Loading...
HomeMy WebLinkAboutOwen Contracting - Contract, Perf Bond, Bonds and COI _ 4.3.2023CONTRACT FOR IMPROVEMENTS TO THE WATERLOO REGIONAL AIRPORT CONSISTING OF RECONSTRUCT TAXIWAY A WEST FAA #3-19-0094-056-2023 BIL AT THE WATERLOO REGIONAL AIRPORT WATERLOO, IOWA THIS AGREEMENT, made and entered into this 3rd day of April , 2023 by and between the Waterloo Regional Airport for the City of Waterloo, Black Hawk County, Iowa, hereinafter referred to as the "Owner" and Owen Contracting, Inc., a corporation organized and existing under the laws of the State of Iowa, hereinafter referred to as the "Contractor." WITNESSETH: That the Contractor for and in consideration of Two Million Four Hundred Eighty -Eight Thousand Five Hundred Twenty -Three and 75/100 Dollars ($2,488,523.75), based on the unit bid prices payable as set forth in the Specifications constituting a part of this Contract, hereby agrees to construct in accordance with the Plans, Specifications and Special Provisions therefore, and in the location designated on the Plans, the various items of work awarded said Contractor on the day of , 20 , as follows, being numbered as shown in schedule of prices bid in the attached Proposal which is a part of this Contract. Said Specifications and Plans are hereby made a part of and the basis of this Agreement and a true copy of said Plans and Specifications is now with the Waterloo Regional Airport in the office of the Director of Aviation, Waterloo, Iowa, under date of , 20. 1. That in consideration of the foregoing, the Owner hereby agrees to pay the Contractor promptly and according to the requirements of the Specifications, the amounts set forth, subject to the conditions as set forth in the Specifications. 2. That it is understood that the parties named herein are the only persons interested in this Contract and principals. 3. That the Contractor has examined the site of the proposed work, Plans, Specifications, Special Provisions and Contract Documents in order that he might become familiar with the character, quality and quantity of the work to be performed, the materials to be furnished and the requirements of the Specifications, Special Provisions and Contract Documents. 4. It is hereby further agreed that any reference herein to the "Contract" shall include all "Contract Documents" for the Waterloo Regional Airport, FAA Project Nos. 3-19-0094-0056 and said "Contract Documents" are hereby made a part of this agreement as fully as if set out at length herein, and that this contract is limited to the items in the proposal as signed by the "Contractor" and included in the "Contract Documents." 5. That in the event any surety upon any bond furnished in connection with this Contract becomes unacceptable to the Owner, or if any such surety shall fail to furnish reports as to his financial condition from time to time as requested by the Owner, the Contractor agrees to furnish promptly such additional security as may be required from time to time to protect the interests of the Owner or of persons supplying labor or materials in the prosecution of the work contemplated by the Contract. 6. That the Contractor shall not commence any work to be performed under this Contract until he has obtained from responsible insurance companies, all insurance required, as set forth in the General Provisions and that the Contractor shall maintain this insurance in full force and effect until the work to be performed under this Contract has been accepted by the Owner. FAA AIP #3-19-0094-056-2023 BIL C-1 Waterloo Regional Airport AEC OM Project #60695167 Reconstruct Taxiway A West 7. That the Contractor shall not start working on any alterations requiring a supplemental agreement until the agreement setting forth the adjusted price shall be executed by the Owner and the Contractor. 8. That the Contractor, at all times, shall observe and comply with all federal, state, territory or possession and local laws, codes, ordinances and regulations in any manner affecting the conduct of the work, and the Contractor and his surety shall indemnify and save harmless the Owner and all his officers, Engineer, agents and servants against claims or liability arising from or based on the violation of any such law, ordinance, deregulation, order or decree, whether by himself or his employees. 9. That it is further understood and agreed by the parties to this Contract that the above work shall be commenced within 10 days after "Notice to Proceed" and shall be completed according to the terms of the entire contract within one hundred -twenty (120) calendar days from the date established in the Notice to Proceed. Failure to complete within the allotted time will result in assessment of liquidated damages in the amount of $500.00 per calendar day for each day in excess of the authorized contract time. In addition, the Runway 18/36 closure for Phase 3 work shall be limited to thirty (30) calendar days. Failure to complete Phase 3 work and re -open Runway 18/36 to traffic within the allotted time will result in assessment of liquidated damages in the amount of $1,000 per calendar day for each day in excess of the thirty (30) calendar days allotted in the contract. 10. The Contractor and Owner understand and agree that time is of essence for completion of the Work and that the Owner will suffer additional expense and financial loss if said work is not completed within the authorized Contract Time. Furthermore, the Contractor and Owner recognize and understand the difficulty, delay, and expense in establishing the exact amount of actual financial loss and additional expense. Accordingly, in place of requiring such proof, the Contractor expressly agrees to pay the Owner as liquidated damages the non -penal sum of $500.00 per day for each calendar day required in excess of the authorized Contract Time for the overall contract. Furthermore, the Contractor understands and agrees that: a. the Owner has the right to deduct from any moneys due the Contractor, the amount of said liquidated damages; b. the Owner has the right to recover the amount of said liquidated damages from the Contractor, Surety, or both. 11. The Contractor understands and agrees that all certifications made by the Contractor within the Proposal shall apply under this Agreement as if fully rewritten herein. The Contractor further certifies the following: a. Certification of Eligibility (29 CFR Part 5.5) (1) By Entering into this contract, the Contractor certifies that neither he or she nor any person or firm who has an interest in the Contractor's firm is a person or firm ineligible to be awarded Government contracts by virtue of Section 3(a) of the Davis -Bacon Act or 29 CFR 5.12(a)(1); (2) No part of this contract shall be subcontracted to any person or firm ineligible for award of a Government contract by virtue of Section 3(a) of the Davis -Bacon Act or 29 CFR 5.12(a)(1); (3) The penalty for making false statements is prescribed in the U.S. Criminal Code 18 U.S.C. b. Certification of Non -Segregated Facilities (41 CFR Part 60-1.8) The federally -assisted construction Contractor, certifies that it does not maintain or provide, for its employees, any segregated facilities at any of its establishments and that it does not permit its employees to perform their services at any location, under its control, where segregated facilities are maintained. The Bidder certifies that it will not maintain or provide, for its employees, segregated facilities at any of its establishments and that it will not permit its employees to perform their services at any location under its control where segregated facilities are maintained. The Bidder agrees that a breach of this certification is a violation of the Equal Opportunity Clause, which is to be incorporated in the contract. As used in this certification, the term "segregated facilities" means any waiting rooms, work areas, restrooms, and washrooms, restaurants and other eating areas, timeclocks, locker rooms and other storage or dressing areas, parking lots, drinking fountains, recreation or entertainment areas, transportation, and housing facilities FAA AIP #3-19-0094-056-2023 BIL C-2 Waterloo Regional Airport AECOM Project #60695167 Reconstruct Taxiway A West provided for employees which are segregated on the basis of race, color, religion, or national origin because of habit, local custom, or any other reason. The Bidder agrees that (except where it has obtained identical certifications from proposed subcontractors for specific time periods) it will obtain identical certifications from proposed subcontractors prior to the award of subcontracts exceeding $10,000 which are not exempt from the provisions of the Equal Opportunity Clause and that it will retain such certifications in its files. 12. It is further understood that any action in court against the Contractor or sureties on his bond because of damage to property or individuals by said Contractor or his workmen, or because of the violation of any provisions of the Specifications, or on account of the failure of said Contractor to fully comply with these provisions, shall be brought in the District Court of the State of Iowa in and for Black Hawk County. 13. Second Party shall maintain all work done hereunder in good order for a period of 12 months from and after the date it is accepted by the Waterloo Regional Airport, City of Waterloo, Iowa, which maintenance shall be without expense to First Party or the abutting property. In the event of the failure or default of Second Party to remedy any or all defects appearing in said work within a period of 12 months from the date of its acceptance by said Board and after having been given ten (10) days' notice so to do by registered letter deposited in the United States Post Office in said City, addressed to said Contractor at the address herein given, then First Party may proceed to remedy such defects and the cost and expenses thereof may be recovered from said Second Party and the sureties on its bond by action brought in any court of competent jurisdiction, but such suit may be brought in the District Court of Black Hawk County, Iowa. IN WITNESS WHEREOF, the parti s ereto have set their hands for the purpose herein expressed to this and three other instruments of like tenor, as of the .Jru day of April 20 23 CITY OF WATERLOO Quert6a glare sus By Mayor ATTEST: Rl,eOCey rFe[ckte City Clerk Secretary CONTRACTOR Owen Contracting, Inc. re s Jek.* 132 S lar:I Way 'Cedar V7115; 3r0 613 Witness Witness Firm Name Signature Title Business Address FAA AIP #3-19-0094-056-2023 BIL C-3 Waterloo Regional Airport AECOM Project #60695167 Reconstruct Taxiway A West Bond Number: 54-251223 PERFORMANCE BOND KNOW ALL MEN BY THESE PRESENTS: That we, Owen Contracting, Inc., as PRINCIPAL, also referred to as CONTRACTOR, and United Fire & Casualty Company , as SURETY, are held and firmly bound unto Waterloo Regional Airport, 2790 Livingston Lane, Waterloo, Iowa 50703 as OWNER, in the full sum of Two Million Four Hundred Eighty -Eight Thousand Five Hundred Twenty -Three and 75/100 Dollars ($2,488,523.75) for the payment of which, well and truly to be made, we bind ourselves, our heirs, executors, administrators, successors and assigns, jointly and severally, by these presents. WHERF Shjthe above -bound Principal as entered into a contract with the OWNER dated the day of _ `� , 20, for Reconstruct Taxiway A West, including: • Reconstruction of Taxiway A south of Taxiway B and east of Runway 18/36 with 7-inch and 12.5-inch Portland Cement Concrete Pavement with pavement widths varying from 35 foot to 50 foot. • Removal and replacement of a Section of the 9-inch Portland Cement Concrete in the General Aviation Apron and replacement including subbase courses. • Removal and replacement of Taxiway A in this section with Medium Intensity Edge Lights, wiring and conduit and replacement with new LED Medium Intensity Taxiway Edge Lights, new conduit and wiring, LED Runway Guard Lights and LED Guidance Signage • Subdrain installation along Taxiway A. • Pavement marking for Taxiway A This work and all other incidentals shall be performed as shown on the Drawings and described in the Specifications. NOW, THEREFORE, the conditions of this obligation are such that if the above -bound PRINCIPAL shall faithfully and fully comply with the terms and conditions of said contract, including, but not limited to, any obligations created by way of warranties and/or guarantees for workmanship and materials which warranty and/or guarantee may extend for a period of time beyond completion of said contract, and such alternations or additions as may be made therein or in the plans and specifications, and shall indemnify and save the OWNER harmless against any claims for using any form of material, process, composition or anything which is patented, and likewise indemnify and save the OWNER harmless against all claims for damages by reason or any default or negligence, want of skill or care on the part of said PRINCIPAL or Agents in and about the performance of said contract, and shall comply with all laws pertaining to said work, and shall comply with and perform any and all warranties and/or guarantees provided for in said contact, then this obligation shall be void; otherwise of full force and effect. PROVIDED, further than upon either the default of the PRINCIPAL, or the failure of the said PRINCIPAL to promptly and efficiently prosecute said Work, in any respect, in accordance with the Contract Documents, the above bound SURETY shall either remedy the default of the PRINCIPAL or shall take charge of said Work and complete the Contract at his own expense, pursuant to its terms, receiving, however, any balance of the funds in the hands of said OWNER due under said contract. It shall be the duty of the SURETY to give an unequivocal notice in writing to the OWNER within ten (10) days after receipt of a declaration of default of the SURETY'S election either to remedy the default or defaults promptly or to perform the contract promptly, time being of the essence. In said notice of election, the SURETY shall indicate the date on which the remedy or performance will commence, and it shall be the duty of the SURETY to give prompt notice in writing to the OWNER immediately upon completion of (a) the remedy and/or correction of each default, (b) the remedy and/or correction of each item of condemned work, (c) the fumishings of each omitted item of work, and (d) the performance of the contract. The SURETY shall not asset solvency of its PRINCIPAL as justification for its failure to promptly remedy the default or defaults or perform the contract. In the event said PRINCIPAL shall fail or delay the prosecution and completion of said Work and said SURETY shall also fail to act promptly as hereinabove provided, then the OWNER shall cause ten (10) days notice of such failure to be given, both to said PRINCIPAL and SURETY, and at the expiration of said ten (10) days, if said PRINCIPAL or SURETY do not proceed promptly to execute said Contract, the OWNER shall have the authority to cause said Work to FAA AIP #3-19-0094-056-2023 BIL C-4 Waterloo Regional Airport AECOM Project #60695167 Reconstruct Taxiway A West be done and when the same is completed and the cost thereof estimated, the said PRINCIPAL and SURETY shall and hereby agree to pay any excess in the cost of said Work above the agreed price to be paid under said Contract. Upon completion of said Contract pursuant to its terms, if any funds remain due on said Contract, the same shall be paid to said PRINCIPAL and SURETY. The said PRINCIPAL and SURETY further agree as part of this obligation to pay all such damages of any kind to person or property that may result from a failure in any respect to perform and complete said Contract including, but not limited to, all repair and replacement costs necessary to rectify construction error, architectural and engineering costs and fees, all (but not limited to) consultant fees, all testing and laboratory fees, and all legal fees and litigation costs incurred by the OWNER. The decision of the OWNER, upon any disputed question connected with the execution of said Contract, or any failure or delay in the prosecution of the Work by said PRINCIPAL or SURETY, shall be final and conclusive. The SURETY agrees that other than as is provided in this bond, it may not demand of the OWNER the OWNER shall (a) perform any thing or act, (b) give any notice, (c) furnish any clerical assistance, (d) render any service, (3) furnish any papers or documents, or (f) take any other action of any nature or description which is not required of the OWNER to be done under the contract documents. IN WITNESS WHEREOF, the SURETY and PRINCIPAL have executed this instrument under their several seals this day of , 20_, the name and corporate seal of each corporate party being hereto affixed and these presents duly signed by its undersigned representative, pursuant to authority of its governing body. FAA AIP #3-19-0094-056-2023 BIL C-5 Waterloo Regional Airport AECOM Project #60695167 Reconstruct Taxiway A West Witness E. A. von Harz, Sr nds Account Manager PRINCIPAL: Owen Contracting, Inc. E � lt?)' eAte 4,+ SURETY: Ujited Fire & Casualty Company Juliona Bartlett, Attorney -in -Fact NOTE: (a) Where the Performance Bond is executed by an attomey-in-fact, there shall be attached to each copy of the Bond a certified copy of Power of Attorney properly executed and dated. (b) Each copy of the Bond shall be countersigned by an authorized agent of the bonding company licensed to do business in the State of Iowa. The title of the person countersigning the Bond shall appear after his or her signature. (c) The seal of the bonding company shall be attached to each copy of the bond. (d) The Contractor's signature on the bond shall correspond with the signature in the contract. (e) The bond shall be accompanied by a corporate resolution (which may be combined with the corporate resolution granting the signing officer authority to execute contracts) granting the corporate officer who executes the Bond the authority to do so. (f) Surety companies executing bonds must appear on the Treasury Department's most current list (Circular 570 as amended) and be authorized to transact business in the State of Iowa. FAA AIP #3-19-0094-056-2023 BIL C-6 Waterloo Regional Airport AECOM Project #60695167 Reconstruct Taxiway A West PAYMENT BOND KNOW ALL MEN BY THESE PRESENTS: That we, Owen Contracting, Inc., as PRINCIPAL, also referred to as CONTRACTOR, and United Fire & Casualty Company , as SURETY, are held and firmly bound unto Waterloo Regional Airport, 2790 Livingston Lane, Waterloo, Iowa 50703 as OWNER, in the full sum of Two Million Four Hundred Eighty -Eight Thousand Five Hundred Twenty -Three and 75/100 Dollars ($2,488,523.75), for the use and protection of said OWNER and all subcontractors and all persons supplying labor, materials, machinery and equipment for the performance of the work provided for in the contract hereinafter referred to, for the payment of which, well and truly to be made, we bind ourselves, our heirs, executors, administrators, successors and assigns, jointly and severally, by these presents. WHEREAS, tj�e above -bound Principal has entered into a contract with the OWNER dated the 3rd day of Abe 20 23 for Reconstruct Taxiway A West, including: • Reconstruction of Taxiway A south of Taxiway B and east of Runway 18/36 with 7-inch and 12.5-inch Portland Cement Concrete Pavement with pavement widths varying from 35 foot to 50 foot. • Removal and replacement of a Section of the 9-inch Portland Cement Concrete in the General Aviation Apron and replacement including subbase courses. • Removal and replacement of Taxiway A in this section with Medium Intensity Edge Lights, wiring and conduit and replacement with new LED Medium Intensity Taxiway Edge Lights, new conduit and wiring, LED Runway Guard Lights and LED Guidance Signage • Subdrain installation along Taxiway A. • Pavement marking for Taxiway A This work and all other incidentals shall be performed as shown on the Drawings and described in the Specifications. NOW, THEREFORE, the condition of this obligation is such that if the above -bound PRINCIPAL shall promptly make payment to all claimants as hereinafter defined, for all labor and materials supplied in the prosecution of the work provided for in said Contract, then this obligation shall be void; otherwise, it shall remain in full force and effect, subject, however, to the following conditions: 1. The said SURETY to this bond, for value received, hereby stipulates and agrees that no change or changes, extension of time or extensions of time, alteration of alterations or addition or additions to the terms of the contract or to the work to be performed thereunder, or the specifications or drawings accompanying same shall in any wise affect its obligation on this bond, and it does hereby waive notice of any such change or changes, extension of time or extensions of time, alteration or alterations or addition or additions to the terms of the contract or to the work or to the specifications or drawings. 2. A claimant is defined as any subcontractor and any person supplying labor, materials, machinery, or equipment in the prosecution of the work provided for in said contract. Signed and sealed this 3rd day of April 20 23 FAA AIP #3-19-0094-056-2023 BIL C-7 Waterloo Regional Airport AECOM Project #60695167 Reconstruct Taxiway A West IN THE PRESENCE OF: Witness E. A. von Harz, Sr. Bonds Account Manager PRINCIPAL: Owen Contracting, Inc. Ariett. Jak OWENf readecb SURETY: United Fire & Casualty Company 614401 gar/ Julia Bartlett, Attorney -in -Fact NOTE: (a) Where the Payment Bond is executed by an attorney -in -fact, there shall be attached to each copy of the Bond a certified copy of Power of Attorney properly executed and dated. (b) Each copy of the Bond shall be countersigned by an authorized agent of the bonding company licensed to do business in the State of Iowa. The title of the person countersigning the Bond shall appear after his or her signature. (c) The seal of the bonding company shall be attached to each copy of the bond. (d) The Contractor's signature on the bond shall correspond with the signature in the contract. (e) The bond shall be accompanied by a corporate resolution (which may be combined with the corporate resolution granting the signing officer authority to execute contracts) granting the corporate officer who executes the Bond the authority to do so. (f) Surety companies executing bonds must appear on the Treasury Department's most current list (Circular 570 as amended) and be authorized to transact business in the State of Iowa. FAA AIP #3-19-0094-056-2023 BIL C-8 Waterloo Regional Airport AECOM Project #60695167 Reconstruct Taxiway A West UNITED FIRE & CASUALTY COMPANY, CEDAR RAPIDS, IA UNITED FIRE & INDEMNITY COMPANY, WEBSTER, TX FINANCIAL PACIFIC INSURANCE COMPANY, LOS ANGELES, CA CERTIFIED COPY OF POWER OF ATTORNEY (original on file at Home Office of Company - See Certification) KNOW ALL PERSONS BY THESE PRESENTS, That United Fire & Casualty Company, a corporation duly organized and existing under the laws of the State of Iowa; United Fire & Indemnity Company, a corporation duly organized and existing under the laws of the State of Texas; and Financial Pacific Insurance Company, a corporation duly organized and existing under the laws of the State of California (herein collectively called the Companies), and having their corporate headquarters in Cedar Rapids, State of Iowa, does make, constitute and appoint GREG T. LA MAIR, JEFFREY R. BAKER, JOSEPH I. SCHMIT, E. A. VON HARZ, BRANDON HORBACH, COURTNEY MEYER, JULIANA BARTLETT, DANIEL M. MOLYNEAUX, LAURA J. ADAMS, LORI S. BURROUGHS, PAMELA K. MATTISON, KAREN S. HARTSON, EACH INDIVIDUALLY e UfgCedar Rapids, IA 52401 Inquiries: Surety Department 118 Second Ave SE INSURANCE their true and lawful Attomey(s)-in-Fact with power and authority hereby conferred to sign, seal and execute in its behalf all lawful bonds, undertakings and other obligatory instruments of similar nature provided that no single obligation shall exceed $100 , 000 , 000.00 and to bind the Companies thereby as fully and to the same extent as if such instruments were signed by the duly authorized officers of the Companies and all of the acts of said Attorney, pursuant to the authority hereby given and hereby ratified and confirmed. The Authority hereby granted is continuous and shall remain in full force and effect until revoked by United Fire & Casualty Company, United Fire & Indemnity Company, and Financial Pacific Insurance Company. This Power of Attorney is made and executed pursuant to and by authority of the following bylaw duly adopted by the Boards of Directors of United Fire & Casualty Company, United Fire & Indemnity Company, and Financial Pacific Insurance Company. "Article VI — Surety Bonds and Undertakings" Section 2, Appointment of Attorney -in -Fact. "The President or any Vice President, or any other officer of the Companies may, from time to time, appoint by written certificates attorneys -in -fact to act in behalf of the Companies in the execution of policies of insurance, bonds, undertakings and other obligatory instruments of like nature. The signature of any officer authorized hereby, and the Corporate seal, may be affixed by facsimile to any power of attomey or special power of attorney or certification of either authorized hereby; such signature and seal, when so used, being adopted by the Companies as the original signature of such officer and the original seal of the Companies, to be valid and binding upon the Companies with the same force and effect as though manually affixed. Such attorneys -in -fact, subject to the limitations set of forth in their respective certificates of authority shall have full power to bind the Companies by their signature and execution of any such instruments and to attach the seal the Companies thereto. The President or any Vice President, the Board of Directors or any other officer of the Companies may at any time revoke all power and authority previously given to any attomey-in-fact. rrrririttntit.3 IN WITNESS WHEREOF, the COMPANIES have each caused these presents to be signed by its vice president and its corporate seal to be hereto affixed this ,,glUilll1ryp ovil i wren. „ ' 4°''' . '1rr'T r ycoe.k 44AP n `i 8 q G �f}•-, 7, 4 DULY 2Z �a nn vi y. 196fi 14 iiriainriniz'�'` 'nr4errnap,nv ' 10th day of March, 2014 UNITED FIRE & CASUALTY COMPANY UNITED FIRE & INDEMNITY COMPANY FINANCIAL PACIFIC INSURANCE COMPANY By: State of Iowa, County of Linn, ss: Vice President On 10th day of March, 2014, before me personally came Dennis J. Richmann to me known, who being by me duly sworn, did depose and say; that he resides in Cedar Rapids, State of Iowa; that he is a Vice President of United Fire & Casualty Company, a Vice President of United Fire & Indemnity Company, and a Vice President of Financial Pacific Insurance Company the corporations described in and which executed the above instrument; that he knows the seal of said corporations; that the seal affixed to the said instrument is such corporate seal; that it was so affixed pursuant to authority given by the Board of Directors of said corporations and that he signed his name thereto pursuant to like authority, and acknowledges same to be the act and deed of said corporations. Judith A. Jones Iowa Notarial Seal Commission number 173041 My Commission Expires 4/23/2024 Notary Public My commission expires: 4/23/2024 I, Mary A. Bertsch, Assistant Secretary of United Fire & Casualty Company and Assistant Secretary of United Fire & Indemnity Company, and Assistant Secretary of Financial Pacific Insurance Company, do hereby certify that I have compared the foregoing copy of the Power of Attorney and affidavit, and the copy of the Section of the bylaws and resolutions of said Corporations as set forth in said Power of Attorney, with the ORIGINALS ON FILE IN THE HOME OFFICE OF SAID CORPORATIONS, and that the same are correct transcripts thereof, and of the whole of the said originals, and that the said Power of Attorney has not been revoked and is now in full force and effect. In testimony whereof I have hereunto subscribed my name and affixed the corporate seal of the said Corporations this et i rrtrrer avv,.. 'prorytKa'`t, BP•A0049 1217 day of , 20 By: -i /1�, /t ,A212,- A, U Assistant Secretary, UF&C & OF&I & FPIC �....N OWENC-1 '4co/zif, CERTIFICATE OF LIABILITY INSURANCE �� OP ID: JT DA06/19/2023TE Y) 06/19/2023 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER 319-233-6103 The Sinnott Agency, Inc. 622 W 4th St., PO Box 1918 Waterloo, IA 50704 Steven Sinnott CONTACT Janan Timmer PHONE 319-233-6103 FAX 319-234-8133 (A/C, No, Ext): (AIC, No): ADDRIEss.Janant@sinnottagency.com INSURER(S) AFFORDING COVERAGE NAIC # INSURER A : Continental Western Group 10804 11 v� CONTRACTING, INC. 1325 RAIL WAY CEDAR FALLS, IA 50613 INSURER B : INSURER C : INSURER D : INSURER E : INSURER F : COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR LTR TYPE OF INSURANCE ADDL INSD SUBR WVD POLICY NUMBER POLICY EFF (MM/DDIYYYY), POLICY EXP (MM/DD/YYYYI LIMITS A X COMMERCIAL GENERAL LIABILITY CPA3220313-25 04/20/2023 04/20/2024 EACH OCCURRENCE $ 1,000,000 CLAIMS -MADE X OCCUR DAMAGE TO RENTED PREMISES (Ea occurrence) 300,000 $ MED EXP (Any one person) $ 10,000 PERSONAL & ADV INJURY $ 1,000,000 GEN'L AGGREGATE X LIMIT APPLIES Fla PER: LOC GENERAL AGGREGATE $ 2,000,000 PRODUCTS - COMP/OP AGG $ 2,000,000 $ A AUTOMOBILE X LIABILITY ANY AUTO OWNED SCHEDULED AUTOS NON -OWNED UUOONLY CPA3220313-25 04/20/2023 04/20/2024 COMBINED SINGLE LIMIT (Ea accident) 1,000,000 $ BODILY INJURY (Per person) $ BODILY INJURY (Per accident) $ PROPERTY aEden)AMAGE (Per accident) $ $ A X X UMBRELLA LIAB EXCESS LIAB X OCCUR CLAIMS -MADE CPA3220313-25 04/20/2023 04/20/2024 EACH OCCURRENCE $ 5,000,000 AGGREGATE $ 5,000,000 DED X RETENTION $ 0 $ A WORKERS COMPENSATION AND EMPLOYERS' LIABILITY ANY PROPRIETOR/PARTNER/EXECUTIVE OFFICER/MEMBER EXCLUDED? (Mandatory in NH) If yes, describe under DESCRIPTION OF OPERATIONS below Y/N N NIA WCA3220314-26 04/20/2023 04/20/2024 X PER STATUTE OTH- ER E.L. EACH ACCIDENT 500,000 $ E.L. DISEASE - EA EMPLOYEE $ 500,000 E.L. DISEASE - POLICY LIMIT 500,000 $ A LEASED/RENTED EQUIPMENT CPA3220313-25 04/20/2023 04/20/2024 50,000 DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached if more space is required) 30 DAY CANCEL NOTICE WILL BE GIVEN TO WATERLOO REGIONAL AIRPORT PER CLIL0012 11/10. CERTIFICATE HOLDER CANCELLATION WLOOAIR WATERLOO REGIONAL AIRPORT CITY OF WATERLOO 2790 AIRPORT BLVD WATERLOO, IA 50703 1 SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. AUTHORIZED REPRESENTATIVE Iavt . di,,, ACORD 25 (2016/03) © 1988-2015 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD