Loading...
HomeMy WebLinkAboutMidwest Concrete - ALO Water Main Improvements, Phase I, Cont No. 1033 - 9.21.2020 FORM OF CONTRACT CONTRACT FOR THE CONSTRUCTION OF WATERLOO REGIONAL AIRPORT WATER MAIN IMPROVEMENTS — PHASE I CITY OF WATERLOO, IOWA CONTRACT NO. 1033 This contract made and entered into this 21 day of September , 2020, by and between the City of Waterloo, Iowa, a Municipal Corporation, (hereinafter referred to as City), and MIDWEST CONCRETE, INC. , of PEOSTA, IOWA (hereinafter referred to as Contractor), WITNESSETH: PAR. 1 Contractor agrees to build and construct the WATERLOO REGIONAL AIRPORT WATER MAIN IMPROVEMENTS — PHASE I, Contract No. 1033 , and furnish all necessary tools, equipment, materials, and labor necessary to do all the work called for in the plans and specifications in a workmanshiplike manner and for the prices set forth in Contractor's proposal, which was accepted by the City, and which is understood and agreed to be a part of this contract. PAR. 2 It is understood and agreed that the resolution adopted by the City Council ordering the construction of the improvement, the Notice to Contractors as published, the Instruction to Bidders, the Form of Proposal, the Construction and Maintenance Bonds, the Council Proceedings relating to this matter, and the Plans and Specifications shall all be considered as forming a part of the contract the same as though they were each set out in said contract. PAR. 3 The Contractor agrees to furnish at its own cost and expense, all necessary materials and labor for said work and to construct said improvements in a thorough, substantial, and workmanlike manner, and in strict accordance with the requirements of this contract, and of the plans and specifications made a part hereof by reference, and to the satisfaction and approval of the City and its engineer. PAR. 4 The Contractor agrees to perform said work and install said improvements on the terms set out in bid or proposal to the City which has been accepted by the City and which is by reference made a part of this contract. FORM OF CONTRACT PAGE 1 OF 5 PAGES PAR. 5 The Contractor agrees to commence said work within ten (10)working days after receipt of"Notice to Proceed" and complete it on or before December 18, 2020, unless an extension of time is granted in writing by the Council of the City. PAR. 6 Should the Contractor fail to complete said improvements in strict accordance with the terms and conditions of this contract, or the plans and specifications therefor promptly by the date herein specified, the City may pay such additional sums as it may be required to pay by reason of the failure of said contractor and deduct any and all such sums from any amount then due the Contractor. PAR. 7 The Contractor agrees to comply with and obey all ordinances of the City of Waterloo, Iowa, relating to the obstruction of streets and alleys, keeping open passage ways for water, traffic, and protecting any excavations in any street or alley, and maintaining proper and sufficient barricades with lights and signals during all hours of darkness, to see that the backfilling is properly done, and agrees to keep the City whole and defend any and all suits that may be brought against the City by reason of any injuries that may be sustained by any person or property allegedly caused by the Contractor, or his agents, while work is done pursuant to this agreement. PAR. 8 The Contractor agrees that in the event a law suit is brought against the City for damages allegedly sustained by reason of any act, omission or negligence of the Contractor or its agents, or on account of any injuries allegedly sustained by reason of any obstruction, hole, depression or barrier placed or dug by the defendant or its agents, in the doing of the work herein contracted for,that it will defend said suit and save the City harmless therein, and in case judgment is rendered against the City, the Contractor agrees to pay the same promptly. The Contractor agrees to carry public liability insurance in a solvent company in a sufficient amount to protect the City and those who use the streets of the City. PAR. 9 The