsible bidder, or negotiated proposal, arrange for a contract between such party and the Obligee. The Surety will make available as work progresses sufficient funds to pay the cost of completion less the balance of the Contract price. The cost of completion includes responsibilities of the Principal for correction of defective work and completion of the Contract, the Obligee's legal and design professional costs resulting directly from the Principal's default, and liquidated damages or actual damages if no liquidated damages are specified in the Contract. The term "balance of the Contract price" means the total amount payable by the Obligee to the Principal under the Contract and any amendments thereto, less the amount properly paid by the Obligee to the Principal; or 3. Determine the amount for which it is liable to the Obligee and pay the Obligee that amount as soon as practicable. In the event this bond is enforced, Principal and Surety agree to indemnify Obligee and hold Obligee harmless from and against any and all costs of enforcement, including but not limited to reasonable attorneys' fees and expenses. Performance Bond Page 1 of 2 Every Surety on this bond shall be deemed and held, any contract to the contrary notwithstanding, to consent to each and all of the following matters, without notice: 1. To any extension of time to the Contract in which to perform the Contract. 2. To any change in the plans, specifications, or Contract when such change does not involve an increase of more than twenty percent (20%) of the total Contract price, and shall then be released only as to such excess increase. 3. That no provision of this bond or of any other contract shall be valid which limits to less than one (1) year from the time of the acceptance of the work the right to sue on this bond for defect in workmanship or material not discovered or known to the Obligee at the time such work was accepted. If the Principal performs the Contract, then this bond shall be null and void; otherwise it shall remain in full force and effect. In no event shall the Surety's total obligation exceed the penal amount of this bond. Terms used herein shall include, as appropriate, the singular or plural number, or the masculine, feminine or neuter gender. IN WITNESS WHEREOF, the undersigned Principal and Surety have executed this Performance Bond as of «/27l PRINCIPAL SURETY Peterson Contractors, Inc. Travelers Casualty and Surety Company of America Name Name By: c. C c,�dE tl C9. l'e -e rsoll president Title: Performance Bond Title: Anne Crowner, Attorney -in -Fact [attach Power of Attorney] Page 2 of 2 NOTE: Date of BOND must not be prior to date of Contract. If CONTRACTOR is Partnership, all partners should execute BOND. If this project includes Federal Funds, the following applies to the payment bond: IMPORTANT: Surety companies executing bonds must appear on the Treasury Department's most current list (Circular 570 as amended) and be authorized to transact business in the State where the project is located. Performance Bond Page 3 of 2 Bond No. 106773100 PAYMENT BOND KNOW ALL MEN BY THESE PRESENTS: that Peterson Contractors, Inc. (Name of Contractor) 104 Black Hawk St., Reinbeck, IA 50669 (Address of Contractor) an Iowa , hereinafter called Principal, (Corporation, Partnership or Individual) and, Travelers Casualty and Surety Company of America (Name of Surety) One Tower Square, Hartford, CT 06183 (Address of Surety) hereinafter called Surety, are held and firmly bound unto City of Waterloo 715 Mulberry St., Waterloo IA 50703 (Name of Owner) (Address of Owner) hereinafter called OWNER, in the penal sum of Seven Hundred Eighty-seven Thousand Three Hundred Sixty-four and Seventy-five Cents Dollars,($787,364.75) in lawful money of the United States, for the payment of which sum well and truly to be made, we bind ourselves, successors, and assigns, jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION is such that whereas, the Principal entered into a certain contract with the OWNER, dated the tot -2. /i 1 day of 20 , a copy of which is hereto attached ancl made a part hereof for the construction of: the Base Bid, Alternate 'A' and Alternate 'B' of the F.Y. 2018 Waterloo Boathouse Enhancements, City of Waterloo. Iowa Contract 940 NOW, THEREFORE, if the Principal shall promptly make payment to all persons, firms, SUBCONTRACTORS, and corporations furnishing materials for or performing labor in the prosecution of the WORK provided for in such contract, and any authorized extension or modification thereof, including all amounts due for materials, lubricants, oil, gasoline, coal and coke, repairs on machinery, equipment and tools, consumed or used in connection with the construction of such WORK, and all insurance premiums on said WORK, and for all labor, performed in such WORK whether by SUBCONTRACTOR or otherwise, then this obligation shall be void; otherwise to remain in full force and effect. PROVIDED, FURTHER, that the said Surety for value received hereby stipulates and agrees that no change, extension of time, alteration or addition to the terms of the contract or to the WORK to be performed thereunder or the SPECIFICATIONS accompanying the same shall in any wise affect its obligation on this BOND, and it does hereby waive notice of any such change, extension of time, alteration or addition to the terms of the contract or to the WORK or to the SPECIFICATIONS. PROVIDED, FURTHER, that no final settlement between the OWNER and the CONTRACTOR shall abridge the right of any beneficiary hereunder, whose claim may be unsatisfied. IN WITNESS HEREOF, this instrument is executed in Three (3) counterparts, each one of (number) which shall be deemed an original, this the clay of �;�=4►�2 20 n . ATTEST: C4� n Secretary (SEAL) Witness as to Principal 1-n; dr,tte-1 Q- P.O. Box A Reinbeck IA 50669-0155 (Address) Witness as to Surety ion ung P.O. Box 9207. Des Moines IA 50306-9207 (Address) Peterson Contractors, Inc. Principal By K'(0 s) C.or-J0 .e 11 Q. Pe_Ae. c son, V �e.,a.cic P.O. Box A, Reinbeck, IA 50669-0155 (Address) ualt Hold Suret Company of America "09i �' _ Surety ,f Attorney -in -Fact Anne Crowner P.O. Box 9207. Des Moines, IA 50306-9207 (Address) NOTE: Date of BOND must not be prior to date of Contract. If CONTRACTOR is Partnership, all partners should execute BOND. If this project includes Federal Funds, the following applies to the payment bond: IMPORTANT: Surety companies executing bonds must appear on the Treasury Department's most current list (Circular 570 as amended) and be authorized to transact business in the State where the project is located. R Farmington Casualty Company Fidelity and Guaranty Insurance Company Fidelity and Guaranty Insurance Underwriters, Inc. St. Paul Fire and Marine Insurance Company St. Paul Guardian Insurance Company Attorney -In -Fact No. 231471 Surety Bond No. or Project Description: POWER OF ATTORNEY St. Paul Mercury Insurance Company Travelers Casualty and Surety Company Travelers Casually and Surety Company of America United States Fidelity and Guaranty Company Principal: Peterson Contractors, Inc. 106773100 Obligee: City of Waterloo KNOW ALL MEN BY THESE PRESENTS: That Farmington Casualty Company, St. Paul Fire and Marine Insurance Company, SC Paul Guardian Insurance Company, St, Paul Mercury Insurance Company, Travelers Casualty and Surety Company, Travelers Casualty and Surety Company of America, and United States Fidelity and Guaranty Company are corporations duly organized under the laws of the State of Connecticut, that Fidelity and Guaranty Insurance Company is a corporation duly organized under the laws of the State of Iowa, and that Fidelity and Guaranty Insurance Underwriters, Inc. is a corporation duly organized under the laws of the State of Wisconsin (herein collectively called the "Companies"), and that the Companies do hereby make, constitute and appoint Craig E. Hansen, Jay D. Freiermuth, Brian M. Deimerly, Cindy Bennett, Anne Crowner, Tim McCulloh, Stacy Venn, Shirley S. Bartenhagen, and Dione R. Young of the City of West Des Moines State of Iowa, their true and lawful Attorney(s)-in-Fact, each in their separate capacity if more than one is named above, to sign, execute, seal and acknowledge any and all bonds, recognizances, conditional undertakings and other writings obligatory in the nature thereof on behalf of the Companies in their business of guaranteeing the fidelity of persons, guaranteeing the performance of contracts and executing or guaranteeing bonds and undertakings required or permitted in any actions or proceedings allowed by law. IN WITNESS WHEREOF, the Companies have caused this instrument to be signed and their corporate seals to be hereto affixed, this 24th day of October, 2016. Farmington Casualty Company Fidelity and Guaranty Insurance Company Fidelity and Guaranty Insurance Underwriters, Inc. St. Paul Fire and Marine Insurance Company St. Paul Guardian Insurance Company St. Paul Mercury Insurance Company Travelers Casualty and Surety Company Travelers Casualty and Surety Company of America United States Fidelity and Guaranty Company State of Connecticut City of Hartford ss. By: Robert L. Raney, Senior Vice President On this the 24th day of October, 2016, before me personally appeared Robert L. Raney, who acknowledged himself to be the Senior Vice President of Farmington Casualty Company, Fidelity and Guaranty Insurance Company, Fidelity and Guaranty Insurance Underwriters, Inc., St. Paul Fire and Marine Insurance Company, St. Paul Guardian Insurance Company, St. Paul Mercury Insurance Company, Travelers Casualty and Surety Company, Travelers Casualty and Surety Company of America, and United States Fidelity and Guaranty Company, and that he, as such, being authorized so to do, executed the foregoing instrument for the purposes therein contained by signing on behalf of the corporations by himself as a duly authorized officer. In Witness Whereof, I hereunto set my hand and official seal. My Commission expires the 30th day of June, 2021. (4.Aa. C is t"ntQ.t1d: Marie C. Tetreault, Notary Public This Power of Attorney is granted under and by the authority of the following resolutions adopted by the Boards of Directors of Farmington Casualty Company, Fidelity and Guaranty Insurance Company, Fidelity and Guaranty Insurance Underwriters, Inc., St. Paul Fire and Marine Insurance Company, St. Paul Guardian Insurance Company, St. Paul Mercury Insurance Company, Travelers Casualty and Surety Company, Travelers Casualty and Surety Company of America, and United States Fidelity and Guaranty Company, which resolutions are now in full force and effect, reading as follows: RESOLVED, that the Chairman, the President, any Vice Chairman, any Executive Vice President, any Senior Vice President, any Vice President, any Second Vice President, the Treasurer, any Assistant Treasurer, the Corporate Secretary or any Assistant Secretary may appoint Attorneys -in -Fact and Agents to act for and on behalf of the Company and may give such appointee such authority as his or her certificate of authority may prescribe to sign with the Company's name and seal with the Company's seal bonds, recognizances, contracts of indemnity, and other writings obligatory in the nature of a bond, recognizance, or conditional undertaking, and any of said officers or the Board of Directors at any time may remove any such appointee and revoke the power given him or her; and it is FURTHER RESOLVED, that the Chairman, the President, any Vice Chairman, any Executive Vice President, any Senior Vice President or any Vice President may delegate all or any part of the foregoing authority to one or more officers or employees of this Company, provided that each such delegation is in writing and a copy thereof is filed in the office of the Secretary; and it is FURTHER RESOLVED, that any bond, recognizance, contract of indemnity, or writing obligatory in the nature of a bond, recognizance, or conditional undertaking shall be valid and binding upon the Company when (a) signed by the President, any Vice Chairman, any Executive Vice President, any Senior Vice President or any Vice President, any Second Vice President, the Treasurer, any Assistant Treasurer, the Corporate Secretary or any Assistant Secretary and duly attested and sealed with the Company's seal by a Secretary or Assistant Secretary; or (b) duly executed (under seal, if required) by one or more Attorneys -in -Fact and Agents pursuant to the power prescribed in his or her certificate or their certificates of authority or by one or more Company officers pursuant to a written delegation of authority; and it is FURTHER RESOLVED, that the signature of each of the following officers: President, any Executive Vice President, any Senior Vice President, any Vice President, any Assistant Vice President, any Secretary, any Assistant Secretary, and the seal of the Company may be affixed by facsimile to any Power of Attorney or to any certificate relating thereto appointing Resident Vice Presidents, Resident Assistant Secretaries or Attorneys -in -Fact for purposes only of executing and attesting bonds and undertakings and other writings obligatory in the nature thereof, and any such Power of Attorney or certificate bearing such facsimile signature or facsimile seal shall be valid and binding upon the Company and any such power so executed and certified by such facsimile signature and facsimile seal shall be valid and binding on the Company in the future with respect to any bond or understanding to which it is attached. I, Kevin E. Hughes, the undersigned, Assistant Secretary, of Farmington Casualty Company, Fidelity and Guaranty Insurance Company, Fidelity and Guaranty Insurance Underwriters, Inc., St. Paul Fire and Marine Insurance Company, St. Paul Guardian Insurance Company, St. Paul Mercury Insurance Company, Travelers Casualty and Surety Company, Travelers Casualty and Surety Company of America, and United States Fidelity and Guaranty Company do hereby certify that the above and foregoing is a true and correct copy of the Power of Attorney executed by said Companies, which is in full force and effect and has not been revoked. IN TESTIMONY WHEREOF, I have hereunto set my hand and affixed the seals of said Companies this day of , 2017 . Kevin E. Hughes, Assistant Secretary To verify the authenticity of this Power of Attorney, cal/1-800-421-3880 or contact us at www.travelersbond.com. P/ease refer to the Attorney -In -Fact number, the above-named individuals and the details of the bond to which the power is attached. PETER -3 OP ID: COZA 4CORO CERTIFICATE OF LIABILITY INSURANCE DATE 09/25/OD/YYYY) 09/25/2017 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER LSB Insurance 242 Tower Park Waterloo, IA 50701 Kevin Boyle _ CONTACT NAME; locC. No EDT INC, No): (MMIDDYYYY) E-MAIL ADDRESS: INS(JRER(S) AFFORDING COVERAGE NAIC 4 INSURER A: Hartford Fire Insuranc Co 19682 INSURED Peterson Contractors, Inc. Reinbeck Motor Inc. PO Box A/104 Blackhawk St Reinbeck, IA 50669 INSURER B: Trumbull Insurance Co 27120 INSURER c: Berkshire Hathaway Ins Co 22276 INSURER D:Zurich American Ins Co 16535 INSURER E : INSURER F : CLAIMS -MADE ( XJ OCCUR COVERAGES CERTIFICATE NUMBER: • THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. R /LTR TYPE OF INSURANCE /NSR SUBR WVD POLICY NUMBER (DM MMIDD/YYYYY) (MMIDDYYYY) LIMITS A GENERAL X LIABILITY COMMERCIAL GENERAL LIABILITY X 41CSEQU2151 07/01/2017 07/01/2018 EACH OCCURRENCE $ 1,000,000 DAMAGE TO RENTEO PREMI$ES(Ea o<wrrencal $ 300,000 CLAIMS -MADE ( XJ OCCUR MED EXP (Any one person) $ 10,000 X Blnkt Contractual PERSONAL 8 ADV INJURY $ 1,000,000 X XCU Coverage GENERAL AGGREGATE $ 2,000,000 GENII AGGREGATE POLICY X LIMIT APPLIES ,PIF T PER: LOC PRODUCTS - COMP/OPAGG $ 2,000,000 $ A AUTOMOBILE X X LIABILITY ANY AUTO ALL OWNED AUTOS HIRED AUTOS X SCHEDULED AUTOS NON -OWNED AUTOS 41 CSE QU2152 07/01/2017 07/01/2018 COMBINED SINGLE LIMIT 2,000,000 (Ea accident) $ BODILY INJURY (Per person) $ BODILY INJURY (Per accident) $ PROPERTY DAMAGE $ JPER ACCIDENT) $ C X UMBRELLA LIAB EXCESS LIAB X OCCUR CLAIMS -MADE 47-XSF-100514-02 07/01/2017 07/01/2018 EACH OCCURRENCE $ 2,000,000 AGGREGATE $ 2,000,000 DED RETENT ON$ $ B WORKERS COMPENSATION AND EMPLOYERS' LIABILITY ANY PROPRIETOR/PARTNER/EXECUTIVE OFFICER/MEMBER EXCLUDED? (Mandatory In NH) Byes describe under DESCRIPTION OF OPERATIONS below Y/N N N / A 41WNQU2150 07/01/2017 07/01/2018 X WC STATU- TORY LIMITS 1OTH- TEL E.L. EACH ACCIDENT $ 1,000,000 E.L. DISEASE - EA EMPLOYEE $ 1,000,000 E.L. DISEASE- POLICY LIMIT $ 1,000,000 D RentfLease Equip. CPP9267064-06 07/01/2017 07/01/2018 Rent/Leas 5,000,000 DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES (Attach ACORD 101, Additional Remarks Schedule If more space Is required) RE: .37339 Waterloo Boathouse Enhancements The City of Waterloo, Iowa is named as an additional insured per contract requirements. CERTIFICATE HOLDER CANCELLATION WATER -1 City of Waterloo 715 Mulberry St. Waterloo, IA 50701 SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. AUTHORIZED REPRESENTATIVE ACORD 25 (2010/05) ©1988.2010 ACORD CORPORATION. All rights reserved. The ACORD name and logo a e registered marks of ACORD ' POLICY NUMBER; 41 CSE QU2151 4,„ THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. ADDITIONAL INSURED - OWNERS, LESSEES OR CONTRACTORS - OPTION I This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART SCHEDULE Name Of Additional Insured Person(s) Or Organization(s): Designated Project(s) Or Location(s) Of Covered Operations: All, except Additional Insureds that are insured under a separate additional insured endorsement on this policy ALL Information required to complete this Schedule, if not shown above, will be shown in the Declarations. A. With respect to those person(s) or organizalion(s) shown in the Schedule above when you have agreed in a written contract or written agreement to provide insurance such as is afforded under this policy to them, Subparagraph f., Any Other Party, under the Additional Insureds When Required By Written Contract, Written Agreement Or Permit Paragraph of Section II — Who Is An Insured is replaced with the following: f. Any Other Party Any other person or organization who is not an insured under Paragraphs a. through e. above, but only with respect to liability for "bodily injury", "property damage" or "personal and advertising injury" caused, in whole or in part, by your acts or omissions or the acts or omissions of those acting on your behalf: (1) In the performance of your ongoing operations for such additional insured at the project(s) or location(s) designated in the Schedule: (2) In connection with your premises owned by or rented to you and shown in the Schedule; or Form HS 24 80 07 13 (3) In connection with "your work" for the additional insured at the project(s) or location(s) designated in the Schedule and included within the "products - completed operations hazard", but only if: (a) The written contract or written agreement requires you to provide such coverage to such additional insured at the project(s) or location(s) designated in the Schedule; and (b) This Coverage Part provides coverage for "bodily injury" or "property damage" included within the "products -completed operations hazard". The insurance afforded to the additional insured shown in the Schedule applies: (1) Only if the "bodily injury" or "property damage" occurs, or the "personal and advertising injury" offense is committed: (a) During the policy period; and (b) Subsequent to the execution of such written contract or written agreement; and © 2013, The Hartford (Includes copyrighted material of Insurance Services Office, Inc., with its permission.) Page 1 of 2 (c) Prior to the expiration of the period of time that the written contract or written agreement requires such insurance be provided to the additional insured. (2) Only to the extent permitted by law; and (3) Will not be broader than that which you are required by the written contract or written agreement to provide for such additional insured. Wth respect to the insurance afforded to the person(s) or organization(s) that are additional insureds under this endorsement, the following additional exclusion applies: This insurance does not apply to "bodily injury", "property damage" or "personal and advertising injury" arising out of the rendering of, or the failure to render, any professional architectural, engineering or surveying services, including: (1) The preparing, approving, or failing to prepare or approve maps, shop drawings, opinions, reports, surveys, field orders, change orders, designs or specifications; or (2) Supervisory, inspection, architectural or engineering activities, The limits of insurance that apply to the additional insured shown in the Schedule are described in the Limits Of Insurance section. How this insurance applies when other insurance is available to the additional insured is described in the Other Insurance Condition in Section IV — Commercial General Liability Conditions, except as otherwise amended below. B. With respect to insurance provided to the person(s) or organization(s) that are additional insureds under this endorsement, the When You Add Others As An Additional Insured To This Insurance subparagraph, under the Other Insurance Condition of Section IV — Commercial General Liability Conditions Is replaced with the following: Page 2 of 2 When You Add Others As An Additional Insured To This Insurance (a) Primary Insurance When Required By Contract This insurance is primary if you have agreed in a written contract or written agreement that this insurance be primary. If other insurance Is also primary, we will share with all that other insurance by the method described in Paragraph (c) below. This insurance does not apply to other insurance to which the additional insured in the Schedule has been added as an additional insured. (b) Primary And Non -Contributory To Other Insurance When Required By Contract This insurance is primary to and will not seek contribution from any other insurance available to an additional insured under your policy provided that: (1) The additional insured in the Schedule is a Named Insured under such other insurance; and (0) You have agreed in a written contract or written agreement that this insurance would be primary and would not seek contribution from any other insurance available to the additional insured in the Schedule, (c) Method Of Sharing If all of the other insurance permits contribution by equal shares, we will follow this method also. Under this approach, each insurer contributes equal amounts until it has paid its applicable limit of insurance or none of the loss remains, whichever comes first. If any of the other insurance does not permit contribution by equal shares, we will contribute by limits. Under this method, each insurer's share is based on the ratio of its applicable limit of insurance to the total applicable limits of insurance of all insurers. All other terms and conditions in the policy remain unchanged. Form HS 24 80 07 13 September 26, 2017 Jamie Knutson, P. E. City of Waterloo 715 Mulberry Street Waterloo, IA 50703 WAYNE CLAASSEN ENGINEERING AND SURVEYING, INC. 2705 University Avenue P.O. Box 898 Waterloo, Iowa 50704 Fax 319/235-0028 319/235-6294 RE: F.Y. 2018 Waterloo Boathouse Enhancements, Contract No. 940 Dear Jamie: We are enclosing herewith three (3) signed Contracts, two (2) copies of the Performance Bond and Payment Bond and the Certificate of Insurance from Peterson Contractors for the above. Please return all copies of the Contract to our office once they are signed by the Mayor. Very truly yours, WAYNE CLAASSEN ENGINEERING AND SURVEYING, INC. William J. Cla en, P. E. WJC/dad Enclosures (Folder\Misc CorresUamie Knutson -Waterloo Boathouse 94011)