Loading...
HomeMy WebLinkAboutShaw Electric - Airport Ceiling Lighting Replacement - 7/15/2019FORM OF CONTRACT FOR THE CONSTRUCTION OF Terminal Building LED Lighting - TERMINAL IMPROVEMENTS WATERLOO REGIONAL AIRPORT In the City of Waterloo, Iowa IDOT CSVI PROJECT NO. 91190AL0200 IDOT CONTRACT NO. 20601 This contract made and entered into this day of , 2019, by and between the City of Waterloo, Iowa, a Municipal Corporation, (hereinafter refe red to as City), and Shaw Electric, Inc. , of 905 Cedar Bend Street, Waterloo, Iowa, 50703 (hereinafter referred to as Contractor), WITNESSETH: PAR. 1 Contractor agrees to build and construct the TERMINAL BUILDING LED LIGHTING - TERMINAL IMPROVEMENTS, and furnish all necessary tools, equipment, materials, and labor necessary to do all the work called for in the plans and specifications in a workmanshiplike manner and for the prices set forth in Contractor's proposal, which was accepted by the City, and which is understood and agreed to be a part of this contract. PAR. 2 It is understood and agreed that the resolution adopted by the City Council ordering the construction of the improvement, the Notice to Contractors as published, the Instruction to Bidders, the Form of Proposal, the Construction and Maintenance Bonds, the Council Proceedings relating to this matter, and the Plans and Specifications shall all be considered as forming a part of the contract the same as though they were each set out in said contract. PAR. 3 The Contractor agrees to furnish at its own cost and expense, all necessary materials and labor for said work and to construct said improvements in a thorough, substantial, and workmanlike manner, and in strict accordance with the requirements of this contract, and of the plans and specifications made a part hereof by reference, and to the satisfaction and approval of the City and its engineer. PAR. 4 The Contractor agrees to perform said work and install said improvements on the terms set out in bid or proposal to the City which has been accepted by the City and which is by reference made a part of this contract. PAR. 5 The Contractor agrees to commence said work within ten (10) working days after receipt of "Notice to Proceed" and complete it on or before November 1, 2019, unless an extension of time is granted in writing by the Council of the City. PAR. 6 Should the Contractor fail to complete said improvements in strict accordance with the terms and conditions of this contract, or the plans and specifications therefor promptly by the date herein specified, the City may pay such additional sums as it may be required to pay by reason of the failure of said contractor and deduct any and all such sums from any amount then due the Contractor. PAR. 7 The Contractor agrees to comply with and obey all ordinances of the City of Waterloo, Iowa, relating to the obstruction of streets and alleys, keeping open passage ways for water, traffic, and protecting any excavations in any street or alley, and maintaining proper and sufficient barricades with lights and signals during all hours of darkness, to see that the backfilling is properly done, and agrees to keep the City whole and defend any and all suits that may be brought against the City by reason of any injuries that may be sustained by any person or property allegedly caused by the Contractor, or his agents, while work is done pursuant to this agreement. FORM OF CONTRACT AECOM 60600098 CSVI 91109AL0200 Terminal Bldg LED Lighting -Terminal Imprvmnts CONTRACT NO. 20601 C-1 OF 3 PAR. 8 PAR. 9 The Contractor agrees that in the event a law suit is brought against the City for damages allegedly sustained by reason of any act, omission or negligence of the Contractor or its agents, or on account of any injuries allegedly sustained by reason of any obstruction, hole, depression or barrier placed or dug by the defendant or its agents, in the doing of the work herein contracted for, that it will defend said suit and save the City harmless therein, and in case judgment is rendered against the City, the Contractor agrees to pay the same promptly. The Contractor agrees to carry public liability insurance in a solvent company in a sufficient amount to protect the City and those who use the streets of the City. The City shall have the right to appoint one or more construction reviewers who shall review the progress of the work in detail; also, to make any test or any material to be used in such work. No material shall be used in any work until the same has first been approved by the construction reviewer. Such construction reviewer shall have full authority to pass judgment upon all materials and upon the manner of doing the work, and their judgment on rejecting any materials, substance, or manner of work shall be final unless it is revoked or modified by the City Engineer. PAR. 10 Any material, which has been rejected by the construction reviewer, shall be at once removed from the line of work and shall not be again taken thereon or placed with the material proposed to be used without the written consent of the City Engineer. PAR. 11 The Contractor shall maintain no cause of action against the City on account of delays and prosecution of work, but if said work is delayed by the City, the Contractor shall have such extra time for completion of the job as was lost by reason of the delay caused by the City. PAR. 12 The Contractor agrees to pay punctually all just claims of labor, material, men, or subcontractors who shall perform labor or furnish materials entering into this improvement. It is agreed that the City need not pay the Contractor until all such claims are paid by the Contractor. It is agreed that the City shall not be liable for said labor, material, or men under this contract. PAR. 13 PAR. 14 PAR. 15 The Contractor agrees to furnish the City, simultaneously with this contract, a bond on a form to be provided by the City in the amount provided by law as stated in the Notice to Bidders, which shall be for the benefit of the City, and any and all persons injured by the breach of any of the terms of this contract. Said bond shall be filed with the City Clerk and shall be subject to the approval of the City Council, and is by reference made a part of this contract. The Contractor agrees that should it abandon work under this contract or cease the prosecution thereof for a period of thirty (30) consecutive days without reasonable cause, and should it fail to proceed with said work within ten (10) days after a notice to continue or carry it on has been mailed to it at the address given herein by the City, or after such notice has been served on it, then the City may proceed to complete said work, using any material, tools, or machinery found along said line of work, doing the work either by contract or as it may elect, and the Contractor and the sureties on its bond shall be liable to the City for the costs and expenses so paid out. Said costs shall be retained by the City from any compensation due, or to become due the Contractor, and may be recovered by the City in an action upon Contractor's bond. In consideration of the full compliance on the part of the Contractor with all the provisions, stipulations, and conditions hereof, or contained in the various instruments made a part of this contract by reference, and upon completion and acceptance of said work, the City agrees to pay to the Contractor, in the manner set out in the Notice to Contractors, the amount of money due the Contractor for work performed and accepted, at the unit prices set out in the Contractor's proposal, which has been accepted by the City. FORM OF CONTRACT AECOM 60600098 CSVI 91109ALO200 Terminal Bldg LED Lighting -Terminal Imprvmnts CONTRACT NO. 20601 C-2 OF 3 PAR. 16 PAR. 17 PAR. 18 PAR. 19 PAR. 20 PAR. 21 The total amount of the contract, based on the Engineer's estimates of quantities and the Contractor's unit bid prices, and for which 100% surety bond is required, is $9,230.72. After the completion of said work, the Contractor agrees to remove all debris and clean up said streets, and to save the City harmless from any damage allegedly resulting from a failure to clean up and remove the debris or put the street back in a proper condition for travel. This contract is not divisible, but in the event of a conflict between this contract and the various instruments incorporated by reference, this contract shall govern. Before the Contractor shall be entitled to receive final payment for work done under this contract, it shall execute and file a bond in the penal sum of not less than 100% of the total amount of the contract, same to be known as "Maintenance Bond," and which bond must be approved by the City Council, and which bond is in addition to the bond given by the Contractor to guarantee the completion of the work. The Contractor shall maintain all work done hereunder in good order for the period of two (2) years from and after the date it is accepted by the Council of the City of Waterloo, Iowa. Said maintenance shall be made without expense to the City or the abutting property. In the event of the failure or default of the Contractor to remedy any or all defects appearing in said work within a period of two (2) years from the date of its acceptance by said Council, and after having been given ten (10) days' notice so to do by registered letter deposited in the United States Post Office in said town, addressed to said contractor at the address herein given, then the City may proceed to remedy such defects. The costs and expenses thereof to be recovered from the Contractor and the sureties on its maintenance bond by an action brought in any court of competent jurisdiction. The Contractor shall give notice to said City by registered letter directed to the Mayor or City Clerk/Auditor thereof not more than four (4) and not less than three (3) months prior to the expiration of the term during which the Contractor is required to maintain said improvements, in good repair by the terms of its Contract. The liability of the Contractor and of the sureties on its bond for maintenance of the said improvements shall continue until three (3) months after such notice has been given to the City, and, in any event, until two (2) years after the acceptance of the work. CITY OF WATERLOO, IOWA Mayor Ity Clerk SHAW ELEC IC, I Contractor BY: Title: 411,r4 C.!t Approved b the City Council • th City of Waterloo, Iowa, this ATTEST: FORM OF CONTRACT AECOM 60600098 tC\41- day of �J City Clerk Waterloo, Iowa 2019. CSVI 91109AL0200 Terminal Bldg LED Lighting -Terminal Imprvmnts CONTRACT NO. 20601 C-3 OF 3 PERFORMANCE BOND KNOW ALL MEN BY THESE PRESENTS: BOND NO. 54227461 That we, Shaw Electric, Inc., of 905 Cedar Bend Street, Waterloo, Iowa, 50703, (the "Principal"), and United Fire & Casualty Company of 118 2nd Ave SE, Cedar Rapids, IA 52401 (the "Surety"), are held and firmly bound unto the City of Waterloo, Iowa (the "Obligee"), in the penal sum of Nine Thousand Two Hundred Thirty and 72/100 Dollars ($9,230,72), lawful money of the United States, for the payment of said sum in connection with a contract (the "Contract") dated on or about July 15, 2019 for the purpose of Terminal Building LED Lighting - Terminal Improvements, Waterloo Regional Airport - CSVI Project No. 91109A0L200, Iowa DOT Contract No. 20601. The Contract is incorporated herein by reference as though fully set forth herein. Whenever the Principal shall be and is declared by the Obligee to be in default under the Contract, with the Obligee having performed its obligations in the Contract, then the Surety, acknowledging that time is of the essence, may promptly remedy the default, or shall promptly undertake to: 1. Complete the Contract in accordance with its terms and conditions; or 2. Obtain one or more bids for completing the Contract in accordance with its terms and conditions, and upon determination by the Surety of the lowest responsible bidder, or negotiated proposal, or, if the Obligee elects, upon determination by the Obligee and the Surety jointly of the lowest responsible bidder, or negotiated proposal, arrange for a contract between such party and the Obligee. The Surety will make available as work progresses sufficient funds to pay the cost of completion less the balance of the Contract price. The cost of completion includes responsibilities of the Principal for correction of defective work and completion of the Contract, the Obligee's legal and design professional costs resulting directly from the Principal's default, and liquidated damages or actual damages if no liquidated damages are specified in the Contract. The term "balance of the Contract price" means the total amount payable by the Obligee to the Principal under the Contract and any amendments thereto, less the amount properly paid by the Obligee to the Principal; or 3. Determine the amount for which it is liable to the Obligee and pay the Obligee that amount as soon as practicable. In the event this bond is enforced, Principal and Surety agree to indemnify Obligee and hold Obligee harmless from and against any and all costs of enforcement, including but not limited to reasonable attorneys' fees and expenses. Every Surety on this bond shall be deemed and held, any contract to the contrary notwithstanding, to consent to each and all of the following matters, without notice: 1. To any extension of time to the Contract in which to perform the Contract. 2. To any change in the plans, specifications, or Contract when such change does not involve an increase of more than twenty percent (20%) of the total Contract price, and shall then be released only as to such excess increase. 3. That no provision of this bond or of any other contract shall be valid which limits to less than one (1) year from the time of the acceptance of the work the right to sue on this bond for defect in workmanship or material not discovered or known to the Obligee at the time such work was accepted. If the Principal performs the Contract, then this bond shall be null and void; otherwise it shall remain in full force and effect. In no event shall the Surety's total obligation exceed the penal amount of this bond. PERFORMANCE BOND AECOM 60600098 CSVI 91109AL0200 Terminal Bldg LED Lighting -Terminal Imprvmnts CONTRACT NO. 20601 PFB-1 of 2 Terms used herein shall include, as appropriate, the singular or plural number, or the masculine, feminine or neuter gender. IN WITNESS WHEREOF, the undersigned Principal and Surety have executed this Performance Bond as of July 15, 2019 PRINCIPAL Shaw Electric, Inc. SURETY United Fire & Casualty Company Name Na By: e By: Walters it Title: Title: Attorney -In -Fact [attach Power of Attorney] NOTE: Date of BOND must not be prior to date of Contract. If CONTRACTOR is Partnership, all partners should execute BOND. PERFORMANCE BOND AECOM 60600098 CSVI 91109AL0200 Terminal Bldg LED Lighting -Terminal Imprvmnts CONTRACT NO. 20601 PFB-2 of 2 PAYMENT BOND KNOW ALL MEN BY THESE PRESENTS: that SHAW ELECTRIC, INC. BOND NO. 54227461 (Name of Contractor) 905 CEDAR BEND STREET, WATERLOO, IOWA 50703 (Address of Contractor) a Corporation , hereinafter called Principal, (Corporation, Partnership or Individual) and, United Fire & Casualty Company (Name of Surety) 118 2nd Ave SE, Cedar Rapids, IA 52401 (Address of Surety) hereinafter called Surety, are held and firmly bound unto CITY OF WATERLOO, IOWA (Name of Owner) 715 MULBERRY STREET, WATERLOO, IOWA 50703 (Address of Owner) hereinafter called OWNER, in the penal sum of Nine Thousand Two Hundred Thirty and 72/100 Dollars ($9,230.72) in lawful money of the United States, for the payment of which sum well and truly to be made, we bind ourselves, successors, and assigns, jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION is such that whereas, the Principal entered into a certain contract with the OWNER, dated the 15th day of July , 2019, a copy of which is hereto attached and made a part hereof for the construction of: TERMINAL BUILDING LED LIGHTING - TERMINAL IMPROVEMENTS WATERLOO REGIONAL AIRPORT NOW, THEREFORE, if the Principal shall promptly make payment to all persons, firms, SUBCONTRACTORS, and corporations furnishing materials for or performing labor in the prosecution of the WORK provided for in such contract, and any authorized extension or modification thereof, including all amounts due for materials, lubricants, oil, gasoline, coal and coke, repairs on machinery, equipment and tools, consumed or used in connection with the construction of such WORK, and all insurance premiums on said WORK, and for all labor, performed in such WORK whether by SUBCONTRACTOR or otherwise, then this obligation shall be void; otherwise to remain in full force and effect. PROVIDED, FURTHER, that the said Surety for value received hereby stipulates and agrees that no change, extension of time, alteration or addition to the terms of the contract or to the WORK to be performed thereunder or the SPECIFICATIONS accompanying the same shall in any wise affect its obligation on this BOND, and it does hereby waive notice of any such change, extension of time, alteration or addition to the terms of the contract or to the WORK or to the SPECIFICATIONS. PAYMENT BOND AECOM 60600098 CSVI 91109A0L200 Terminal Bldg LED Lighting -Terminal Imprvmnts CONTRACT NO. 20601 PB -1 of 2 PROVIDED, FURTHER, that no final settlement between the OWNER and the CONTRACTOR shall abridge the right of any beneficiary hereunder, whose claim may be unsatisfied. IN WITNESS HEREOF, this instrument is executed in (4) counterparts, each one (number) of which shall be deemed an original, this the 15th day of July , 2019. ATTEST: Shaw Electric, Inc. N/A (Principal) Secretary (SEAL) By ii71///t. Witness as to Principal 3o F Q i vier (Address) c)CA-kft.A p , IA SaM3 ATTEST: Witness asety Sofia Burne to 212 Brady Street, Suite 4B, Davenport IA 52801 Principal 1 kick Sc!a�t 4 kr — CAH-ralltr q 30 E ICi vt (Address) E) Av.k pot 1 (j\ UNO3 United Fire & Casualty Company (s) By \J Surety Walter G. Z'& -In -Fact 212 Brady Street, Suite 4B (Address) Davenport, IA 52801 (Address) (Address) NOTE: Date of BOND must not be prior to date of Contract. If CONTRACTOR is Partnership, all partners should execute BOND. PAYMENT BOND AECOM 60600098 CSVI 91109A0L200 Terminal Bldg LED Lighting -Terminal Imprvmnts CONTRACT NO. 20601 PB -2 of 2 UNITED FIRE & CASUALTY COMPANY, CEDAR RAPIDS, IA UNITED FIRE & INDEMNITY COMPANY, WEBSTER, TX FINANCIAL PACIFIC INSURANCE COMPANY, ROCKLIN, CA CERTIFIED COPY OF POWER OF ATTORNEY (original on file at Home Office of Company — See Certification) KNOW ALL PERSONS BY THESE PRESENTS, That United Fire & Casualty Company, a corporation duly organized and existing under the laws of the State of Iowa; United Fire & Indemnity Company, a corporation duly organized and existing under the laws of the State of Texas; and Financial Pacific Insurance Company, a corporation duly organized and existing under the lairs of the State of California (herein collectively called the Companies), and having their corporate headquarters in Cedar Rapids, State of Iowa, does make, constitute and appoint LAURA A. FOUST, SCOTT A. SAVERAID, BRIAN C. MATLOCK..,..,.MICHAEL F. WERNSMAN, JOYCE L. BRIGGS, STACY A. BANFIELD, SETH W. DOUP, AARON E. MATLOCK, WALTER G. ZIMMERER, MEREDITH MORROW, EACH INDIVIDUALLY Inquiries: Surety Department 118 Second Ave SE' Cedar Rapids, IA 52401 theirtrue and lawful Attomey(s)-in-Fact with power and authority hereby conferred to sign, seal and execute in its behalf all lawful bonds, undertakings and other obligatory instruments of similar nature provided that no single obligation shall exceed $100, 000, 000.00 and to bind the Companies thereby as fully and to the same extent as if such instruments were signed by the duly authorized officers of the Companies and all of the acts of said Attorney, pursuant to the authority hereby given and hereby ratified and confirmed: The Authority hereby granted is continuous and shall remain in full force and effect until revoked by United Fire & Casualty Company, United Fire & Indemnity Company, and Financial Pacific Insurance Company. This Power of Attorney is made and executed pursuant to and by authority of the following bylaw duly adopted on May 15, 2013, by the Boards of Directors of United Fire & Casualty Company, United Fire & Indemnity Company, and Financial Pacific Insurance Company. "Article VI — Surety Bonds and Undertakings" Section 2, Appointment of Attorney -in -Fact. The President or any Vice President, or any other officer of the Companies may, from time to time, appoint by written certificates attorneys -in -fact to act m behalf of the Companies in the execution of policies of insurance, bonds, undertakings and other obligatory instruments of like nature. The signature of any officer authorized hereby, and the Corporate seal, may be affixed by facsimile to any power of attorney or special power of attorney or certification of either authorized hereby; such signature and seal, when so used, being adopted by the Companies as the original signature of such officer and the original seal of the Companies, to be valid and binding upon the Companies with the same force and effect as though manually affixed. Such attorneys -in -fact, subject to the limitations'. set of forth in their respective certificates of authority shall have full power to bind the Companies by their signature and execution of any such instruments and to attach the seal the Companies thereto. The President or any Vice President, the Board of Directors or any other officer of the Companies may at any time revoke all power and authority previously given to any attomey-in-fact. "`SCA 09 70., nn State of Iowa, County'of Linn, ss: IN WITNESS WHEREOF, the COMPANIES have each caused these presents to be signed by its vice president and its corporate seal to be hereto affixed this 11t h day of Sept ember , 2013 UNITED FIRE & CASUALTY COMPANY UNITED FIRE & INDEMNITY COMPANY FINANCIAL PACIFIC INSURANCE COMPANY By: Vice President On 11'th daV of September, 2013. before me personally came. Dennis J. Riclnmann to me known, who being by me duly sworn, did depose and say; that he. resides in Cedar Rapids, State of Iowa; that he is a Vice President of United Fire & Casualty Company, a Vice President of United Fire & Indemnity Company, and a Vice President of Financial Pacific Insurance Company the corporations described in and which executed the above instrument that he knows the seal of said corporations; that the seal affixed to the said instrument is such corporate seal; that it was so affixed pursuant to authority given by the Board of Directors of said corporations and that he signed his name thereto pursuant to like authority, and acknowledges sante to be the' act and deed of said corporations. Patti Waddell lowa Notarial Seal Commission number 713274 My Commission Expires 10/26/2019 ea I X.2.I�i�a�i�{�✓ 1�✓�' VV`t Notary Public My commission expires: 10/26/2019 I, Mary A. Bertsch, Assistant Secretary of United Fire & Casualty Company. and Assistant Secretary of United Fire &.Indemnity Company, and Assistant Secretary of Financial Pacific Insurance Company, do hereby certify that I have compared the foregoing copy of the Power of Attorney and affidavit, and the copy of the Section of the bylaws and resolutions of said Corporations as set forth in said Power of Attorney, with the ORIGINALS ON FILE IN THE HOME OFFICE OF SAID CORPORATIONS, and that the same are correct transcripts thereof, and of the whole of the said originals, and that the said Power of Attorney has not been revoked and is now itt full force and effect. in testimony whereof I hay eun o subscribed my name and affixed rporate seal of the said Corporations,. this ;„ day of , 20. BPOA00491217 Assistant Secretary OF&C<& OF&I & FPIC This paper has a colored background and void pantograph. Ami D® CERTIFICATE OF LIABILITY INSURANCE DATE(MM/D1/9YYY) THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER Hub International Iowa dba Ruhl & Ruhl Insurance 212 Brady Street; Suite 4B Davenport IA 52801 CONTACT NAME: Laura A. Foust, CPCU, AAI, CISR, CRIS PHONE FAX (A/C. No Ext): 563 823 6734 (A/c, No): 866-873-6117 ADDRESS:Iaura.foust@hubinternational.com LIMITS INSURER(S) AFFORDING COVERAGE NAIC # INSURER A: United Fire & Casualty 13021 INSURED SHAWELE-03 Shaw Electric, Inc.; Industrial Automated Systems 930 E. River Drive Davenport IA 52803 INSURER B : Lafayette Insurance Company 18295 INSURER C : Columbia Casualty Company 31127 INSURER D : INSURER E : CLAIMS -MADE INSURER F : OCCUR COVERAGES CERTIFICATE NUMBER: 1157847838 REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR LTR TYPE OF INSURANCE ADDL INSD SUBR WVD POLICY NUMBER POLICY EFF (MM/DD/YYYY) POLICY EXP (MM/DD/YYYY) LIMITS A X COMMERCIAL GENERAL LIABILITY 60071302 9/30/2018 9/30/2019 EACH OCCURRENCE $ 1,000,000 CLAIMS -MADE X OCCUR DAMAGE T• RENTED PREMISES (Ea occurrence) $ 100,000 MED EXP (Any one person) $ 5,000 PERSONAL & ADV INJURY $ 1,000,000 GEN'L AGGREGATE POLICY OTHER: X LIMIT APPLIES jE X PER: LOC GENERAL AGGREGATE $ 2,000,000 PRODUCTS - COMP/OP AGG $ 2,000,000 $ A AUTOMOBILE X LIABILITY ANY AUTO OWNED AUTOS ONLY HIRED AUTOS ONLY X y SCHEDULED AUTOS NON -OWNED AUTOS ONLY 60071302 9/30/2018 9/30/2019 COMBI EDtSINGLELIMIT (Ea aX $ 1,000,000 BODILY INJURY (Per person) $ BODILY INJURY (Per accident ) $ PROPERTY DAMAGE (Per accident) $ $ A X UMBRELLALIAB EXCESSLIAB X OCCUR CLAIMS -MADE 60071302 9/30/2018 9/30/2019 EACH OCCURRENCE $7,000,000 AGGREGATE $7,000,000 DED RETENTION $ $ A B WORKERS COMPENSATION AND EMPLOYERS' LIABILITY ANYPROPRIETOR/PARTNER/EXECUTIVE OFFICER/MEMBEREXCLUDED? (Mandatory in NH) If yes, describe under DESCRIPTION OF OPERATIONS below Y / N N NIA 60071302 30302912 9/30/2018 9/30/2018 9/30/2019 9/30/2019 X STATUTE OTH- ER E.L. EACH ACCIDENT $ 500,000 E.L. DISEASE - EA EMPLOYEE $ 500,000 E.L. DISEASE - POLICY LIMIT $ 500,000 A C Leased/Rented Equipment Professional Liiability 60071302 CEO 6017219322 9/30/2018 9/30/2018 9/30/2019 9/30/2019 Limit: Per Claim/Aggregate Deductible: $100,000 $2,000,000 $20,000 DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached if more space is required) Terminal Building LED Lighting - Terminal Improvements, Waterloo Regional Airport - CSVI Project No. 91109A0L200, Iowa DOT Contract No. 20601 City of Waterloo, Iowa, and the Engineer, AECOM additional insureds as respects the above captioned general liability policy when agreed in a written contract, subject to policy terms, conditions and exclusions. CERTIFICATE HOLDER CANCELLATION City of Waterloo, Iowa;Attn John P Kehoe 715 Mulberry Street Waterloo IA 50703-0000 SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. AUTHORIZED REPRESENTATIVE ACORD 25 (2016/03) © 1988-2015 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD