Loading...
HomeMy WebLinkAboutPlumb Tech - Waterloo Center for the Arts - 11.20.2023Init. '��= DocumentAl0l® 2017 Standard Form of Agreement Between Owner and Contractor where the basis of payment is a Stipulated Sum AGREEMENT made as of the Twentieth day of November in the year Two Thousand Twenty -Three (In words, indicate day, month and year.) BETWEEN the Owner: (Name, legal status, address and other information) City of Waterloo 715 Mulberry Street, Waterloo, IA 50703 Telephone Number: 319-291-4323 and the Contractor: (Name, legal status, address and other information) Plumb Tech Inc. 3261 W Airline Hwy Waterloo, IA 50703 Telephone Number: 319-233-5616 for the following Project: (Name, location and detailed description) Waterloo Center of the Arts Chiller Replacement Waterloo, Iowa The project consists of replacing the air-cooled chiller serving the Waterloo Center For The Arts. There will be piping modifications as indicated in the drawings and specifications. The Architect: (Name, legal status, address and other it formation) MODUS Engineer ing 214 East 4th Street, Waterloo IA 50703 Telephone Number: 319-325-0650 The Owner and Contractor agree as follows. ADDITIONS AND DELETIONS: The author of this document has added information needed for its completion. The author may also have revised the text of the original AIA standard form. An Additions and Deletions Report that notes added information as well as revisions to the standard form text is available from the author and should be reviewed. A vertical line in the left margin of this document indicates where the author has added necessary Information and where the author has added to or deleted from the original AIA text. This document has important legal consequences. Consultation with an attorney is encouraged with respect to its completion or modification. The parties should complete A101®-2017, Exhibit A, Insurance and Bonds, contemporaneously with this Agreement. AIA Document A2010--2017, General Conditions of the Contract for Construction, is adopted In this document by reference. Do not use with other general conditions unless this document is modified. AIA Document A101 — 2017. Copyright ®1915, 1918, 1925, 1937, 1951, 1958, 1961, 1963, 1967, 1974, 1977, 1987, 1991, 1997, 2007 and 2017. All rights reserved. "The American Institute of Architects,' "American Institute of Architects," "AIA," the AIA Logo, and "AIA Contract Documents" are trademarks of The American Institute of Architects. This document was produced by AIA software at 12:55:27 ET on 12/06/2023 under Order No.2114398889 which expires on 01/07/2024, Is not for resale, Is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents° Terms of Service. To report copyright violations, a -mail docinfo@aiacontracts.com. User Notes: (3B9ADA50) TABLE OF ARTICLES 1 THE CONTRACT DOCUMENTS 2 THE WORK OF THIS CONTRACT 3 DATE OF COMMENCEMENT AND SUBSTANTIAL COMPLETION 4 CONTRACT SUM 5 PAYMENTS 6 DISPUTE RESOLUTION 7 TERMINATION OR SUSPENSION 8 MISCELLANEOUS PROVISIONS 9 ENUMERATION OF CONTRACT DOCUMENTS EXHIBIT A INSURANCE AND BONDS ARTICLE 1 THE CONTRACT DOCUMENTS The Contract Documents consist of this Agreement, Conditions of the Contract (General, Supplementary, and other Conditions), Drawings, Specifications, Addenda issued prior to execution of this Agreement, other documents listed in this Agreement, and Modifications issued after execution of this Agreement, all of which form the Contract, and are as fully a part of the Contract as if attached to this Agreement or repeated herein. The Contract represents the entire and integrated agreement between the parties hereto and supersedes prior negotiations, representations, or agreements, either written or oral. An enumeration of the Contract Documents, other than a Modification, appears in Article 9. ARTICLE 2 THE WORK OF THIS CONTRACT The Contractor shall fully execute the Work described in the Contract Documents, except as specifically indicated in the Contract Documents to be the responsibility of others. ARTICLE 3 DATE OF COMMENCEMENT AND SUBSTANTIAL COMPLETION § 3.1 The date of commencement of the Work shall be: (Check one of the following boxes.) [ X ] The date of this Agreement. [ ] A date set forth in a notice to proceed issued by the Owner. [ j Established as follows: (Insert a date or a means to determine the date of commencement of the Work.) If a date of commencement of the Work is not selected, then the date of commencement shall be the date of this Agreement. § 3.2 The Contract Time shall be measured from the date of commencement of the Work. § 3,3 Substantial Completion § 3,31 Subject to adjustments of the Contract Time as provided in the Contract Documents, the Contractor shall achieve Substantial Completion of the entire Work: Init. AIA Document A101 — 2017. Copyright@ 1915, 1918, 1925, 1937, 1951, 1958, 1961, 1983, 1987, 1974, 1977, 1987, 1991, 1997, 2007 and 2017. All rights reserved. 'The American Institute of Architects; 'American Institute of Architects,' AIA," the AIA Logo, and 'AIA Contract Documents' are trademarks of The American Institute of Architects. This document was produced at 12:55:27 ET on 12/00/2023 under Order No.2114398889 which expires on 01/07/2024, 1s not ( for resale, Is licensed for one-time use only, and may only be used In accordance with the AIA Contract Documentse Terms of Service. To report copyright violations, e-mail docinfo@alacontracts.com. User Notes: (3B9ADA50) Init. (Check one of the following boxes and complete the necessary information) [ ] Not later than ( ) calendar days from the date of commencement of the Work. [ X ] By the following date: November 5, 2024. § 3.3.2 Subject to adjustments of the Contract Time as provided in the Contract Documents, if portions of the Work are to be completed prior to Substantial Completion of the entire Work, the Contractor shall achieve Substantial Completion of such portions by the following dates: Portion of Work Substantial Completion Date § 3.3.3 If the Contractor fails to achieve Substantial Completion as provided in this Section 3.3, liquidated damages, if any, shall be assessed as set forth in Section 4.5. ARTICLE 4 CONTRACT SUM § 4.1 The Owner shall pay the Contractor the Contract Sum in eunent funds for the Contractor's performance of the Contract. The Contract Sum shall be Two Hundred Thirty-six Thousand Nine Hundred Fifty Dollars and Zero Cents ($ 236,950.00 ), subject to additions and deductions as provided in the Contract Documents. § 4.2 Alternates § 4.2,1 Alternates, if any, included in the Contract Sum: Item Price § 4,2,2 Subject to the conditions noted below, the following alternates may be accepted by the Owner following execution of this Agreement. Upon acceptance, the Owner shall issue a Modification to this Agreement. (Insert below each alternate and the conditions that must be met for she Owner to accept the alternate) Item § 4.3 Allowances, if any, included in the Contract Sum: (Identjr each allowance) Price Conditions for Acceptance Item Price General Allowance $10,000 § 4.4 Unit prices, if any: (Identify the item and state the unit price and quantity limitations, if any, to which the unit price will be applicable) Item Units and Limitations # Price per Unit ($0100) § 4,5 Liquidated damages, if any: (Insert terms and conditions for liquidated damages, if any.) § 4.6 Other: (Insert provisions for bonus or other incentives, if any, that might result in a change to the Contract San) AIA Document A101 —2017. Copydght ®1915, 1918, 1925, 1937, 1951, 1958, 1981, 1963, 1987, 1974, 1977, 1987, 1991, 1997, 2007 and 2017. AI rights reserved. 'The American Institute of Architects," °American Institute of Architects; "AIA, the AIA Logo, and "AIA Contract Documents' are trademarks of The American Institute of Architects. This document was produced at 12:55:27 ET on 12/06/2023 under Order No.2114398889 which expires on 01/07/2024, Is not for resale, Is licensed for one-time use only, and may only be used In accordance with the AIA Contract Documents° Terms of Service. To report copyright violations, a -mall doclnfo@alacontracls.com. User Notes: (3e9ADA50) ARTICLE 5 PAYMENTS § 5.1 Progress Payments § 5.1.1 Based upon Applications for Payment submitted to the Architect by the Contractor and Certificates for Payment issued by the Architect, the Owner shall make progress payments on account of the Contract Sum to the Contractor as provided below and elsewhere in the Contract Documents. § 5.1.2 The period covered by each Application for Payment shall be one calendar month ending on the last day of the month, or as follows: § 5.1.3 Provided that an Application for Payment is received by the Architect not later than the 15th day of a month, the Owner shall make payment of the amount certified to the Contractor not later than the 15th day of the following month, If an Application for Payment is received by the Architect after the application date fixed above, payment of the amount certified shall be made by the Owner not later than (30 ) days after the Architect receives the Application for Payment. (Federal, state or local laws may require payment within a certain period of time) § 5.1.4 Each Application for Payment shall be based on the most recent schedule of values submitted by the Contactor in accordance with the Contract Documents. The schedule of values shall allocate the entire Contract Sum among the various portions of the Work. The schedule of values shall be prepared in such form, and supported by such data to substantiate its accuracy, as the Architect may requite. This schedule of values shall be used as a basis for reviewing the Contractor's Applications for Payment. § 5.1.5 Applications for Payment shall show the percentage of completion of each portion of the Work as of the end of the period covered by the Application for Payment. § 5.1.6 In accordance with AIA Document A201T —2017, General Conditions of the Contract for Construction, and subject to other provisions of the Contract Documents, the amount of each progress payment shall be computed as follows: § 5.116.1 The amount of each progress payment shall first include: .1 That portion of the Contract Sum properly allocable to completed Work; .2 That portion of the Contract Sum properly allocable to materials and equipment delivered and suitably stored at the site for subsequent incorporation in the completed construction, or, if approved in advance by the Owner, suitably stored off the site at a location agreed upon in writing; and .3 That portion of Construction Change Directives that the Architect determines, in the Architect's professional judgment, to be reasonably justified. § 5.1.6.2 The amount of each progress payment shall then be reduced by: .1 The aggregate of any amounts previously paid by the Owner; .2 The amount, if any, for Work that retrains uncorrected and for which the Architect has previously withheld a Certificate for Payment as provided in Article 9 of AIA Document A201-2017; .3 Any amount for which the Contractor does not intend to pay a Subcontractor or material supplier, unless the Work has been performed by others the Contractor intends to pay; .4 For Work performed or defects discovered since the last payment application, any amount for which the Architect may withhold payment, or nullify a Certificate of Payment in whole or in part, as provided in Article 9 of AIA Document A201-2017; and .5 Retainage withheld pursuant to Section 5.1.7. § 5.1.7 Retainage § 5.1.7.1 For each progress payment made prior to Substantial Completion of the Work, the Owner may withhold the following amount, as retainage, from the payment otherwise due: (Insert a percentage or amount to be withheld as retainagefrom each Application for Payment. The amount of retainage may be limited by governing latv) 5% Init. AIA Document A101 — 2017. Copydght01915, 1916, 1925, 1937, 1951, 1958, 1961, 1963, 1967, 1979, 1977, 1987, 1991, 1997, 2007 and 2017. All rights reserved. 'The American Institute of Architects; 'American Institute of Architects, 'AIA; the AIA Logo, and 'AIA Contract Documents' are trademarks of The American Institute of Architects. This document was produced at 12:55:27 ET on 12/06/2023 under Order No.2114396689 which expires on 01/07/2029, is not / for resale, Is licensed forone-lime use only, and may only be used In accordance with the AIA Contract Documents®Terms of Service. To report copyright violations, a -mall doclnfo@alacontracls.com. User Notes: (3139ADA50) § 5.1.7.1.1 The following items are not subject to retainage: (Insert any items not subject to the withholding ofretainage, 'such as general conditions, insurance, etc.) § 5.1.7.2 Reduction or limitation of retainage, if any, shall be as follows: (If the retainage established in Section 5.1.7.1 is to be modified prior to Substantial Completion of the entire Work, including modifications for Substantial Completion gfportions of the Work as provided b1 Section 3.3.2, insert provisions for such modifications) § 5.1.7.3 Except as set forth in this Section 5.1.7.3, upon Substantial Completion of the Work, the Contractor may submit an Application for Payment that includes the retainage withheld from prior Applications for Payment pursuant to this Section 5.1.7. The Application for Payment submitted at Substantial Completion shall not include retainage as follows: (Insert any other conditions for release of retainage upon Substantial Completion) § 5.1.8 If final completion of the Work is materially delayed through no fault of the Contractor, the Owner shall pay the Contractor any additional amounts in accordance with Article 9 of AIA Document A201-2017. § 5.1.9 Except with the Owner's prior approval, the Contractor shall not make advance payments to suppliers for materials or equipment which have not been delivered and stored at the site. § 5.2 Final Payment § 5.2.1 Final payment, constituting the entire unpaid balance of the Contract Sum, shall be made by the Owner to the Contractor when .1 the Contractor has fully performed the Contract except for the Contractor's responsibility to correct Work as provided in Article 12 of AIA Document A201-2017, and to satisfy other requirements, if any, which extend beyond final payment; and .2 a final Certificate for Payment has been issued by the Architect. § 5.2.2 The Owner's final payment to the Contractor shall be made no later than 30 days after the issuance of the Architect's final Certificate for Payment, or as follows: § 5.3 Interest Payments due and unpaid under the Contract shall bear interest from the date payment is due at the rate stated below, or in the absence thereof, at the legal rate prevailing from time to time at the place where the Project is located. (Insert rate of interest agreed upon, if any) c� ARTICLE 6 DISPUTE RESOLUTION § 6.1 Initial Decision Maker The Architect will serve as the Initial Decision Maker pursuant to Article 15 of AIA Document A201-2017, unless the parties appoint below another individual, not a party to this Agreement, to serve as the Initial Decision Maker. Of the parties mutually agree, insert the name, address and other contact information of the Initial Decision Maker, if other than the Architect.) Init. AIA Document A101 — 2017. Copyright 01915, 1918, 1925, 1937, 1951, 1958, 1961, 1963, 1967, 1974, 1977, 1987, 1991, 1997, 2007 and 2017. All rights reserved. The American Institute of Architects; "American Institute or Architects; 'AIA; the AIA Logo, and "AIA Contract Documents' are trademarks of The American Institute of Architects. This document was produced at 12:55:27 ET on 12/06/2023 under Order No.2114398669 which expires on 01/07/2024, Is not / for resale, Is licensed for onetime use only, and may only be used in accordance with the AIA Contract Documentse Terms of Service. To report copyright violations, e-mail doclnfo@aiaconiracls.cam. User Notes: (3EOADA50) § 6.2 Binding Dispute Resolution For any Claim subject to, but not resolved by, mediation pursuant to Article 15 of AIA Document A201-2017, the method of binding dispute resolution shall be as follows: (Check the appropriate box.) [ ] Arbitration pursuant to Section 15.4 of AIA Document A201-2017 [ X ] Litigation in a court of competent jurisdiction [ ] Other (Specify) If the Owner and Contractor do not select a method of binding dispute resolution, or do not subsequently agree in writing to a binding dispute resolution method other than litigation, Claims will be resolved by litigation in a court of competent jurisdiction. ARTICLE 7 TERMINATION OR SUSPENSION § 7.1 The Contract may be terminated by the Owner or the Contractor as provided in Article 14 of AIA Document A201-2017. § 7.1.1 If the Contract is terminated for the Owner's convenience in accordance with Article 14 of AIA Document A201-2017, then the Owner shall pay the Contractor a termination fee as follows: (Inseri the amount of or method for determining, the fee, if any, payable to the Contactor following a termination for the Owner's convenience) § 7.2 The Work may be suspended by the Owner as provided in Article 14 of AIA Document A201-2017. ARTICLE 8 MISCELLANEOUS PROVISIONS § 8.1 Where reference is made in this Agreement to a provision of AIA Document A201-2017 or another Contract Document, the reference refers to that provision as amended or supplemented by other provisions of the Contract Documents. § 8.2 The Owner's representative: (Name, address, entail address, and other information) Greg Ahlhelm 715 Mulberry Street, Waterloo, IA 50703 Telephone Number: 319-291-4323 § 8.3 The Contractor's representative: (Nance, address, email address, and other information) Plumb Tech Inc. 3261 W Airline Hwy Waterloo, IA 50703 Telephone Number: 319-233-5616 Init. AIA Document A101 — 2017. Copyright @ 1915,1918, 1925, 1937, 1951, 1958, 1961, 1983, 1987, 1974, 1977, 1907, 1991, 1997, 2007 and 2017. All rights reserved, "The American Institute of Architects," "American Institute of Architects; °AIA; the AIA Logo, and "AIA Contract Documents" are trademarks of The American Institute of Architects. Thls document was produced al 12:55:27 ET on 12/08/2023 under Order No.2114398889 which expires on 01/07/2024, Is not 1 for resale, is licensed for one-time use only, and may only be used In accordance with the AIA Contract Documents° Terms of Service. To report copyright violations, a -mall docInfo(jalacontracts.com. User Notes: (3B9ADA50) Init. § 8.4 Neither the Owner's nor the Contractor's representative shall be changed without ten days' prior notice to the other party. § 8.5 Insurance and Bonds § 8.5.1 The Owner and the Contractor shall purchase and maintain insurance as set forth in AIA Document AIOITM- 2017, Standard Form of Agreement Between Owner and Contractor where the basis of payment is a Stipulated Sum, Exhibit A, Insurance and Bonds, and elsewhere in the Contract Documents. § 8.5.2 The Contractor shall provide bonds as set forth in MA Document AI OITM-2017 Exhibit A, and elsewhere in the Contract Documents. § 8.6 Notice in electronic format, pursuant to Article I of AIA Document A201-2017, may be given in accordance with AIA Document E203TM-2013, Building Information Modeling and Digital Data Exhibit, if completed, or as otherwise set forth below: (If other than in accordance with AIA Document E203-2013, insert requirements for delivering notice in electronic format such as name, title, and email address of the recipient and whether and how the system will be required to generate a read receipt for the transmission.) § 8.7 Other provisions: ARTICLE 9 ENUMERATION OF CONTRACT DOCUMENTS § 9.1 This Agreement is comprised of the following documents: .1 AIA Document A101TM-2017, Standard Form of Agreement Between Owner and Contractor 2 AIA Document A101T -2017, Exhibit A, Insurance and Bonds .3 AIA Document A201T^t 2017, General Conditions of the Contract for Construction .4 AIA Document E203Th'-2013, Building Information Modeling and Digital Data Exhibit, dated as indicated below: (Insert the date of the E203-20I3 incorporated into this Agreement) .5 Drawings Number MEl M2 E2 .6 Specifications Section See attached document .7 Addenda, Wally: Number Addendum #I Title MEPT Symbols List Mechanical Plan Electrical Plan Title Date 11/6/2023 Date 11/6/2023 11/6/2023 11/6/2023 Date Pages 5 Pages Pages Portions of Addenda relating to bidding or proposal requirements are not part of the Contract Documents unless the bidding or proposal requirements are also enumerated in this Article 9. .8 Other Exhibits: AIA Document A101— 2017. Copyright 01915, 1918, 1925, 1937, 1951, 1958, 1961, 1963, 1967, 1974, 1977, 1987, 1991, 1997, 2007 and 2017. All rights reserved. 'The American Institute of Archilects; "American Institute of Architects, "AIA; the AIA Logo, and 'AIA Contract Documents' are trademarks of The American Institute of Architects. Thls document was produced at 12:55:27 ET on 12/06/2023 under Order No.2114398889 which expires on 01/07/2024, Is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents°Terms of Service. To report copyright violations, a -mall doclnfo@a alaconiracts.com. User Notes: (3B9ADA50) Init, (Check all boxes that apply and include appropriate information ideni f ,ing the exhibit where required,) [ ] AIA Document E204T"I 2017, Sustainable Projects Exhibit, dated as indicated below: (Insert the date of the E204-2017 incorporated into this Agreement.) [ ] The Sustainability Plan: Title Date Pages [ ] Supplementaty and other Conditions of the Contract: Document Title Date Pages .9 Other documents, if any, listed below: (List here any additional documents that are intended to form part of the Contract Documents. AMA Document A201T64--2017 provides that the advertisement or invitation to bid, Instructions to Bidders, sample forms, the Contractor's bid or proposal, portions ofAddenda relating to bidding or proposal requirements, and other information fru'nished by the Owner in anticipation of receiving bids or proposals, are not part of the Contract Documents unless enumerated in this Agreement. Any such documents should be listed here only if intended to be part of the Contract Documents) This Agreement entered into as of the day and year first written above, QCCertan J 4r OWNER (Signature) Quentin M. Hart, City of Waterloo - Mayor CONTRACTOR (Signature) Zach 13ehrends President (Printed name and title) (Printed name and title) AIA Document A101 — 2017. Copyright all 1915, 1918, 1925, 1937, 1951, 1958, 1961, 1963, 1967, 1974, 1977, 1987, 1991, 1987, 2007 and 2017. All rights reserved, "The American Institute of Architects, "American Institute of Architects," "AIA," the NA Logo, and "AIA Contract Documents" are trademarks of The American Institute of Architects. Thls document was produced at 12:55:27 ET on 12/0812023 under Order No.2114398889 which expires on 01/07/2024, Is not for resale, Is licensed for one-time use only, and may only be used in accordance with the AIA Contract Documents® Terms of Service. To report copyright violations, a -mall doclnfo@alacontracts.com. User Notes: (3139ADA50) TABLE OF CONTENTS NOTICE OF PUBLIC HEARING 2 NOTICE TO BIBBERS 4 GENERAL SPECIFICATIONS FOR CONSTRUCTION 22 DIVISION 00 - PROCUREMENT AND CONTRACTING REQUIREMENTS 00 2115 FORM OF PROPOSAL 2 DIVISION 23 - HEATING, VENTILATING, AND AIR-CONDITIONING (HVAC) 23 0050 BASIC HVAC REQUIREMENTS 6 23 0090 MINOR HVAC DEMOLITION FOR REMODELING 2 23 0519 METERS AND GAUGES FOR HVAC PIPING 3 23 0529 HANGERS AND SUPPORTS FOR HVAC PIPING AND 3 EQUIPMENT 23 0548 VIBRATION AND SEISMIC CONTROLS FOR HVAC PIPING AND 2 EQUIPMENT 23 0553 IDENTIFICATION FOR HVAC PIPING AND EQUIPMENT 1 23 0593 TESTING, ADJUSTING, AND BALANCING FOR HVAC 3 23 0719 HVAC PIPING INSULATION 4 23 0913 DDC INSTRUMENTS AND CONTROL DEVICES FOR HVAC 5 23 0993 SEQUENCE OF OPERATION 7 23 2113 HYDRONIC PIPING 6 23 2133 HYDRONIC SPECIALTIES 3 23 2500 CLEANING AND TREATMENT OF HYDRONIC SYSTEMS 4 23 6400 AIR COOLED SCROLL WATER CHILLERS 7 DIVISION 26 - ELECTRICAL 26 0050 BASIC ELECTRICAL REQUIREMENTS 5 26 0090 MINOR ELECTRICAL DEMOLITION FOR REMODELING 2 26 0519 ELECTRICAL POWER CONDUCTORS AND CABLES 3 26 0529 HANGERS AND SUPPORTS FOR ELECTRICAL SYSTEMS 2 26 0533 RACEWAY AND BOXES FOR ELECTRICAL SYSTEMS 4 26 0553 IDENTIFICATION FOR ELECTRICAL SYSTEMS 1 262726 WIRING DEVICES 2 Waterloo Center for the Arts Chiller Replacement -1 TABLE OF CONTENTS MERCHANTS BONDING COMPANY, MERCHANTS BONDING COMPANY (MUTUAL) P.O. BOX 14498, DES MOINES, IA 50306-3498 PHONE: (800) 678-8171 FAX: (515) 243-3854 Performance Bond CONTRACTOR: (Name, legal status and address) Plumb Tech Inc. 3261 W Airline Hwy Waterloo, IA 50703 OWNER: (Name, legal status and address) City of Waterloo, IA 715 Mulberry Street Waterloo, IA 50703 CONSTRUCTION CONTRACT Date: November 20, 2023 Amount: $236,950.00 Description: (Name and location) Waterloo Center for the Arts Chiller Replacement BOND Date: November 20, 2023 (Not earlier than Construction Contract Date) Amount: $236,950.00 Modifications to this Bond: ❑ None ❑ See Section 16 CONTRACTOR AS PRINCIPAL Company: (Corporate Seal) Plumb Tech, Inc. p Signature: / EJ'^- Name 2ctc het rc1 aebrer,d, and Title: Preslc/-enf (Any additional signatures appear on the last page of this Pe (FOR INFORMATION ONLY— Name, address and telephone) AGENT or BROKER: The Accel Group LLC 301 Oak Ridge Circle Waverly, IA 50677 319-365-8611 Bond No. 100298031 SURETY: (Name, legal status and principal place of business) Merchants Bonding Company (Mutual) 6700 Westown Parkway, West Des Moines, IA 50266 This document has important legal consequences. Consultation with an attorney Is encouraged with respect to its completion or modification. Any singular reference to Contractor, Surety, Owner or other party shall be considered plural where applicable. This document combines two separate bonds, a Performance Bond and a Payment Bond, Into one form. This is not a single combined Performance and Payment Bond. SURETY Company: (Corporate Seal) Merchants Bonding Company (Mutual) Signatur/ A kn.? on Frerichs and Title: Attorney -In Fact rformance Bond) OWNER'S REPRESENTATIVE: (Architect, Engineer or other party) MODUS Engineering 214 East 4th St Waterloo, Iowa 50703 Printed in cooperation with American Institute of Architects (AIA). The language in this document conforms exactly to the language used in AIA Document A312-Performance Bond-2010 edition. 1 CON 0656 (2/15) § 1 The Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner for the performance of the Construction Contract, which is incorporated herein by reference. § 2 If the Contractor performs the Construction Contract, the Surety and the Contractor shall have no obligation under this Bond, except when applicable to participate in a conference as provided in Section 3. § 3 If there is no Owner Default under the Construction Contract, the Surety's obiligation under this Bond shall arise after . l the Owner first provides notice to the Contractor and the Surety that the Owner is considering declaring a Contractor Default. Such notice shall indicate whether the Owner is requesting a conference among the Owner, Contractor and Surety to discuss the Contractor's performance. If the Owner does not request a conference, the Surety may, within five (5) business days after receipt of Owner's notice, request such a conference. If the Surety timely requests a conference, the Owner shall attend. Unless the Owner agrees otherwise, any conference requested under this Section 3.1 shall be held within ten (10) business days of the Surety's receipt of the Owner's notice. If the Owner, the Contractor and the Surety agree, the Contractor shall be allowed a reasonable time to perform the Construction Contract, but such an agreement shall not waive the Owner's right, if any, subsequently to declare a Contractor Default; .2 the Owner declares a Contractor Default, terminates the Construction Contract and notifies the Surety; and . 3 the Owner has agreed to pay the Balance of the Contract Price in accordance with the terms of the Construction Contract to the Surety or to a contractor selected to perform the Construction Contract. § 4 Failure on the part of the Owner to comply with the notice requirement in Section 3.1 shall not constitute a failure to comply with a condition precedent to the Surety's obligations, or release the Surety from its obligations, except to the extent the Surety demonstrates actual prejudice. § 5 When the Owner has satisfied the conditions of Section 3. the Surety shall promptly and at the Surety's expense take one of the following actions: § 5.1 Arrange for the Contractor, with the consent of the Owner, to perform and complete the Construction Contract: § 5 2 Undertake to perform and complete the Construction Contract itself through its agents or independent contractors: § 5.3 Obtain bids or negotiated proposals from qualified contractors acceptable to the Owner for a contract for performance and completion of the Construction Contract, arrange for a contract to be prepared for execution by the Owner and a contractor selected with the Owner's concurrence, to be secured with performance and payment bonds executed by a qualified surety equivalent to the bonds issued on the Construction Contract, and pay to the Owner the amount of damages as described in Section 7 in excess of the Balance of the Contract Price incurred by the Owner as a result of the Contractor Default; or § 5.4 Waive its right to perform and complete, arrange for completion, or obtain a new contractor and with reasonable promptness under the circumstances: .1 After investigation, determine the amount for which it may be liable to the Owner and, as soon as practicable after the amount is determined, make payment to the Owner; or . 2 Deny liability in whole or in part and notify the Owner, citing the reasons for denial. § 6 If the Surety does not proceed as provided in Section 5 with reasonable promptness, the Surety shall be deemed to be in default on this Bond seven days after receipt of an additional written notice from the Owner to the Surety demanding that the Surety perform its obligations under this Bond, and the Owner shall be entitled to enforce any remedy available to the Owner. If the Surety proceeds as provided in Section 5.4 and the Owner refuses the payment or the Surety has denied liability, in whole or in part, without further notice the Owner shall be entitled to enforce any remedy available to the Owner. CON 0656 (2/15) § 7 If the Surety elects to act under Section 5.1, 5.2, or 5.3, then the responsibilities of the Surety to the Owner shall not be greater than those of the Contractor under the Construction Contract, and the responsibilities of the Owner to the Surety shall not be greater than those of the Owner under the Construction Contract. Subject to the commitment by the Owner to pay the Balance of the Contract Price, the Surety is obligated, without duplication, for .1 the responsibilities of the Contractor for correction of defective work and completion of the Construction Contract: .2 additional legal, design professional and delay costs resulting from the Contractor's Default, and resulting from the actions or failure to act of the Surety under Section 5: and .3 liquidated damages, or if no liquidated damages are specified in the Construction Contract, actual damages caused by delayed performance or non-performance of the Contractor. § 8 If the Surety elects to act under Section 5.1, 5.3 or 5.4, the Surety's liability is limited to the amount of this Bond. § 9 The Surety shall not be liable to the Owner or others for obligations of the Contractor that are unrelated to the Construction Contract, and the Balance of the Contract Price shall not be reduced or set off on account of any such unrelated obligations. No right of action shall accrue on this Bond to any person or entity other than the Owner or its heirs, executors, administrators, successors and assigns. § 10 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders and other obligations. § 11 Any proceeding, legal or equitable, under this Bond may be instituted in any court of competent Jurisdiction in the location in which the work or part of the work is located and shall be instituted within two years after a declaration of Contractor Default or within two years after the Contractor ceased working or within two years after the Surety refuses or fails to perform its obligations under this Bond, whichever occurs first. If the provisions of this Paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in the Jurisdiction of the suit shall be applicable. § 12 Notice to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears. § 13 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefinm and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so furnished, the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. § 14 Definitions § 14.1 Balance of the Contract Price. The total amount payable by the Owner to the Contractor under the Construction Contract after all proper adjustments have been made, including allowance to the Contractor of any amounts received or to be received by the Owner in settlement of insurance or other claims for damages to which the Contractor is entitled, reduced by all valid and proper payments made to or on behalf of the Contractor under the Construction Contract. § 14.2 Construction Contract. The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and changes made to the agreement and the Contract Documents. § 14.3 Contractor Default. Failure of the Contractor, which has not been remedied or waived, to perform or otherwise to comply with a material term of the Construction Contract. § 14.4 Owner Default. Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. § 14.5 Contract Documents. All the documents that comprise the agreement between the Owner and Contractor. § 15 If this Bond is issued for an agreement between a Contractor and subcontractor, the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. CON 0656 (2/15) § 16 Modifications to this bond are as follows: (Space is provided below for additional signatures of added parties, other than those appearing on the cover page) CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) l y �, ^ Signature: r Signatu U C Name and Title: Name and Title: Address: Address: CON 0656 (2/15) MERCHANTS BONDING COMPANY,. MERCHANTS BONDING COMPANY (MUTUAL) P.O. BOX 14498 DES MOINES, IA 50306-3498 PHONE: (800) 678-8171 FAX: (515) 243-3854 Payment Bond CONTRACTOR: (Name, legal status and address) Plumb Tech, Inc. 3261 W Airline Hwy Waterloo, IA 50703 OWNER: (Nance, legal status and address) City of Waterloo, IA 715 Mulberry Street Waterloo, IA 50703 CONSTRUCTION CONTRACT Date: November 20, 2023 Amount: $236,950.00 Description: (Name and location) Waterloo Center for the Arts Chiller Replacement BOND Date: November 20, 2023 (Not earlier than Construction Contact Date) Amount: $236,950.00 Modifications to this Bond: ❑ None 0 See Section 18 CONTRACTOR AS PRINCIPAL Company: (Corporate Seal) Plumb Tech, Inc. Signature: i Name ZaJi4ry rcncs and Title: Prrsic-leni - Bond No. 100298031 SURETY: (Name, legal status and principal place of business) Merchants Bonding Company (Mutual) 6700 Westown Parkway, West Des Moines, IA 50266 This document has Important legal consequences. Consultation with an attorney Is encouraged with respect to Its completion or modification. Any singular reference to Contractor, Surety, Owner or other party shall be considered plural where applicable. This document combines two separate bonds, a Performance Bond and a Payment Bond, into one form. This is not a single combined Performance and Payment Bond. SURETY Company: (Corporate Seal) Merchants Bonding Company (Mutual) Signatult:4 ,t /' p per`( Name Lori A'Frerichs and Title: Attor iey-In-Fact (Any additional signatures appear on the last page of this Payment Bond.) (FOR INFORMATION ONLY— Name, address and telephone) AGENT or BROKER: The Accel Group LLC 301 Oak Ridge Circle Waverly, IA 50677 319-365-8611 OWNER'S REPRESENTATIVE: (Architect, Engineer or other party) MODUS Engineering 214 East 4th St Waterloo, Iowa 50703 Printed in cooperation with American Institute of Architects (AIA). The language in this document conforms exactly to the language used in AIA Document A312-Payment Bond-2010 edition. 5 CON 0656 (2/15) § 1 The Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner to pay for labor, materials, and equipment furnished for use in the performance of the Construction Contract, which is incorporated herein by reference, subject to the following terms. § 2 If the Contractor promptly makes payment of all sums due to Claimants, and defends, indemnifies, and holds harmless the Owner from claims, demands, liens or suits by any person or entity seeking payment for labor, materials or equipment furnished for use in the performance of the Construction Contract, then the Surety and the Contractor shall have no obligation under this Bond. § 3 If there is no Owner Default under the Construction Contract, the Surety's obligation to the Owner under this Bond shall arise after the Owner has promptly notified the Contractor and the Surety (at the address described in Section 13) of claims, demands, liens or suits against the Owner or the Owner's property by any person or entity seeking payment for labor, materials or equipment furnished for use in the performance of the Construction Contract and tendered defense of such claims, demands, liens or suits to the Contractor and the Surety. § 4 When the Owner has satisfied the conditions in Section 3., the Surety shall promptly and at the Surety's expense defend, indemnify and hold harmless the Owner against a duly tendered claim, demand, lien or suit. § 5 The Surety's obligations to a Claimant under this Bond shall arise after the following: § 5.1 Claimants, who do not have a direct contract with the Contractor, .1 have furnished a written notice of non-payment to the Contractor, stating with substantial accuracy the amount claimed and the name of the party to whom the materials were, or equipment was, furnished or supplied or for whom the labor was done or performed, within ninety (90) days after having last performed labor or last furnished materials or equipment included in the Claim; and .2 have sent a Claim to the Surety (at the address described in Section 13). § 5.2 Claimants, who are employed by or have a direct contract with the Contractor, have sent a Claim to the Surety (at the address described in Section 13). § 6 If a notice of non-payment required by Section 5.1.1 is given by the Owner to the Contractor, that is sufficient to satisfy a Claimants obligation to furnish a written notice of non-payment under Section 5.1.1. § 7 When a Claimant has satisfied the conditions of Sections 5.1 or 5.2, whichever is applicable, the Surety shall promptly and at the Surety's expense take the following actions: § 7.1 Send an answer to the Claimant, with a copy to the Owner, within sixty (60) days after receipt of the Claim, stating the amounts that are undisputed and the basis for challenging any amounts that are disputed: and § 7.2 Pay or arrange for payment of any undisputed amounts. § 7.3 The Surety's failure to discharge its obligations under Section 7.1 or Section 7.2 shall not be deemed to constitute a waiver of defenses the Surety or Contractor may have or acquire as to a Claim, except as to undisputed amounts for which the Surety and Claimant have reached agreement. If, however, the Surety fails to discharge its obligations under Section 7.1 or Section 7.2, the Surety shall indemnify the Claimant for the reasonable attorney's fees the Claimant incurs thereafter to recover any sums found to be due and owing to the Claimant. § 8 The Surety's total obligation shall not exceed the amount of this Bond, plus the amount of reasonable attorney's fees provided under Section 7.3, and the amount of this Bond shall be credited for any payments made in good faith by the Surety. § 9 Amounts owed by the Owner to the Contractor under the Construction Contract shall be used for the performance of the Construction Contract and to satisfy claims, if any, under any construction performance bond. By the Contractor furnishing and the Owner accepting this Bond, they agree that all funds earned by the Contractor in the performance of the Construction Contract are dedicated to satisfy obligations of the Contractor and Surety under this Bond, subject to the Owner's priority to use the funds for the completion of the work. CON 0656 (2/15) § 10 The Surety shall not be liable to the Owner, Claimants or others for obligations of the Contractor that are unrelated to the Construction Contract. The Owner shall not be liable for the payment of any costs or expenses of any Claimant under this Bond, and shall have under this Bond no obligation to make payments to, or give notice on behalf of Claimants or otherwise have any obligations to Claimants under this Bond. § 11 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders and other obligations. § 12 No suit or action shall be commenced by a Claimant under this Bond other than in a court of competent jurisdiction in the state in which the project that is the subject of the Construction Contract is located or after the expiration of' one year from the date (1) on which the Claimant sent a Claim to the Surety pursuant to Section 5.1.2 or 5.2. or (2) on which the last labor or service was performed by anyone or the last materials or equipment were furnished by anyone under the Construction Contract, whichever of (I) or (2) first occurs. If the provisions of this Paragraph are void or prohibited by law, the minimum period of' limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. § 13 Notice and Claims to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears. Actual receipt of notice or Claims, however accomplished, shall be sufficient compliance as of the date received. § 14 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so furnished, the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. § 15 Upon request by any person or entity appearing to be a potential beneficiary of this Bond, the Contractor and Owner shall promptly furnish a copy of this Bond or shall permit a copy to be made. § 16 Definitions § 16.1 Claim. A written statement by the Claimant including at a minimum: .1 the name of the Claimant; .2 the name of the person for whom the labor was done, or materials or equipment furnished; .3 a copy of the agreement or purchase order pursuant to which labor, materials or equipment was furnished for use in the performance of the Construction Contract: .4 a brief description of the labor, materials or equipment furnished: .5 the date on which the Claimant last performed labor or last furnished materials or equipment for use in the performance of the Construction Contract: .6 the total amount earned by the Claimant for labor, materials or equipment furnished as of the date of the Claim: .7 the total amount of previous payments received by the Claimant; and .8 the total amount due and unpaid to the Claimant for labor, materials or equipment furnished as of the date of the Claim. § 16.2 Claimant. An individual or entity having a direct contract with the Contractor or with a subcontractor of the Contractor to furnish labor, materials or equipment for use in the performance of the Construction Contract. The term Claimant also includes any individual or entity that has rightfully asserted a claim under an applicable mechanic's lien or similar statute against the real property upon which the Project is located. The intent of this Bond shall be to include without limitation in the terms "labor, materials or equipment" that part of water, gas, power, light, heat, oil. gasoline, telephone service or rental equipment used in the Construction Contract, architectural and engineering services required for performance of the work of the Contractor and the Contractor's subcontractors, and all other items for which a mechanic's lien may be asserted in the jurisdiction where the labor, materials or equipment were furnished. § 16.3 Construction Contract. The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and all changes made to the agreement and the Contract Documents. CON 0656 (2/15) § 16.4 Owner Default. Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract. § 16.5 Contract Documents. All the documents that comprise the agreement between the Owner and Contractor. § 17 If this Bond is issued for an agreement between a Contractor and subcontractor, the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. § 18 Modifications to this bond are as follows: (Space is provided below for additional signatures of added parties, other than those appearing on the cover page) CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) Signature: Signature Name and Title: Name and Titl Address: Address: CON 0656 (2/15) MERCHAN:1" BONDING COMPANYTA POWER OF ATTORNEY Know All Persons By These Presents, that MERCHANTS BONDING COMPANY (MUTUAL) and MERCHANTS NATIONAL BONDING, INC., both being corporations of the State of Iowa, dlb/a Merchants National Indemnity Company (in California only) (herein collectively called the "Companies") do hereby make, constitute and appoint, Individually, Lori A Frerichs their true and lawful Attorney(s)-in-Fact, to sign its name as surety(ies) and to execute, seal and acknowledge any and all bonds, undertakings, contracts and other written Instruments in the nature thereof, on behalf of the Companies in their business of guaranteeing the fidelity of persons, guaranteeing the performance of contracts and executing or guaranteeing bonds and undertakings required or permitted In any actions or proceedings allowed by law. This Power -of -Attorney is granted and Is signed and sealed by facsimile under and by authority of the following By -Laws adopted by the Board of Directors of Merchants Bonding Company (Mutual) on April 23, 2011 and amended August 14, 2015 and adopted by the Board of Directors of Merchants National Bonding, Inc., on October 16, 2015. "The President, Secretary, Treasurer, or any Assistant Treasurer or any Assistant Secretary or any Vice President shall have power and authority to appoint Attorneys -in -Fact, and to authorize them to execute on behalf of the Company, and attach the seal of the Company thereto, bonds and undertakings, recognizances, contracts of indemnity and other writings obligatory in the nature thereof." 'The signature of any authorized officer and the seal of the Company may be affixed by facsimile or electronic transmission to any Power of Attorney or Certification thereof authorizing the execution and delivery of any bond, undertaking, recognizance, or other suretyship obligations of the Company, and such signature and seal when so used shall have the same force and effect as though manually fixed.' In connection with obligations In favor of the Florida Department of Transportation only, it is agreed that the power and aut hority hereby given to the Attorney -In -Fact Includes any and all consents for the release of retained percentages and/or final estimates on engineering and construction contracts required by the State of Florida Department of Transportation. It is fully understood that consenting to the State of Florida Department of Transportation making payment of the final estimate to the Contractor and/or Its assignee, shall not relieve this surety company of any of its obligations under its bond. In connection with obligations In favor of the Kentucky Department of Highways only, it is agreed that the power and authority hereby given to the Attorney -In -Fact cannot be modified or revoked unless prior written personal notice of such Intent has been given to the Commissioner - Department of Highways of the Commonwealth of Kentucky at least thirty (30) days prior to the modification or revocation. In Witness Whereof, the Companies have caused this Instrument to be signed and sealed this 7th day of December 2023 • • .a. Ff1 e.• .• Ci .\\ O �4jo.• 0 v':• 2003 ,4, .4. 1933 d•e.. :'.F ';may• do STATE OF IOWA " COUNTY OF DALLAS ss. MERCHANTS BONDING COMPANY (MUTUAL) MERCHANTS NATIONAL BONDING, INC. dlbla MERCHANTS NATIONAL INDEMNITY COMPANY By On this 7th day of December 2023 , before me appeared Larry Taylor, to me personally known, who being by me duly sworn did say that he is President of MERCHANTS BONDING COMPANY (MUTUAL) and MERCHANTS NATIONAL BONDING, INC.; and that the seals affixed to the foregoing instrument are the Corporate Seals of the Companies; and that the said instrument was signed and sealed In behalf of the Companies by authority of their respective Boards of Directors. Kim Lee Commission Number 702737 My Commission Expires April 14, 2024 Wary Public (Expiratio of notary's commission does not invalidate this instrument) I, William Warner, Jr., Secretary of MERCHANTS BONDING COMPANY (MUTUAL) and MERCHANTS NATIONAL BONDING, INC., do hereby certify that the above and foregoing is a true and correct copy of the POWER -OF -ATTORNEY executed by said Companies, which Is still In full force and effect and has not been amended or revoked. In Witness Whereof, I have hereunto set my hand and affixed the seal of the Companies on this 20th day of November 2023 . P�,0N . . 2• 03 u R9ro?0, ' 2003 ;0.0 j ;d. :ate: POA 0018 (10/22) Secretary PLUMTEC-01 LFRERICHS '4cL Rif) CERTIFICATE OF LIABILITY INSURANCE �� DATE(MM/DD/YYYY) 12/11 /2023 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER The Accel Group LLC 301 Oak Ridge Circle Waverly, IA 50677 CONTACT NAME: PHONE (A/c, No, Ext): (319) 352-2880 FAX No): (319) 365-6919 ADDRESS: certs@acceladvantage.com INSURER(S) AFFORDING COVERAGE NAIC # INSURER A: United Fire & Casualty Ins Co 13021 INSURED Plumb Tech Inc. 3261 W. Airline Hwy. Waterloo, IA 50703 INSURER B : INSURER C : INSURER D : INSURER E : INSURER F : COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLIC ES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR LTR TYPE OF INSURANCE ADDL INSD SUBR W VD POLICY NUMBER POLICY EFF (MM/DD/YYYY) POLICY EXP (MM/DD/YYYY) LIMITS A X COMMERCIAL GENERAL LIABILITY X 60056082 4/27/2023 4/27/2024 EACH OCCURRENCE $ 1,000,000 CLAIMS -MADE X OCCUR DAMAGISES(RENTEDoccurrence) PREMES (Ea $ 100,000 MED EXP (Any one person) $ 5,000 PERSONAL & ADV INJURY $ 1,000,000 GEN'L X AGGREGATE LIMIT APPLIES PRO- PER: GENERAL AGGREGATE $ 2,000,000 PRODUCTS - COMP/OP AGG 2,000,000LOC $ 2,000,000 $ A AUTOMOBILE X LIABILITY ANY AUTO OWNED SCHEDULED AUTOS NON-OWNEDUUO 60056082 4/27/2023 4/27/2024 COMBINED SINGLE LIMIT (Ea accident) $ 1,000,000 BODILY INJURY (Per person) $ BODILY INJURY (Per accident) $ PROPERTY a E accident) DAMAGE $ $ A X UMBRELLA LIAB EXCESS LIAB X OCCUR CLAIMS -MADE 60056082 4/27/2023 4/27/2024 EACH OCCURRENCE $ 5,000,000 AGGREGATE $ 5,000,000 DED RETENTION $ $ A WORKERS COMPENSATION AND EMPLOYERS' LIABILITY ANY PROPRIETOR/PARTNER/EXECUTIVE OFFICER/MEMBER EXCLUDED? (Mandatory in NH) If yes, describe under DESCRIPTION OF OPERATIONS below Y / N N / A 30302711 4/27/2023 4/27/2024 X PER STATUTE OTH- ER E.L. EACH ACCIDENT $ 1,000,000 E.L. DISEASE - EA EMPLOYEE $ 1,000,000 E.L. DISEASE - POLICY LIMIT $ 1,000,000 DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached if more space is required) Arts Chiller Replacement Project CERTIFICATE HOLDER CANCELLATION Cityof Waterloo 715 Mulberry St. Waterloo, IA 50703 SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. AUTHORIZED REPRESENTATIVE aat, . ACORD 25 (2016/03) © 1988-2015 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD