Loading...
HomeMy WebLinkAboutCedar Valley Corp., LLC-3/14/2016FORM OF CONTRACT CONTRACT FOR THE CONSTRUCTION OF F.Y. 2016 MIDPORT BOULEVARD EXTENSION PHASE III CITY OF WATERLOO, IOWA CONTRACT NO. 894 This contract made and entered into this �-rday of 20kk,-, by and between the City of Waterloo, Iowa, a Municipal Corporation, (hereinafter referred to as City), and CEDAR VALLEY CORP.. LLC of Waterloo, Iowa, (hereinafter referred to as Contractor), WITNESSETH: PAR.1 Contractor agrees to build and construct the F.Y. 2016 MIDPORT BOULEVARD EXTENSION PHASE III, Contract No. 894 and furnish all necessary tools, equipment, materials, and labor necessary to do all the work called for in the plans and specifications in a workmanshiplike manner and for the prices set forth in Contractor's proposal, which was accepted by the City, and which is understood and agreed to be a part of this contract. PAR. 2 It is understood and agreed that the resolution adopted by the City Council ordering the construction of the improvement, the Notice to Contractors as published, the Instruction to Bidders, the Form of Proposal, the Construction and Maintenance Bonds, the Council Proceedings relating to this matter, and the Plans and Specifications shall all be considered as forming a part of the contract the same as though they were each set out in said contract. PAR.3 The Contractor agrees to furnish at its own cost and expense, all necessary materials and labor for said work and to construct said improvements in a thorough, substantial, and workmanlike manner, and in strict accordance with the requirements of this contract, and of the plans and specifications made a part hereof by reference, and to the satisfaction and approval of the City and its engineer. FORM OF CONTRACT PAGE 1 OF 5 PAGES PAR. 4 PAR. 5 PAR. 6 PAR. 7 PAR. 8 PAR. 9 The Contractor agrees to perform said work and instalt said improvements on the terms set out in bid or proposal to the City which has been accepted by the City and which is by reference made a part of this contract. The Contractor agrees to commence said work within ten (10) working days after receipt of "Notice to Proceed" and comptete it on or before Auqust 1.2016 unless an extension oftime is granted in writing bythe Council ofthe City. Should the Contractor fail to complete said improvements in strict accordance with the terms and conditions of this contract, or the plans and specifications therefor promptty by the date herein specified, the City may pay such additional sums as it may be required to pay by reason of the failure of said contractor and deduct any and alt such sums from any amount then due the Contractor. The Contractor agrees to compty with and obey all ordinances of the City of Waterloo, Iowa, relating to the obstruction of streets and alleys, keeping open passage ways for water, traffic, and protecting any excavations in any street or alley, and maintaining proper and sufficient barricades with tights and signals during alt hours of darkness, to see that the backfilling is properly done, and agrees to keep the City whole and defend any and all suits that may be brought against the City by reason of any injuries that may be sustained by any person or property altegedly caused by the Contractor, or his agents, while work is done pursuant to this agreement. The Contractor agrees that in the event a law suit is brought against the City for damages allegedly sustained by reason of any act, omission or negligence of the Contractor or its agents, or on account of any injuries allegedly sustained by reason of any obstruction, hole, depression or barrier placed or dug by the defendant or its agents, in the doing of the work herein contracted for, that it will defend said suit and save the City harmless therein, and in case judgment is rendered against the City, the Contractor agrees to pay the same promptly. The Contractor agrees to carry public liability insurance in a solvent company in a sufficient amount to protect the City and those who use the