Loading...
HomeMy WebLinkAboutWHKS & Co., Consultant Agreement - Shaulis-Hammond Roundabout - 10.2.2023whks PROFESSIONAL SERVICES AGREEMENT THIS AGREEMENT, by and between City of Waterloo, Iowa hereinafter referred to as the "Client" and WHKS & Co., hereinafter referred to as "WHKS", is made as follows: WHEREAS, the Client has a need for certain professional services relating to the project described as East Shaulis Road and Hammond Avenue Roundabout. WHEREAS, WHKS proposes to furnish the professional services required by the Client for said project, NOW THEREFORE, the Client hereby agrees to retain and compensate WHKS to perform the professional services in accordance with the terms and conditions of this Agreement and the attached Standard Terms and Conditions. Scope of Services WHKS shall perform the following described services for the Client: Design engineering services as described on the attached Scope of Services included in Exhibit A. Basis of Compensation For the services described above, the Client shall remunerate WHKS as follows: Billed Hourly with a Not -to -Exceed Fee of $142,250 including expenses. Executed this 2nd City of Waterloo, Iowa By: Printed Name: Title: QuertEuz »anti day of October Quentin Hart Mayor , 2023 WHKS & co. By: Printed Name: Title: Steven Scott Sweet, P.E. Principal whks Exhibit A to Professional Services Agreement A. Project Description: The Project consists of the survey, design, and preparation of plans and specifications and bid letting services for street, fire hydrant relocation and storm sewer draining to open ditches for the construction of a roundabout at the intersection of East Shaulis Road and Hammond Avenue in Waterloo, Iowa. The Client will provide any available existing as -built plans, right-of-way information, pavement design and geotechnical engineering. The project is partly funded by an Iowa DOT Traffic Safety Improvement Grant and will be let by the City. The individual managing the project for WHKS who the point of contact will be and has authority to make decisions is S. Scott Sweet. The Project Manager who manages the project on the City's behalf is Mohammad Elahi. B. Scope of Services Provided Under This Agreement: 1. Project Management and Meetings • Meetings may be in -person or virtual • Perform general project administrative duties including supervision and coordination of the project team, review of project costs and billings, prepare invoices using Consultant's standard forms, preparation of status reports, and general administrative activities. • Hold kick-off meeting with Client to discuss the project and review the scope. • Attend three (3) review meetings for the project. • Attend one (1) council meeting for the project. • Advise the Client of the necessity of obtaining Special Engineering Services as described in Paragraph E., and act as the Client's representative in connection with any such services not actually performed by WHKS. 2. Topographic Survey and Research of Existing Conditions • Perform a site topographical survey for the project. • Establish project control. • Create a base map for the project. • Confirm and locate the existing underground utilities as located by the Iowa One Call locate system. • Collect, obtain and review relevant information from the Client. • Prepare (5) survey plats for right-of-way acquisitions. 3. Traffic Study • Prepare a traffic study for the intersection documenting the capacity and lane configuration. The report will include the following: • Traffic Analysis This task will include collecting turning movement counts and analyzing traffic counts. • Roundabout Capacity Analysis The AM and PM Peak hour traffic will be analyzed and capacity calculations shown for existing and projected conditions. This section will indicate performance and potential needs at the intersection. All supporting calculations shall be provided within the Appendix of the traffic study memorandum. The following scenarios will be analyzed in the report: Existing year 2023 Design year 2043 4. Preliminary and Final Design • This task includes the following items: • Roadway Design • Intersection Detail Design • Fire Hydrant Relocation • Storm Sewer System Design • Sidewalk Design • Paint Marking Design • Erosion Control Design 5. Plan Preparation • Prepare preliminary plans, check plans, and final plans and specifications to show the character and scope of work to be performed by contractors on the Project. Plans will follow City of Waterloo and SUDAS standards. The plans will include the following: A Sheets — Cover and General Notes (estimated at 2 sheets) B Sheets — Typical Sections (estimated at 4 sheets) C Sheets — Estimate of Quantities and Tabulations (estimated at 10 sheets) D Sheets — Mainline Plan and Profile (estimated at 2 sheets) E Sheets — Sideroad Plan and Profile (estimated at 2 sheets) G Sheets — Alignment and Control (estimated at 4 sheets) J Sheets — Traffic Control (estimated at 6 sheets) L Sheets — Intersection Detail (estimated at 6 sheets) M Sheets — Water and Storm Sewer (estimated at 6 sheets) P Sheets — Street Light Layout and Wiring (estimated at 1 sheet) R Sheets — Erosion Control (estimated at 1 sheet) S Sheets — Sidewalk Plan and Profile (estimated at 4 sheets) T Sheets — Earthwork Tabulation (estimated at 4 sheets) U Sheets — Detail Sheets (estimated at 6 sheets) W Sheets — Cross Sections (estimated at 8 sheets) 6. Final Plan Preparation and Bid Letting Services • Address comments on the plans and specifications. • Perform QA/QC on the plans. • Prepare opinion of probable construction cost on completed plans and specifications. • Furnish signed PDF copies of the plans, specifications, and other contract documents as required to the Client. • A Storm Water Pollution Prevention Plan (SWPPP) will be prepared. • Answer contractor's questions during the bidding phase. • Prepare addendums to the contract documents prior to bid letting, if necessary. C. Deliverables: • Submit preliminary, check and final plans and specifications to the Client for review. • Submit preliminary, check and final plans and specifications to the Iowa DOT for review. • Submit preliminary plans to Iowa DOT On -Call consultant for roundabout review. D. Special Considerations: • WHKS will determine streetlight pole locations and wiring. Client will provide specifications and standard drawings for street lights, and when necessary, streetlight technical and plan notes. • Client may reduce Scope of Work after consultations with WHKS due to budgetary constraint in a manner not to hinder WHKS's progress of work. • A reasonable project schedule and expected delivery date for contract documents by WHKS will be agreed upon at kickoff meeting and shall be considered part of this agreement. • Subject to WHKS approval, Client may modify the schedule to accommodate Client's fiscal budgetary plans. • Issuing progress payments by Client may take up to a month after receipt of an invoice from WHKS. • Invoicing will be once a month based on progress. Invoices will include a short description of the work that was performed for the invoice period. • Invoices shall show total amount to date, % budget invoiced, and approximate % work completed. • Iowa DOT review of plans may take several weeks which might cause a wait period during which period there might be no performable task to be conducted by WHKS. E. Special Engineering Services: Special Engineering Services are those services not listed above, but which may be required or advisable to accomplish the Project. Special Engineering Services shall be performed when authorized by the Client for additional fees, to be determined at the time authorized. Special Engineering Services include: 1. Land surveying and platting 2. Easement research, plats or descriptions 3. Negotiation for easements or land acquisition 4. Funding assistance, including grant and/or loan applications 5. Wetland Delineations or mitigation plans 6. Floodplain and hydraulic/hydrologic modeling 7. Permits other than those identified above 8. Geotechnical design/recommendations 9. Structural evaluation and/or design 10. Cultural resource survey or other studies or documentation that may be required by regulatory agencies that are not specifically listed in the scope of services 11. National Environmental Policy Act (NEPA) compliance, including historical and archeological investigations 12. Attendance at additional meetings (other than those listed above) 13. Construction phase engineering services, including construction administration, staking, construction observation, preparation of record drawings and project close-out service 14. Attendance at a City of Waterloo Council Worksession 15. Public Meeting Presentation 1. Scope of Services Client and WHKS have agreed to a list of services WHKS will provide to Client as listed on the Professional Services Agreement Form. 2. Governing Law The laws of the State of Iowa will govern this Agreement, its interpreta- tion and performance. Any litigation arising in any way from this Agreement shall be brought in the courts of that State. 3. Standard of Care Services provided by WHKS under this Agreement will be performed in a manner consistent with that degree of care and skill ordinarily exercised by members of the same profession currently practicing under similar circumstances and locality. 4. Integration This Agreement comprises the final and complete agreement between Client and WHKS. It supersedes all prior communications, representa- tions, or agreements, whether oral or written, relating to the subject matter of this Agreement. Execution of this Agreement signifies that each party has read the document thoroughly. Amendments to this Agreement shall not be binding unless made in writing and signed by both Client and WHKS. 5. Guarantees and Warranties WHKS shall not be required to sign any documents, no matter by whom requested, that would result in WHKS having to guarantee or warrant the existence of conditions whose existence WHKS cannot ascertain. Client also agrees not to STANDARD TERMS AND CONDITIONS FOR PUBLIC SECTOR PROJECTS make resolution of any dispute with WHKS or payment of any amount due to WHKS in any way contingent upon WHKS signing any such guarantee or warranty. 6. Indemnification WHKS agrees, to the extent permitted by law, to indemnify and hold Client harmless from any damage, liability or cost (including reasonable attorney's fees and costs of defense) to the extent caused by WHKS' negligent acts, errors or omissions in the performance of professional services under this Agreement and those of its subconsultants or anyone for whom WHKS is legally liable. Client agrees, to the extent permitted by law, to indemnify and hold WHKS harmless from any damage, liability or cost (including reasonable attorneys' fees and costs of defense) to the extent caused by Client's negligent acts, errors or omissions and those of Client's contractors, subcontractors or consultants or anyone for whom Client is legally liable. Neither WHKS nor Client shall be obligated to indemnify the other party in any manner whatsoever for the other party's own negligence. 7. Billing and Payment Provisions Invoices shall be submitted by WHKS monthly and are due upon presentation and shall be considered PAST DUE if not paid within thirty (30) calendar days of the invoice date. If payment is not received by WHKS within thirty (30) calendar days of the invoice date, Client shall pay as interest an additional charge of one whks engineers + planners + land surveyors and one -quarter percent (1.25%) of the PAST DUE amount per month. Payment thereafter shall first be applied to accrued interest and then to the unpaid principal. If Client fails to make payments within sixty (60) days from the date of an invoice or otherwise is in breach of this Agreement, WHKS may, at its option, suspend performance of services upon five (5) calendar days' notice to Client. WHKS shall have no liability whatsoever to Client for any costs or damages as a result of such suspension caused by any breach of this Agreement by Client. If Client fails to make payment to WHKS in accordance with the payment terms herein, this shall constitute a material breach of this Agreement and shall be cause for termination by WHKS. In the event legal action is necessary to enforce the payment provisions of this Agreement, WHKS shall be entitled to collect from Client any judgment or settlement sums due, reasonable attorneys' fees, court costs and expenses incurred by WHKS in connection therewith and, in addition, the reasonable value of WHKS personnel time and expenses spent in connection with such collection action, computed at WHKS current fee schedule and expense policies. Payment of invoices is in no case subject to unilateral discounting or set -offs by Client, and payment is due regardless of suspension or termination of this Agreement by either party. 8. Ownership of Records All reports, plans, specifications, field data and notes and other Page 1 of 4 documents, inclu on electronic m WHKS as ins are paid for and shall be the property of the Client, however shall remain the intellectual property Revision Agreed to by Sweet 9/13/2023 ing all documents dia, prepared by ments of service of WHKS. copics, including reproducible copics, of the plans and specifications for information and plans and spccifications shall not be used by Client or by othcrs on othcr similar projects except by agreement in writing by WHKS. 9. Delivery of Electronic Files In accepting and utilizing any drawings, reports and data on any form of electronic media generated and provided by WHKS, Client covenants and agrees that all such electronic files are instruments of service of WHKS, who shall be deemed the author, and who shall retain all rights under common and statutory laws, and other rights, including copyrights. Client is aware that differences may exist between the electronic files delivered and the respective construction documents due to addenda, change orders or other revisions. In the event of a conflict between the signed construction documents prepared by WHKS and electronic files, the signed construction documents shall govern. Client and WHKS agree that the electronic files prepared by WHKS shall conform to the current CADD software in use by WHKS or to other mutually agreeable CADD specifica- tions defined in the Agreement. Any changes to the CADD specifications by either Client or WHKS are subject to review and acceptance by the other party. Additional efforts by WHKS made necessary by a change to the CADD specifications or other software shall be compensated for as Additional Services. The electronic files provided by WHKS to Client are submitted for an acceptance period of 60 days. Any defects Client discovers during this period will be reported to WHKS and will be corrected as part of the Scope WHKS shall be permitted to retain copies, including reproducible copies of the plans and specifications. If the plans or specifications are used by the Client or by others without written permission from WHKS, then WHKS shall bear no responsibility for any adverse outcome arising from this use. Revision Agreed to by Sweet 9/13/2023 Services. Correction of defects detected and reported after the acceptance period will be compensated for as Additional Services. Client agrees not to reuse the electronic files, in whole or in part, for any purpose or project other than the project that is the subject of this Agreement. Client agrees not to transfer the electronic files to others without the prior written consent of WHKS, except as required by law. In addition, Client agrees, to the extent permitted by law, to indemnify and hold WHKS harmless from any damage, liability or cost, including reasonable attorney's fees and costs of defense, arising from any changes made by anyone other than WHKS or from any reuse of the electronic files without the prior written consent of WHKS. Under no circumstance shall delivery of the electronic files for use by Client be deemed a sale by WHKS and WHKS makes no warranties, either express or implied, of merchantability and fitness for any particular purpose. In no event shall WHKS be liable for any loss of profit or any consequential damages. 10. Changed Conditions Client shall rely on the judgment of WHKS as to the continued adequacy of this agreement in light of occurrences or discoveries that were not originally contemplated by or known to WHKS. Should WHKS call for contract renegotiation, WHKS shall identify the changed conditions necessitating renegotiation and WHKS and Client shall promptly and in good faith enter into renegotiation of this Agreement. If terms cannot be agreed to, the parties agree that either party has the absolute right to terminate this Agreement. 11. Permits and Approvals WHKS shall assist Client in applying for those permits and approvals typically required by law for projects similar to the one for which WHKS services are being engaged. This assistance consists of completing and submitting forms as to the results of certain work included in the Scope of Services. 12. Suspension of Services If the project is suspended for more than thirty (30) calendar days in the aggregate, WHKS shall be compensated for services performed and charges incurred prior to receipt of notice to suspend and, upon resumption, an equitable adjustment in fees to accommodate the resulting demobilization and remobilization costs. In addition, there shall be an equitable adjustment in the project schedule based on the delay caused by the suspension. If the project is suspended for more than ninety (90) calendar days in the aggregate, WHKS may, at its option, terminate this Agreement upon giving notice in writing to Client. 13. Termination Either Client or WHKS may terminate this Agreement at any time with or without cause upon giving the other party seven (7) calendar days prior written notice. Client shall within thirty (30) calendar days of termination pay WHKS for all services rendered and all costs incurred up to the date of termination, in accordance with the compensation provisions of the Agreement. 14. Unauthorized Changes In the event Client, Client's contractors or subcontractors or anyone for whom Client is legally liable makes or permits to be made any changes to any reports, plans, specifications or other contract documents prepared by WHKS without obtaining WHKS' prior written consent, Client shall assume full responsibility for the results of such changes. Therefore, Client agrees to waive any claim against WHKS and to release WHKS from any liability arising directly or indirectly from such changes. Client also agrees, to the extent permitted by laws, to indemnify and hold WHKS harmless from any Page 2 of 4 damage, liability or cost, including reasonable attorneys' fees and costs of defense, arising from such changes. 15. Jobsite Safety Neither the professional activities of WHKS nor the presence of WHKS or its employees and subconsultants at a construction site, shall relieve the General Contractor and any other entity of their obligations, duties and responsibilities including, but not limited to, construction means, methods, sequence, techniques or procedures necessary for performing, superintending or coordinating all portions of the construction work in accordance with the contract documents and any health or safety precautions required by any regulatory agencies. WHKS and its personnel have no authority to exercise any control over any construction contractor or other entity or their employees in connection with their work or any health or safety precautions. 16. Additional Services Services which are requested by Client or are required as part of the Project, but are not included in the Scope of Services, are considered Additional Services. WHKS will notify Client in writing when Additional Services will be needed. WHKS and Client will agree on the extent of the Additional Service(s) required and will agree on the method and amount of the compensation for performance of said agreed upon Additional Services. WHKS will not perform Additional Services which will result in additional cost to Client without documented verbal or written authority of Client. In the event WHKS is requested or required to participate in any dispute resolution procedure which involves any aspect of the Project, Client agrees to compensate WHKS for the reasonable value of WHKS' personnel time and expenses spent in connection with such procedures computed at WHKS' then current fee schedule and expense policies. 17. Dispute Resolution In an effort to resolve any conflicts that arise, Client and WHKS agree that all disputes between them arising out of or relating to this Agreement shall be submitted to nonbinding mediation unless the parties mutually agree otherwise. 18. Third Party Beneficiaries Nothing contained in this Agreement shall create a contractual relationship with or a cause of action in favor of a third party against either Client or WHKS. WHKS' services under this Agreement are being performed solely for Client's benefit, and no other entity shall have any claim against WHKS because of this Agreement or the performance or nonperformance of services hereunder. 19. Extension of Protection Client agrees to extend any and all liability limitations and indemnifications provided by Client to WHKS to those individuals and entities WHKS retains for performance of the services under this Agreement, including but not limited to WHKS officers and employees and their heirs and assigns, as well as WHKS subconsultants and their officers, employees, heirs and assigns. 20. Timeliness of Performance WHKS will perform the services described in the Scope of Services with due and reasonable diligence consistent with sound professional practices. 21. Delays WHKS is not responsible for delays caused by factors beyond WHKS' reasonable control, including but not limited to delays because of strikes, lockouts, work slowdowns or stoppages, accidents, acts of God, failure of any governmental or other regulatory authority to act in a timely manner, failure of Client to furnish timely information or approve or disapprove of WHKS' services or work product promptly, or delays caused by faulty performance by Client or by contractors of any level. When such delays beyond WHKS' reasonable control occur, Client agrees WHKS is not responsible for damages, nor shall WHKS be deemed to be in default of this Agreement. 22. Right to Retain Subconsultants WHKS may use the services of subconsultants when, in the sole opinion of WHKS, it is appropriate and customary to do so. Such persons and entities include, but are not limited to, aerial mapping specialists, geotechnical consultants and testing laboratories. WHKS' use of other consultants for additional services shall not be unreasonably restricted by Client provided WHKS notifies Client in advance. 23. Assignment Neither party to this Agreement shall transfer, sublet or assign any rights under or interest in this Agreement (including but not limited to monies that are due or monies that may be due) without the prior written consent of the other party. 24. Severability and Survival Any provision of this Agreement later held to be unenforceable for any reason shall be deemed void, and all remaining provisions shall continue in full force and effect. 25. Hazardous Materials It is acknowledged by both parties that WHKS' Scope of Services does not include any services related to asbestos or hazardous or toxic materials. In the event WHKS or any other party encounters asbestos or hazardous or toxic materials at the jobsite, or should it become known in any way that such materials may be present at the jobsite or any adjacent areas that may affect the performance of WHKS services, Page 3 of 4 WHKS may, at its option and without liability for consequential or any other damages, suspend performance of services on the project until Client retains appropriate specialist consultant(s) or contractor(s) to identify, abate and/or remove the asbestos or hazardous or toxic materials, and warrant that the jobsite is in full compliance with applicable laws and regulations. 26. Joint Participation The parties have participated jointly in the negotiation and preparation of all agreements between the parties. Each party has had an opportunity to obtain the advice of legal counsel and to review and comment upon this instrument. Accordingly, no rule of construction shall apply against any party or in favor of any party. This instrument shall be construed as if the parties jointly prepared it and any uncertainty or ambiguity shall not be interpreted against one party and in favor of another. 27. Record Documents If required in the Professional Services Agreement, WHKS shall, upon completion of the Work, compile for and deliver to the Client a reproducible set of Record Documents that are based upon the marked -up record drawings, addenda, change orders and other data furnished by the Contractor or other third parties. These Record Documents may show certain significant changes from the original design made during construction. Because these Record Documents are based on unverified information provided by other parties, which the Consultant is entitled to assume as reliable, the Consultant does not warrant their accuracy. Revised 02/23/07 Revised: 04/29/09 Page 4 of 4