City shall have the right to appoint one or more construction reviewers who shall review the progress of the work in detail; also, to make any test or any material to be used in such work. No material shall be used in any work until the same has first been approved by the construction reviewer. Such construction reviewer shall have full authority to pass judgment upon all materials and upon the manner of doing the work, and their judgment on rejecting any materials, substance, or manner of work shall be final unless it is revoked or modified by the City Engineer. FORM OF CONTRACT PAGE 2 OF 5 PAGES PAR. 10 Any material, which has been rejected by the construction reviewer, shall be at once removed from the line of work and shall not be again taken thereon or placed with the material proposed to be used without the written consent of the City Engineer. PAR. 11 The Contractor shall maintain no cause of action against the City on account of delays and prosecution of work, but if said work is delayed by the City, the Contractor shall have such extra time for completion of the job as was lost by reason of the delay caused by the City. PAR. 12 The Contractor agrees to pay punctually all just claims of labor, material, men, or subcontractors who shall perform labor or furnish materials entering into this improvement. It is agreed that the City need not pay the Contractor until all such claims are paid by the Contractor. It is agreed that the City shall not be liable for said labor, material, or men under this contract. PAR. 13 The Contractor agrees to furnish the City, simultaneously with this contract, a bond on a form to be provided by the City in the amount provided by law as stated in the Notice to Bidders, which shall be for the benefit of the City, and any and all persons injured by the breach of any of the terms of this contract. Said bond shall be filed with the City Clerk and shall be subject to the approval of the City Council, and is by reference made a part of this contract. PAR. 14 The Contractor agrees that should it abandon work under this contract or cease the prosecution thereof for a period of thirty (30) consecutive days without reasonable cause, and should it fail to proceed with said work within ten (10) days after a notice to continue or carry it on has been mailed to it at the address given herein by the City, or after such notice has been served on it, then the City may proceed to complete said work, using any material, tools, or machinery found along said line of work, doing the work either by contract or as it may elect, and the Contractor and the sureties on its bond shall be liable to the City for the costs and expenses so paid out. Said costs shall be retained by the City from any compensation due, or to become due the Contractor, and may be recovered by the City in an action upon Contractor's bond. PAR. 15 In consideration of the full compliance on the part of the Contractor with all the provisions, stipulations, and conditions hereof, or contained in the various instruments made a part of this contract by reference, and upon completion and acceptance of said work, the City agrees to pay to the Contractor, in the manner set out in the Notice to Contractors, the amount of money due the Contractor for work performed and accepted, at the unit prices set out in the Contractor's proposal, which has been accepted by the City. FORM OF CONTRACT PAGE 3 OF 5 PAGES PAR. 16 The total amount of the contract, based on the Engineer's estimates of quantities and the Contractor's unit bid prices, and for which 100% surety bond is required is $254,230.32. PAR. 17 After the completion of said work, the Contractor agrees to remove all debris and clean up said streets, and to save the City harmless from any damage allegedly resulting from a failure to clean up and remove the debris or put the street back in a proper condition for travel. PAR. 18 This contract is not divisible, but in the event of a conflict between this contract and the various instruments incorporated by reference, this contract shall govern. PAR. 19 Before the Contractor shall be entitled to receive final