streets of the City. The City shall have the right to appoint one or more construction reviewers who shall review the progress of the work in detail; also, to make any test or any material to be used in such work. No material shall be used in any work untit the same has first been approved by the construction reviewer. Such construction reviewer shall have full authority to pass judgment upon alt materiats and upon the manner of doing the work, and their judgment on rejecting any materials, substance, or manner of work shall be final unless it is revoked or modified by the City Engineer. FORM OF CONTRACT PAGE 2 OF 5 PAGES PAR. 10 PAR. 11 PAR. 12 PAR. 13 PAR. 14 PAR. 15 Any material, which has been rejected by the construction reviewer, shall be at once removed from the line of work and shall not be again taken thereon or placed with the material proposed to be used without the written consent of the City Engineer. The Contractor shall maintain no cause of action against the City on account of delays and prosecution of work, but if said work is detayed by the City, the Contractor shall have such extra time for completion of the job as was Iost by reason of the delay caused by the City. The Contractor agrees to pay punctuaHy all just claims of labor, material, men, or subcontractors who shall perform labor or furnish materials entering into this improvement. It is agreed that the City need not pay the Contractor until aU such claims are paid by the Contractor. It is agreed that the City shall not be Iiable for said labor, material, or men under this contract. The Contractor agrees to furnish the City, simultaneously with this contract, a bond on a form to be provided by the City in the amount provided by Iaw as stated in the Notice to Bidders, which shall be for the benefit of the City, and any and all persons injured by the breach of any of the terms of this contract. Said bond shall be filed with the City Clerk and shall be subject to the approval of the City Council, and is by reference made a part of this contract. The Contractor agrees that should it abandon work under this contract or cease the prosecution thereof for a period of thirty (30) consecutive days without reasonable cause, and should it fail to proceed with said work within ten (10) days after a notice to continue or carry it on has been mailed to it at the address given herein by the City, or after such notice has been served on it, then the City may proceed to complete said work, using any material, tools, or machinery found along said line of work, doing the work either by contract or as it may elect, and the Contractor and the sureties on its bond shall be Iiable to the City for the costs and expenses so paid out. Said costs shall be retained by the City from any compensation due, or to become due the Contractor, and may be recovered by the City in an action upon Contractor's bond. In consideration of the full compliance on the part of the Contractor with ati the provisions, stipulations, and conditions hereof, or contained in the various instruments made a part of this contract by reference, and upon completion and acceptance of said work, the City agrees to pay to the Contractor, in the manner set out in the Notice to Contractors, the amount of money due the Contractor for work performed and accepted, at the unit FORM OF CONTRACT PAGE 3 OF 5 PAGES PAR. 16 PAR. 17 PAR. 18 PAR. 19 PAR. 20 PAR. 21 prices set out in the Contractor's proposal, which has been accepted by the City. The tota! amount of the contract, based on the Engineer's estimates of quantities and the Contractor's unit bid prices, and for which 100% surety bond is required is $559975.14. After the completion of said work, the Contractor agrees to remove all debris and clean up said streets, and to save the City harmless from any damage allegedly resulting from a failure to clean up and remove the debris or put the street back in a proper condition for travel. This contract is not divisible, but in the event of a conflict between this contract and the various instruments incorporated by reference, this contract shati govern. Before the Contractor shall be entitled to receive final payment for work done under this contract, it shall execute and file a bond in the penal sum of not Iess than 100% of the total amount of the contract, same to be known as "Maintenance Bond," and which bond must be approved by the City Council, and which bond is in addition to the bond given by the Contractor to guarantee the completion of the work. The Contractor shall maintain all work done hereunder in good order for the period of two (2) years from and after the date it is accepted by the Council of the City of Waterloo, Iowa. Said maintenance shall be made without expense to the City or the abutting property. In the event of the failure or defauft of the Contractor to remedy any or all defects appearing in said work within a period of two (2) years from the date of its acceptance by said Council, and after having been given ten (10) days notice so to do by registered letter deposited in the United States Post Office in said town, addressed to said contractor at the address herein given, then the City may proceed to remedy such defects. The costs and expenses thereof to be recovered from the Contractor and the sureties on its maintenance bond by an action brought in any court of competent jurisdiction. The Contractor shali give notice to said City by registered Ietter directed to the Mayor or City ClerklAuditor thereof not more than four (4) and not Iess than three (3) months prior to the expiration of the term during which the Contractor is required to maintain said improvements, in good repair by the terms of its Contract. The Iiability of the Contractor and of the sureties on its bond for maintenance of the said improvements shaH continue until three (3) months after such notice has been given to the City, and, in any event, until two (2) years after the acceptance of the work. FORM OF CONTRACT PAGE 4 OF 5 PAGES CITY OF WATERLOO, IOWA Mayor City Clerk Cedar Vc.II{y Cop L. L Contractor BY: Title: Ser. Approved by the City Council of the City of Waterloo, Iowa, this day of 1 nw c.h , 20 �V. ATTEST: �°L Q IM_—f2_._C�( �� �Q 2a City Clerk Waterloo, Iowa FORM OF CONTRACT PAGE 5 OF 5 PAGES Bond No.: 190033523 PERFORMANCE BOND KNOW ALL MEN BY THESE PRESENTS: That we, Cedar Valley Corp., LLC of Waterloo, IA (the "Principal"), and Liberty Mutual Insurance Company of Boston, MA (the "Surety"), are held and firmly bound unto the City of Waterloo, Iowa (the "Obligee"), in the penal sum of Five Hundred Fifty Nine Thousand Nine Hundred Seventy Five and 14/100 Dollars ($559,975.14), lawful money of the United States, for the payment of said sum in connection with a contract (the "Contract") dated on or about 1 -k& -oh �A. u i u for the purpose of F.Y. 2016 Midport Boulevard Extension Phase III, Waterloo, Iowa; Contract No.: 894. The Contract is incorporated herein by reference as though fully set forth herein. Whenever the Principal shall be and is declared by the Obligee to be in default under the Contract, with the Obligee having performed its obligations in the Contract, then the Surety, acknowledging that time is of the essence, may promptly remedy the default, or shall promptly undertake to: 1. Complete the Contract in accordance with its terms and conditions; or 2. Obtain one or more bids for completing the Contract in accordance with its terms and conditions, and upon determination by the Surety of the lowest responsible bidder, or negotiated proposal, or, if the Obligee elects, upon determination by the Obligee and the Surety jointly of the lowest responsible bidder, or negotiated proposal, arrange for a contract between such parry and the Obligee. The Surety will make available as work progresses sufficient funds to pay the cost of completion less the balance of the Contract price. The cost of completion includes responsibilities of the Principal for correction of defective work and completion of the Contract, the Obligee's legal and design professional costs resulting directly from the Principal's default, and liquidated damages or actual damages if no liquidated damages are specified in the Contract. The term "balance of the Contract price" means the total amount payable by the Obligee to the Principal under the Contract and any amendments thereto, less the amount properly paid by the Obligee to the Principal; or 3. Determine the amount for which it is liable to the Obligee and pay the Obligee that amount as soon as practicable. In the event this bond is enforced, Principal and Surety agree to indemnify Obligee and hold Obligee harmless from and against any and all costs of enforcement, including but not limited to reasonable attorneys' fees and expenses. Every Surety on this bond shall be deemed and held, any contract to the contrary notwithstanding, to consent to each and all of the following matters, without notice: 1. To any extension of time to the Contract in which to perform the Contract. Performance Bond Page 1 of 2 2. To any change in the plans, specifications, or Contract when such change does not involve an increase of more than twenty percent (20%) of the total Contract price, and shall then be released only as to such excess increase. 3. That no provision of this bond or of any other contract shall be valid which limits to less than one (1) year from the time of the acceptance of the work the right to sue on this bond for defect in workmanship or material not discovered or known to the Obligee at the time such work was accepted. If the Principal performs the Contract, then this bond shall be null and void; otherwise it shall remain in full force and effect. In no event shall the Surety's total obligation exceed the penal amount of this bond. Terms used herein shall include, as appropriate, the singular or plural number, or the masculine, feminine or neuter gender. IN WITNESS WHEREOF, the undersigned Principal and Surety have executed this Performance Bond as of ILA, as 11'. PRINCIPAL Title: Seh: or V' c e eLr-$, d eJ SURETY Title: Anne Crowner, Attornev-in-Fact [attach Power of Attorney] NOTE: Date of BOND must not be prior to date of Contract. If CONTRACTOR is Partnership, all partners should execute BOND. If this project includes Federal Funds, the following applies to the payment bond: IMPORTANT: Surety companies executing bonds must appear on the Treasury Department's most current list (Circular 570 as amended) and be authorized to transact business in the State where the project is located. Performance Bond Page 2 of 2 Bond No.: 190033523 PAYMENT BOND KNOW ALL MEN BY THESE PRESENTS: that Cedar Valley Corp., LLC (Name of Contractor) P.O. Box 1740, Waterloo IA 50704 (Address of Contractor) a Corporation hereinafter called Principal, (Corporation, Partnership or Individual) and, Liberty Mutual Insurance Company (Name of Surety) 175 Berkeley Street, Boston, MA 02116 (Address of Surety) hereinafter called Surety, are held and firmly bound unto City of Waterloo (Name of Owner) 715 Mulberry Street Waterloo, IA 50703 (Address of Owner) hereinafter called OWNER, in the penal sum of Five Hundred Fifty Nine Thousand Nine Hundred Seventy Five and 14/100 Dollars, ($559,975.14 ) in lawful money of the United States, for the payment of which sum well and truly to be made, we bind ourselves, successors, and assigns, jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION is such that whereas, the Principal entered into a certain contract with the OWNER, dated the J`t*�-\ day of 1aw.r 20 t 4 , a copy of which is hereto attached and made a part hereof for the construction of: F.Y. 2016 Midport Boulevard Extension Phase III, Waterloo, Iowa; Contract No.: 894 NOW, THEREFORE, if the Principal shall promptly make payment to all persons, firms, SUBCONTRACTORS, and corporations furnishing materials for or performing labor in the prosecution of the WORK provided for in such contract, and any authorized extension or modification thereof, including all amounts due for materials, lubricants, oil, gasoline, coal and coke, repairs on machinery, equipment and tools, consumed or used in connection with the construction of such WORK, and all insurance premiums on said WORK, and for all labor, performed in such WORK whether by SUBCONTRACTOR or otherwise, then this obligation shall be void; otherwise to remain in full force and effect. PROVIDED, FURTHER, that the said Surety for value received hereby stipulates and agrees that no change, extension of time, alteration or addition to the terms of the contract or to the WORK to be performed thereunder or the SPECIFICATIONS accompanying the same shall in any wise affect its obligation on this BOND, and it does hereby waive notice of any such change, extension of time, alteration or addition to the terms of the contract or to the WORK or to the SPECIFICATIONS. PROVIDED, FURTHER, that no final settlement between the OWNER and the CONTRACTOR shall abridge the right of any beneficiary hereunder, whose claim may be unsatisfied. IN WITNESS HEREOF, this instrument is executed in Three ( 3 ) counterparts, each one of (number) which shall be deemed an original, this the 20 Nb ATTEST: P ' cipal) Secretary (SEAL) Z 941 62-r` L) Witness as to Principal P.O. Box 1740 (Address) 1 q,kl\ day of M arc h P.O. Box 1740 (Address) Waterloo, IA 50704 Waterloo, IA 50704 LiberbrMutual Indirance Company Surety ATTEST: Attorney -in -Fact Anne Crowner 175 Berkley Street Witness as to Su ty Stacy Venn (Address) 175 Berkley Street Boston, MA 02116 (Address) Boston, MA 02116 NOTE: Date of BOND must not be prior to date of Contract. If CONTRACTOR is Partnership, all partners should execute BOND. If this project includes Federal Funds, the following applies to the payment bond: IMPORTANT: Surety companies executing bonds must appear on the Treasury Department's most current list (Circular 570 as amended) and be authorized to transact business in the State where the project is located. This Power of .Atlorney linlis Ohe acls of Ohose named herein, and thoy have 110 authority to bind the Company excepl in the manner and to the extenl lierein s(ated. Not valid for niortgage, note, loan, Ietter of credit, bank deposit, curroncy rate, interest rate or residual value guarantees. To conlirm the validity oF this Power of Attorney calI 610-832- 8240 between 9:00 am and 4:30 pm EST 011 any business day. American Fire and Casualty Company Liberty Mutual Insuronco Company Tho Ohio Casuafty Insurance Cornpany West American Insuranco Company POWER OF ATTORNEY KNOWN ALL PERSONS BY THESE PRESENTS: That Ame,ican Fire & Casually Company and The Ohio Casually Insurance Company are corporatons duly organized under the laws of Ihe SlaIe of New Hampshire, lhat Ubedy Mutual lnsurance Company is a corporalion duly organized under the laws of Rio Slale of Massachusetls, and Wesi American lnsurance Company is 2 corporalion duly organized under Rio la of Rio Slate oI lndiana (herein collectivety calfed lhe 'Companies'), pursuanl to and by aulhority horein set foilh, doos hereby name, consftule and appoint, Shlrlov S. Bar(enhaqen, Cindy Bennett, Lacey Cramblit Anne Crowner Brlan M. Oelmerlv Jay 0. Freiermuth Craiq E. Hanson, Tini McCulIoh Slacv Venn Dione R. Younq of the city of West Des Moines alale of lowe ils true and lawful allorney-in-fact, wilh full power and authodty hereby conferred lo sign, execute and acknowledge the foliowing surely bond: Prinolpal Narue: Cedar VaIIey Corp., LLC Obligee Name: City of Waterloo Surety Bond Number: 190033523 Bond Aniount: $559,975.14 IN WITNESS WHEREOF, this Power of Altorney has been subscribed by an aulhorized officer or official o[ the Cornpanies and Ihe corporate seals of the Companies havo beon alfixed therelo this Jot day of January 2016. STATE OF PENNSYLVANIA 55 COUNTY OF M0NTGOMERY By: American Fire and Casualty Company The Ohio Casualty Insurance Company LTherty Mutual nsurance Company Wepfnorican Insurance Company David M Carey, Assistanl Secretary On Ihis lhis 22'' day af Januarv 2016 before me personaily appeared David M. Carey, who acknowledged himself to be the Assislant Secretary of Anierican Fire and Casualty Company, Uberty Mulual lnsurance Company, The Ohio Casually Company, and WesI American lnsurance Company. and lhat he, as such, being aulhorized so to do, execule lho foregoing inslwrnent lor the purposes therein conlained by signing on behalf of (he corporalions by himself 85 8 duty aulhorized officer. IN WITNESS WREREOF, have hereunto subscribed my name and alflxed my notanial seal al Plymoulh Meeting, Pennsylvania, on (he day and year lirsl above wrilten. COMMONWEALTH OF PENNSYLVANIA Norarial Seat Teresa PasIelia, Notary Pubtc Ptyrrtoutlr Twp., Morrtgomery County My Co,,it,,tsaton Eaptres Ma,ch 28.2017 Member Penesyteanin 8sauctatton ot Notartea This Power of Atlorney is made and executed pursuant to and by authorily of the foliowing By-laws and Aulhorizalions of Amedcan Fire and Casuatty Cesipany, The Ohio Casually lnsuranoe Company, Liberly Mutual Insuranco Company, and West American lnsurance Company wtiich resolulions are now in hill force and effecl reading as foltows: ARTICLE IV - OFFICERS - Section 12. Power of Altorney. Any ollioer ar other offrcial of Ihe Corporation authorized for Ihat purpose in wdling by Ihe Chairman or Ihe President, and subject to such limilalion as the Chairnian or he President may prescribe, shall appoint suoh allorneys-in-fact, 25 may be necessary to act in behalf of the Corporalion 10 make, execule, seal, acknowledge and deliver as surety any and all undetlakings, honda, recognizances and olher surety obligalions. Sucli allorneys-in-faol, subject to tbe Iimilalions sel forlh in lheir respeclive powers of allorney, shall have full power lo bind the Corporalion by their signalure and execution of any such instrumenls and lo atlach Ihereto lhe seal of lhe Corporalion. Wlien so executed, such instruments shall be 29 binding as if signed by Ihe President and al(ested lo by lhe Secretary. Any power or aulhorily granled (0 any representalive or atlorney- in-facI undor Rio provisions of IhJs arliclo may bo revoked at any time by the Board, the Chairman, the President or by Ihe olf icer or otflcers granling such power or aulhodty. ARTICLE XIll - Exoculion of Conlracls - SECTION 5. Surely Bonds and linderlakings. Any oflicer of the Company aulhorized for lhat purpose in writing by Iho chairrnan or llie presidenl, and subjecl to such limitations as Ihe chairman or lhe presidenl rnay prescribe, shall appoinl such atlornoys-in-fact, 85 may be necessary to aol in behalf of Iho Company lo niake, execulo, seal, acknowledge and deliver as surety any and all underlakings, honda, r000gnizances and other suroly obligalions. Such allornoys-in-lact subject lo lho limilalions set forth in lheir respective powers of atlomey, shall have full power lo bind lhe Company by lheir signaturo and oxeculion of any such inslwmenls and 10 atlach lhoreto tho soal of the Cornpany. When so executed such inslrumenls shall be as binding 29 if signed by lhe prosidenl and atosled by lhe secrelary. Certlflcate of Deslgnatlon - The Presidenl of tho Company, acling pursuanl 10 lhe Dylaws of (he Company, aulhorizes David M. Caroy, Assistanl Secrolary to appotnl such allorneys-in- facl as may be necessary 10 aol on bohalf of lho Company 10 make, oxecule, seal, acknowledge and doliver as surety any and alt underlakings, honda, rocogntzances and olher suroty obligalions. Authoriration - By unanimous consenl of the Company's Doard of Direclors, lhe Company consents lhat facsimile or ntechanically roproduced signalure of any assislant secrolary of lhe Company, wharever appearing upon a oerlifiod copy of any power ol allorney issued by lhe Cornpany in connedion wilh surely honda, shall be valid and binding upon lho Company wilh lho same forco and effoct 89 though manually alixod. 1, Grugory W. Davunporl, lhe undersigned, Assislanl Secrelary, of American Fire and Casually Company, The Ohio Casually lnsurance Company, Liberty Mulual lnsurance Company, and WesI Anierican lnsurance Company do hereby cerlify lhal Rio original power of allorney of which lhe foregoirg isa hill, lrue and correcl copy of lhe Power of Allorney execuled by said Companies, is in full force and effect and has nol been revokod. IN TESTIMONY WFIEREOE, l have herounlo aol my hand and aflixed lho soals of said Companies lhis By: Teresa Pastelia, otary Publio day of By: Gregory W. Davonport, Assistanl Secrelery ACORLF CERTIFICATE OF LIABILITY INSURANCE 3/9/2016 THIS CERT(FICATE IS ISS(JED AS A MATTER OF INFORMATION ONLY AND CONFERS P10 RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIEICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE GOVERAGE AFFORDED BY TKE POLIGIES BELOW. THIS CERTIFICATE OF INSURANGE DOES NOT CONST!TUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, .AND THE CERTIFICATE HOLDER. IMPORTANT: lf the certificate haider is an ADDITIONAL INSURED, the policy(ies) must bo endorsod. If SUBROGATION IS WAIVED, subject to the terms and conditions of the poticy, certain policies may require an endorsement. A statement on this certificate doos not confer rights to the certificate holder in Iieu of such endorsement(s). PRODUCER Arthur J. Gauagher Risk Management Services, Inc. 4200 Corporate Drive Ste 160 West Des Moines IA 50266 CONTACT Elisabeth Jackson PHONE nn FAX wr.no FxF)' Q'.'QVL INC No): - - , iiit ellsabethjackson@ajg.com INSURER(S) AFFORDING COVERAGE NAIC # INSURERA:CiflCiflflati Insurance Company 10677 INSURED Jackson Enterprises Corp.; Cedar VaIIey Corp., LLC Cedar VaIIey Corp. 2637 Wagner Road Waterloo IA 50703 INSURER B: CPP0894610 INSURER c: 12/1/2016 INSURER D. DAMA0ET0RENTED PREMISES (Ea oCCUrronce) . 5500,000 INSURER E:_ NSURER F: 2122580991 REVISION NUMBER: THIS 5 'ID CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW 1-IAVE BEEN I$SUED TO THE INSURED NAMED ABOVE FOR THE POLICV PERIOD INOICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSLJED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POUCIES OESCRIBED HEREIN 15 SUBJECT TO ALL THE TERMS, EXCLUSION$ AND CONDITIONS OF SUCF-I POLICIES. LIMITS SI-IOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR LTR TYPE OF INSURANCE ADOL INSD SUBR WVD POLICY NUMBER POLICY EFF (MM!DDTYYYY) POLIGY EXP (MM/OD[YYYY) LIMITS A X COMMERCIALGENERALLIABILITY ¥ CPP0894610 12/1/2015 12/1/2016 EACHOCCURRENCE 51,000000 DAMA0ET0RENTED PREMISES (Ea oCCUrronce) . 5500,000 CLAIMS -MADE X OCCUR MED EXP (Anyone person) $lO,00. PERSONAL & AUV INJURY si 000,000 GENERAL AGGREGATE 52,000,000 50ft excl delete _&. X xcu Included CENL AGOREGATE POLICY OTHER: LIMIT APPLIES PER: X LOC PRODUCTS COMP(OPAGG 52,000,000 Emp Ben 1000000 A AUTOMOSILELIABILITY X X ANY AUTO HIRED AUTOS —i SCIIEDULED NON -OWNED CPP0694610 12/1/2015 12/1/2016 5i,000,000 BODILY INJURY (Per person) $ SODILY INJURY (Per accident) PROPERTYDAMAGE - $ - - - A X 0MBRELLALIAB EXCESS LIAB X OCCUR CLAIMS -MADE CPP0894610 12/1/2015 12/1/2016 EACHOCCURRENCE s2,000,000 AGGREGATE 2,000,000 $ DED RETENTION$ A WORKER$COMPENSATION ANDEMPLOYERS'LIABILITY ANY PROPRIETOR'PARTNEIVEXECUTIVE OFFICERIMEMBEREXCLUDED? (Mandatory In NN) 11 yes, describe under DESCRIPTION OF OPERATIONS below Y/N N NIA WC1918723 12/1/2015 12/1/2016 X PER STATUTE OTH- ER E.L. EACH ACCIDENT 5500,000 ._ ....................................................... E.L. DISEASE - EA EMPLOYEE s500,000 E,L. DISEASE - POUCY LIMIT . 5500,000 DESCRIPTION OF OPERATIONS 1 L0CATIONS / VEHICLES (ACORD 101, Addltlonal Remarks Schedule, may be attached IF mo 0 SBC0 is roqui eri) The City of Waterloo 15 additional insUred on the General LiabiIity (GA2330207) with regards to F.Y. 2016 Midport Boolevard Extension Phase 111, Contract No. 894. CERTIFICATE HOLDER CANCELLATION City of Waterloo 715 Mu!berry St. Waterloo IA 50703 USA SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEPORE THE EXPIRATION DATE THEREOF, NOTIGE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. AUTHORIZED REPRESENTATIVE AGORD 25(2014/01) © 1988-2014 ACORD CORPORATION. Alt rights reserved. The ACORD name and logo a e registered marks oIACORD