payment for work done under this contract, it shall execute and file a bond in the penal sum of not less than 100% of the total amount of the contract, same to be known as "Maintenance Bond," and which bond must be approved by the City Council, and which bond is in addition to the bond given by the Contractor to guarantee the completion of the work. PAR. 20 The Contractor shall maintain all work done hereunder in good order for the period of two (2) years from and after the date it is accepted by the Council of the City of Waterloo, Iowa. Said maintenance shall be made without expense to the City or the abutting property. In the event of the failure or default of the Contractor to remedy any or all defects appearing in said work within a period of two (2) years from the date of its acceptance by said Council, and after having been given ten (10) days notice so to do by registered letter deposited in the United States Post Office in said town, addressed to said contractor at the address herein given, then the City may proceed to remedy such defects. The costs and expenses thereof to be recovered from the Contractor and the sureties on its maintenance bond by an action brought in any court of competent jurisdiction. PAR. 21 The Contractor shall give notice to said City by registered letter directed to the Mayor or City Clerk/Auditor thereof not more than four (4) and not less than three (3) months prior to the expiration of the term during which the Contractor is required to maintain said improvements, in good repair by the terms of its Contract. The liability of the Contractor and of the sureties on its bond for maintenance of the said improvements shall continue until three (3) months after such notice has been given to the City, and, in any event, until two (2) years after the acceptance of the work. FORM OF CONTRACT PAGE 4 OF 5 PAGES CITY OF WATERLOO, IOWA Quentin }-fart Mayor Kelley �elchle : City Clerk AvgCSA- COv utr t' Inc. Contractor BY: Title: 0 vq r Approved by the City Council of the City of Waterloo, Iowa, this 21st day of September , 2020, ATTEST: Kellen �elchleEo City Clerk Waterloo, Iowa FORM OF CONTRACT PAGE 5 OF 5 PAGES Bond #2444793 PERFORMANCE BOND KNOW ALL MEN BY THESE PRESENTS: That we, Midwest Concrete, Inc of 9835 Cottingham Rd, Peosta, IA 52068 (the "Principal"), and West Bend Mutual Insurance Company of, P.O. Box 620976, Middleton, WI 53562 (the "Surety"), are held and firmly bound unto the City of Waterloo, Iowa (the "Obligee"), in the penal sum of Two Hundred Fifty-Four Thousand, Two Hundred Thirty Dollars and 32 Cents Dollars ($ $254,230.32 ) lawful money of the United States, for the pament of said sum in connection with a contract (the "Contract") dated on or about eptember 21, 2020 for the purpose of Waterloo Regional Airport Water Main Improvements— Phase I, Contract. No. 1033. The Contract is incorporated herein by reference as though fully set forth herein. Whenever the Principal shall be and is declared by the Obligee to be in default under the Contract, with the Obligee having performed its obligations in the Contract, then the Surety, acknowledging that time is of the essence, may promptly remedy the default, or shall promptly undertake to: 1. Complete the Contract in accordance with its terms and conditions; or 2. Obtain one or more bids for completing the Contract in accordance with its terms and conditions, and upon determination by the Surety of the lowest responsible bidder, or negotiated proposal, or, if the Obligee elects, upon determination by the Obligee and the Surety jointly of the lowest responsible bidder, or negotiated proposal, arrange for a contract between such party and the Obligee. The Surety will make available as work progresses sufficient funds to pay the cost of completion less the balance of the Contract price. The cost of completion includes responsibilities of the Principal for correction of defective work and completion of the Contract, the Obligee's legal and design professional costs resulting directly from the Principal's default, and liquidated damages or actual damages if no liquidated damages are specified in the Contract. The term "balance of the Contract price" means the total amount payable by the Obligee to the Principal under the Contract and any amendments thereto, less the amount properly paid by the Obligee to the Principal; or 3. Determine the amount for which it is liable to the Obligee and pay the Obligee that amount as soon as practicable. In the event this bond is enforced, Principal and Surety agree to indemnify Obligee and hold Obligee harmless from and against any and all costs of enforcement, including but not limited to reasonable attorneys' fees and expenses. Every Surety on this bond shall be deemed and held, any contract to the contrary notwithstanding, to consent to each and all of the following matters, without notice: Performance Bond Page 1 of 2 1. To any extension of time to the Contract in which to perform the Contract. 2. To any change in the plans, specifications, or Contract when such change does not involve an increase of more than twenty percent (20%) of the total Contract price, and shall then be released only as to such excess increase. 3. That no provision of this bond or of any other contract shall be valid which limits to less than one (1) year from the time of the acceptance of the work the right to sue on this bond for defect in workmanship or material not discovered or known to the Obligee at the time such work was accepted. If the Principal performs the Contract, then this bond shall be null and void; otherwise it shall remain in full force and effect. In no event shall the Surety's total obligation exceed the penal amount of this bond. Terms used herein shall include, as appropriate, the singular or plural number, or the masculine, feminine or neuter gender. IN WITNESS WHEREOFthe}em�er 5 si eod Principal and Surety have executed this Performance Bond as of p PRINCIPAL SURETY Midwest Concrete, Inc. West Bend Mutual Insurance Company Name Name By: G By: P",rkeel yan oats Nicole Hermsn Title: Owner Title: Attorney-In-Fact [attach Power of Attorney] NOTE: Date of BOND must not be prior to date of Contract. If CONTRACTOR is Partnership, all partners should execute BOND. If this project includes Federal Funds, the following applies to the payment;bond: IMPORTANT: Surety companies executing bonds must appear on the Treasury Department's most current list (Circular 570 as amended) and be authorized to transact business in the State where the project is located. Performance Bond Page 2 of 2 Bond #2444793 PAYMENT BOND KNOW ALL MEN BY THESE PRESENTS: that Midwest Concrete Inc. (Name of Contractor) 9835 Cottingham Rd., Peosta IA 52068 (Address of Contractor) a Corporation hereinafter called Principal, (Corporation, Partnership or Individual) and, West Bend Mutual Insurance Company (Name of Surety) P.O. Box 620976 Middleton WI 53562 (Address of Surety) hereinafter called Surety, are held and firmly bound unto City of Waterloo Iowa (Name of Owner) 715 Mulberry Street,Waterloo IA 50703 (Address of Owner) hereinafter called OWNER, in the penal sum of Two Hundred Fifty-Four Thousand, Two Hundred Thirty Dollars and 32 Cents Dollars,($ 254,230.32 ) in lawful money of the United States, for the payment of which sum well and truly to be made, we bind ourselves, successors, and assigns, jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION is such that whereas, the Principal entered into a certain contract with the OWNER, dated the 21st day of September 20 20 , a copy of which is hereto attached and made a part hereof for the construction of: WATERLOO REGIONAL AIRPORT WATER MAIN IMPROVEMENTS- PHASE 1 CITY CONTRACT NUMBER 1033 CITY OF WATERLOO, IOWA NOW, THEREFORE, if the Principal shall promptly make payment to all persons, firms, SUBCONTRACTORS, and corporations furnishing materials for or performing labor in the prosecution of the WORK provided for in such contract, and any authorized extension or modification thereof, including all amounts due for materials, lubricants, oil, gasoline, coal and coke, repairs on machinery, equipment and tools, consumed or used in connection with the construction of such WORK, and all insurance premiums on said WORK, and for all labor, performed in such WORK whether by SUBCONTRACTOR or otherwise, then this obligation shall be void; otherwise to remain in full force and effect. PROVIDED, FURTHER, that the said Surety for value received hereby stipulates and agrees that no change, extension of time, alteration or addition to the terms of the contract or to the WORK to be performed thereunder or the SPECIFICATIONS accompanying the same shall in any wise affect its obligation on this BOND, and it does hereby waive notice of any such change, extension of time, alteration or addition to the terms of the contract or to the WORK or to the SPECIFICATIONS. PROVIDED, FURTHER, that no final settlement between the OWNER and the CONTRACTOR shall abridge the right of any beneficiary hereunder, whose claim may be unsatisfied. IN WITNESS HEREOF, this instrument is executed in 1 counterparts, each one of which shall be deemed an original, this the 21st (number) day of September 20 20 ATTEST: Midwest Concrete, Inc. { Principal (Principal) Secretary (SEAL) By (s) Ry n Coates 9835 Cottinqham Rd (Address) Peosta, IA 52068 Witness as to Principal 9835 Cottingham Rd (Address) Peosta, IA 52068 TRICOR Insurance. Sur y _ ATTEST: By ppff`,�� Nic le Hermsen Attorn y-' -Fact �h& 600 Star Brewery Dr., Ste 110 Witness as to Surety Kim I�-ess (Address) 600 Star Brewery Dr., Ste 110 Dubuque, IA 52001 (Address) Dubuque, 1A 52001 NOTE: Date of BOND must not be prior to date of Contract. If CONTRACTOR is Partnership, all partners should execute BOND. ;If this_project includes Federal.Funds, the.following applies to`tfle payment bond: IMPORTANT: Surety companies executing bonds must appear on the Treasury Department's most current list (Circular 570 as amended) and be authorized to transact business in the State where the project is located. 1NEST BE D THE SILVER LIN,ING A MUT'uAL JNSU AN+ce COMPANY 0attd lei, x"793 POWEWO AO"RIN Know all men by these Presents,That West Bend Mutual Insurartos;Company,a corporation hawing its principal offloaJOthie.tllfy 0 i Bend,Wisconsin odes make,constitute and appoint: Nirals Harmsen lawful Aftomey(s)-ln=fact,to make,execute,seal and:d�ti�orfbr and on its b t a�€as;surety and as ifs.pct"and deed any,andall bonds,untlertakings"and contracts of suretyship,provided that rro`i tattdz unde4af pg pr oaa1r�act pf sure st of d unclar this Out, Shall exceed"in amount the sura-of: Ten nnitll t k ottar 't$1U,ODQ;t1 A' This Power of Attorney-is granted and is signed and sealed by facsimile under and by tho��lth,odty.of the following Resolution adopted by the Board of Directors 6f West Bend Mutual Insurance Company at a meeting duly calfed'and held oft the 2;1st day of December, 1999. Appointment ofAttorney-ln-Fact The presidentor,any..vice president,or any other off eer 9f West Bend Mutual Insurance Cbmpany may appoint by written certificate Attorneys-ln4F ct to act on Walfof the-company hzthe execution of and attesting of` liondsand undertakings and other,written obllgatoryinsteumentsafiikmature. The sfgnature"of�rwofficerauthorized""hereby. and the corporate seal may be affixed byfacsinifle to any.such power of,attorney or hD anycert Brie rplat ng th06reand any such power of attorney or certfJlcaie bearing such frresrmflesfgnatures or facsfrnfie seal Agll be vatfd and, brnding Upon the company,and any such power so executed and certffred byfacsimilesfgna'tures and facsim leseal�shaltba'validand binding upon the company in the future with respect to any bond or undertaking or ether writing obligatory in Pattrrr to which.lt is attached Any such appointment maybe revolted,for cause,pr without cause,;by any said officer at atiy Umv. In witness whereof,the West Bend Mutual Insurance Company has caused these presents to be 81n ed by lts';presiderit unde s-hW- and its corporate seal to be hereto duly attested by its secretary this 22nd day of Se tember,.2017 Attest N,- Chrisiogher C. Bart iu r' �1 Kevin A.Steiner Secretary ~; S _ iChief gxeeutive OfFxcerf Pre.4ident` c? r State of Wisconsin "y County of Washington On the 22nd day of September, 2017,before me personally came Kevin A.Steiner,to me known being by duly sworn,did depose and say that he resides in the County of Washington,State of Wisconsin;that he is the President of West Bend Mutual insurance Company, the corporation described in and which executed the above instrument;that he knows the seal of the said corporation;that the seal affixed to said instrument is such corporate seal;that is was so affixed by order of the board of directors of said corporation and that he signed his name thereto by like order. �y VI4TAR). nedum PUBLIC_-��+ 509100 211 VOrat-,Attorney roof wss�° Notary Public,'Washington Co.,WI • My Commissi©n.19 Permanent The undersigned,duly elected to the once stated below, now the"incumbent in West Bend Mutual Insurance Company,a Wisconsin corporation authorized to matte this certificate,Do Hereby Certify that the foregoing attached Power of Attorney remains in 1`611 force effect and has not been revoked and that the Resolution of the Board of Directors,set forth in the Power of Attorney is now in force. Signed and sealed at West Bend,Wisconsin this 21 st day of September 2020 f L t s r." ' 4a�her Dunn _ . r rrY '74 ic+r president—Chief Financial€7flncet Notice; Any questions concerning this Power al'Aftorney Maybe diroctet to the Bond Manager at'NS11,a division of"Wo #=Bend Mutual Insurance Company, 1900 S.181h Ave. West Bcnd,WI 53095 1 ph{262�334.6430 1 1-800-231-5004 1 fax(262)338-5058 1 www.thesilverlinin8.ei7m MIDWCON-03 KHESS '4co�zo CERTIFICATE OF LIABILITY INSURANCE FDATE(MMIDDIYYYY) 9/28/2020 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER.THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S),AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED,the policy(ies)must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy,certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER CONTACT NAME: TRICOR,Inc.-Dubuque PHONE 600 Star Brewery Drive (A/C,No,Ext): (563) 556-5441 FA 600 No):(608)723-6440 Suite 110 ADDRESS: Dubuque,IA 52001 INSURERS AFFORDING COVERAGE NAIC# INSURER A:Sheboygan Falls/LeMars/Done al Ins Co. 15148 INSURED INSURER B:Markel Insurance Company Midwest Concrete Inc AHL Equipment Leasing,Inc. INSURER C 9835 Cottingham Rd INSURER D: Peosta,IA 52068 INSURER E: INSURER F: COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR TYPE OF INSURANCE ADDL SUBR POLICY NUMBER POLICY EFF POLICY EXP LIMITS LTR D IN WVD MM DD YYY MM DD YYY A X COMMERCIAL GENERAL LIABILITY EACH OCCURRENCE $ 1,000,000 CLAIMS-MADE X OCCUR CPA9030194 4/15/2020 4/15/2021 DAMAGE TO RENTED 100,000 X PREMISES Ea occurrence $ MED EXP(Any oneperson) $ 5,000 PERSONAL&ADV INJURY $ 1,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $ 2,000,000 POLICY PE� El LOC PRODUCTS-COMP/OP AGG $ 2,000,000 OTHER: $ A AUTOMOBILE LIABILITY COMBINED SINGLE LIMIT 1,000,000 Ea accident $ X ANY AUTO CAA9030194 4/15/2020 4/15/2021 BODILY INJURY Perperson) $ OWNED SCHEDULED AUTOS ONLY AUTOS BODILY INJURY Per accident $ HIRED L $ NON-OWNED PROPERTY DAMAGE AUTOS ONLY AUTOS ONLY Per accident) ccident $ A X UMBRELLA LIAB X OCCUR EACH OCCURRENCE $ 4,000,000 EXCESS LIAB CLAIMS-MADE CWA9030194 4/15/2020 4/15/2021 AGGREGATE $ 4,000,000 DED RETENTION$ $ A WORKERS COMPENSATIONX PER OTH- AND EMPLOYERS'LIABILITY STATUTE ER Y/N WCA9030194 4/15/2020 4/15/2021 500,000 ANY PROPRIETOR/PARTNER/EXECUTIVE N/A E.L.EACH ACCIDENT $ OFFICER/MEMBER EXCLUDED? (Mandatory in NH) E.L.DISEASE-EA EMPLOYEE $ 500,000 If yes,describe under 500,000 DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT $ B Pollution Liability CPLMOL102653 4/15/2020 4/15/2022 Occurrence 1,000,000 DESCRIPTION OF OPERATIONS/LOCATIONS/VEHICLES ACORD 101,Additional Remarks Schedule,may be attached if more space is required) Project: Waterloo Regional Airport Water Main improvements The City of Waterloo is additional insured on the general liability policy with respect to the insured contract. CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE Cit of Waterloo THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN Y ACCORDANCE WITH THE POLICY PROVISIONS. 715 Mulberry St Waterloo,IA 50703 AUTHORIZED REPRESENTATIVE ACORD 25(2016/03) ©1988-2015 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD