Loading...
HomeMy WebLinkAboutMarcelino Bailon Perez - (RECORDED) Dev Agmnt - 3.18.2024 2024-17111 • RECORDED:07/10/2024 03:53:34 PM RECORDING FEE:$82.00 REVENUE TAX:$ COMBINED FEE:$82.00 SANDIE L.SMITH,RECORDER BLACK HAWK COUNTY,IOWA C 4 cS l.tj evt i'(o Threparer: Christopher S.Wendland, P.O. Box 596, Waterloo, Iowa 50704 (319)234-5701 After recording, return to Community Planning&Development, 715 Mulberry Street, Waterloo, IA 50703. DEVELOPMENT AGREEMENT This Development Agreement (the "Agreement") is entered into as of iv\Ae_r_,A 18 , 2024, by and between Marcelino Bailon Perez ("Developer"), and the City of Waterloo, Iowa ("City"). RECITALS A. Developer is willing and able to finance and rehabilitate an existing property located at 215 Locust Street, Waterloo, Iowa (the "Property"), legally described as set forth on Exhibit "A" attached hereto. B. City considers development within the City a benefit to the community and is willing for the overall good and welfare of the community to provide financial incentives so as to encourage that goal. City believes that rehabilitation of the Property is in the best interests of the City and in accordance with the public purposes and provisions of the applicable State and local laws and requirements under which the project has been undertaken and is being assisted. AGREEMENT NOW, THEREFORE, in consideration of the mutual covenants set forth herein, the parties agree as follows: 1. Sale of Property; Title. Subject to the terms hereof, City shall sell the Property to Developer on contract (the "Contract") for the sum of$5,000.00 (the "Purchase Price"). Other terms of sale shall be as set forth in the Contract, the form of which is attached hereto as Exhibit "B." 2. Improvements by Developer. Developer acknowledges that it has had a reasonable opportunity to inspect the Property and to conduct other due diligence related to the Project. Developer agrees to accept the Property in its "AS IS" condition, without any warranty from City, expressed or implied, as to the condition of the Property, its marketability, or its fitness for any particular purpose. At its own cost Developer shall (a) remove and properly dispose of all debris and unwanted personal property from the dwelling, (b) renovate the existing structure to a finished state for single-family residential purposes, and (c) make other improvements to the buildings and grounds, including but not limited to sidewalk, and shall be responsible for removal of all construction debris, proper leveling or shaping of groundscape, and grassing and/or landscaping (construction and finishing as so described are referred to collectively as the "Improvements"). The Improvements shall be constructed in accordance with the terms of this Agreement, all applicable City, state, and federal building codes and shall comply with all applicable City ordinances and other applicable law. Developer shall submit specific plans, building designs and site plans for City review and approval before the commencement of construction and shall not substantially deviate from such plans, specifications or designs. Developer will use its best efforts to obtain, or cause to be obtained, in a timely manner, all required permits, licenses and approvals, and will meet, in a timely manner, all requirements of all applicable local, state, and federal laws and regulations which must be obtained or met before the Improvements may be lawfully constructed. The Property, the Improvements, and all other work to make the project site usable for Developer's purposes as contemplated by this Agreement are collectively referred to as the "Project." 3. Timeliness of Construction; Possibility of Contract Forfeiture. The parties agree that Developer's commitment to cause the Project to be undertaken and to renovate the Property and complete the Improvements in a timely manner constitutes a material inducement for the City to sell the Property to Developer and to extend the incentives provided for in this Agreement, and that without said commitment City would not do so. A. Deadlines to commence and complete. Subject to Unavoidable Delays (defined below), Developer must obtain a building permit and begin renovation of the dwelling within four (4) months after Contract execution (the "Start Date") and must Substantially Complete rehabilitation within fourteen (14) months after Contract execution (the "Completion Deadline"). For purposes of this Agreement, "Substantially Complete" means the date on which the Improvements have been completed to the extent necessary for the City to issue a certificate of occupancy relating thereto and the City has verified that Project elements for which no permit was necessary have been Substantially Completed. All deadlines are subject to Unavoidable Delays as defined in paragraph B below. The City's Community Planning and Development Director may, but shall not be required to, consent to an extension of time of up to six (6) months for construction of the Improvements. Any additional or longer time extensions will require consent of the City Council. B. Events triggering termination and/or Contract forfeiture. If Developer does not begin or Substantially Complete construction of the Improvements on the schedule(s) stated above, subject to Unavoidable Delays, 2 then City may terminate this Agreement as set forth in Section 12, and City shall then have no further obligation to Developer under this Agreement. If development has commenced within the required period, as the same may be extended, and is subsequently stopped or delayed as a result of an act of God, war, civil disturbance, court order, labor dispute, fire, or other cause beyond the reasonable control of Developer (each an "Unavoidable Delay"), the requirement that construction be completed by the Completion Deadline shall be tolled for a period of time equal to the period of Unavoidable Delay. As promptly as possible, Developer shall notify City in writing of the occurrence of any Unavoidable Delay and shall again notify City in writing when the Unavoidable Delay has ended. If City terminates this Agreement as provided in Section 12, City shall have no further obligations to Developer under this Agreement, including but not limited to any legal or equitable obligation to reimburse Developer for any costs expended by Developer with respect to the Project or to compensate Developer for any value added to the Property by any Improvements. In connection with termination of the Agreement as set forth herein, City may forfeit the Contract in addition to exercising any other available remedies. 4. Utilities. Developer will be responsible for obtaining or extending water, sewer, telephone, telecommunications, electricity, gas and other utility services from street right of way to any location on the Property and for payment of any associated connection fees and costs of usage after the Contract date. 5. City Incentives. To aid the Project, City agrees to provide the following assistance: A. Partial Purchase Price Refund. Within thirty (30) days after Developer has Substantially Completed the Improvements and has obtained final inspection on all permits obtained for the Project, City will refund the Purchase Price to Developer. B. Grant. Concurrently with refund of the Purchase Price pursuant to paragraph A above, City will make a $5,000.00 infill housing incentive grant to Developer. 6. No Encumbrances; Limited Exception. Until the Improvements are Substantially Completed, Developer agrees that it shall not create, incur, or suffer to exist any Liens on the Property, other than such mortgage or mortgages as may be reasonably necessary to finance Developer's completion of the Improvements and of which Developer notifies City before Developer executes any such mortgage. Developer may not mortgage the Property or any part thereof for any purpose except in connection with financing of the Improvements. Any other mortgage shall be void. 7. No Assignment or Conveyance. Developer agrees that it will not sell, convey, assign or otherwise transfer its interest in the Contract or the Property prior to 3 completion of the Project, whether in whole or in part, to any other person or entity without the prior written consent of City. Reasonable grounds for the City to withhold its consent shall include but are not limited to the inability of the proposed transferee to demonstrate to the City's satisfaction that it has the financial ability to observe all of the terms to be performed by Developer under this Agreement. 8. Additional Covenants of Developer. In addition to the other promises, covenants and agreements of Developer as provided elsewhere in this Agreement, Developer agrees as follows: A. Until the Improvements have been Substantially Completed, Developer shall make such reports to City, in such detail and at such times as may be reasonably requested by City, as to the actual progress of Developer with respect to construction of the Improvements. B. Developer will comply with all applicable land development laws and City and county ordinances, and all laws, rules and regulations relating to its businesses, other than laws, rules and regulations where the failure to comply with the same, or where the sanctions and penalties resulting therefrom, would not have a material adverse effect on the business, property, operations, or condition, financial or otherwise, of Developer. C. Developer will cooperate fully with the City in resolution of any traffic, parking, trash removal or public safety problems which may arise in connection with the construction and operation of the Improvements. 9. Representations and Warranties of City. City hereby represents and warrants as follows: A. City is not prohibited from consummating the transaction contemplated in this Agreement by any law, regulation, agreement, instrument, restriction, order or judgment. B. Each person who executes and delivers this Agreement and all documents to be delivered hereunder is and shall be authorized to do so on behalf of City. 10. Representations and Warranties of Developer. Developer hereby represents and warrants as follows: A. It has all requisite power and authority to own and operate its properties, to carry on its business as now conducted and as presently proposed to be conducted, and to enter into and perform its obligations under this Agreement. 4 B. This Agreement has been duly and validly authorized, executed and delivered by Developer and, assuming due authorization, execution and delivery by the other parties hereto, is in full force and effect and is a valid and legally binding instrument of Developer that is enforceable in accordance with its terms, except as the same may be limited by bankruptcy, insolvency, reorganization or other laws relating to or affecting creditors' rights generally. C. The execution and delivery of this Agreement, the consummation of the transactions contemplated hereby, and the fulfillment of or compliance with the terms and conditions of this Agreement are not prevented by, limited by, in conflict with, or result in a violation or breach of, any contractual restriction, evidence of indebtedness, agreement or instrument of whatever nature to which Developer is now a party or by which it or its property is bound, nor do they constitute a default under any of the foregoing. D. There are no actions, suits or proceedings pending or threatened against or affecting Developer in any court or before any arbitrator or before or by any governmental body in which there is a reasonable possibility of an adverse decision which could materially adversely affect the business (present or prospective) or financial position of Developer or which in any manner raises any questions affecting the validity of the Agreement or Developer's ability to perform its obligations under this Agreement. 11. Default. The following shall be "Events of Default" under this Agreement, and the term "Event of Default" shall mean any one or more of the following events that continues beyond any applicable cure periods: A. Failure by Developer to cause the Improvements to be commenced and completed pursuant to the terms, conditions and limitations of this Agreement; B. Transfer by Developer of any interest (either directly or indirectly) in the Improvements, the Property, or this Agreement, without the prior written consent of City, except as expressly authorized by this Agreement; C. Failure by any party hereto to substantially observe or perform any covenant, condition, obligation or agreement on its part to be observed or performed under this Agreement; D. Any representation or warranty made by Developer in this Agreement, or made by Developer in any written statement or certificate furnished by Developer pursuant to this Agreement, shall prove to have been incorrect, incomplete or misleading in any material respect on or as of the date of the issuance or making thereof; 5 E. Developer (1) files any petition in bankruptcy or for any reorganization, arrangement, composition, readjustment, liquidation, dissolution, or similar relief under the federal bankruptcy law or any similar state law; (2) makes an assignment for the benefit of its creditors; (3) admits in writing its inability to pay its debts generally as they become due; (4) is adjudicated a bankrupt or insolvent; or if a petition or answer proposing the adjudication of Developer as a bankrupt or its reorganization under any present or future federal bankruptcy act or any similar federal or state law shall be filed in any court and such petition or answer shall not be discharged or denied within ninety (90) days after the filing thereof; or a receiver, trustee or liquidator of Developer, or part thereof, shall be appointed in any proceedings brought against Developer and shall not be discharged within ninety (90) days after such appointment, or if Developer shall consent to or acquiesce in such appointment; or (5) defaults under any mortgage applicable to the Property; or F. Any representation or warranty made by Developer in this Agreement, or made by Developer in any written statement or certificate furnished by Developer pursuant to this Agreement, shall prove to have been incorrect, incomplete or misleading in any material respect on or as of the date of the issuance or making thereof. 12. Remedies. A. Default by Developer. Whenever any Event of Default in respect of Developer occurs and is continuing, the City may terminate this Agreement. Before exercising such remedy, City shall give 30 days' written notice to Developer of the Event of Default, provided that by the conclusion of such period the Event of Default shall not have been cured, or the Event of Default cannot reasonably be cured within 30 days and Developer shall not have provided assurances reasonably satisfactory to the City that the Event of Default will be cured as soon as reasonably possible. Upon termination, City may exercise any and all remedies available at law, equity, contract or otherwise to recover ownership of the Property as set forth in this Agreement. B. Default by City. Whenever any Event of Default in respect of City occurs and is continuing, Developer may take such action against City to require it to specifically perform its obligations hereunder. Before exercising such remedy, Developer shall give 30 days' written notice to City of the Event of Default, provided that by the conclusion of such period the Event of Default shall not have been cured, or if the Event of Default cannot reasonably be cured within 30 days and City shall not have provided assurances reasonably satisfactory to the Developer that the Event of Default will be cured as soon as reasonably possible. C. Remedies under this Agreement shall be cumulative and in addition to any other right or remedy given under this Agreement or existing at law or in 6 equity or by statute. Waiver as to any particular default, or delay or omission in exercising any right or power accruing upon any default, shall not be construed as a waiver of any other or any subsequent default and shall not impair any such right or power. 13. Indemnification and Releases. A. Developer hereby releases City, its elected officials, officers, employees, and agents (collectively, the "indemnified parties") from, covenants and agrees that the indemnified parties shall not be liable for, and agrees to indemnify, defend and hold harmless the indemnified parties against, any loss or damage to property or any injury to or death of any person occurring at or about the Property arising after the Contract date or resulting from any defect in the Improvements. The indemnified parties shall not be liable for any damage or injury to the persons or property of Developer or its employees, contractors or agents, or any other person who may be on or about the Property or the Improvements, due to any act of negligence or willful misconduct of any person, other than any act of negligence or willful misconduct on the part of any such indemnified party or its officers, employees or agents. B. Except for any willful misrepresentation, any willful misconduct, or any unlawful act of the indemnified parties, Developer agrees to protect and defend the indemnified parties, now or forever, and further agrees to hold the indemnified parties harmless, from any claim, demand, suit, action or other proceedings or any type or nature whatsoever, by any person or entity whatsoever that arises or purportedly arises from (1) any violation of any agreement or condition of this Agreement (except with respect to any suit, action, demand or other proceeding brought by Developer against the City to enforce its rights under this Agreement), or (2) the acquisition and condition of the Property and the construction, installation, ownership, and operation of the Improvements, or (3) otherwise as a result of or in connection with the Project or Developer's failure to carry on or complete same. C. The indemnification obligations under this Section shall include attorneys' fees and expenses incurred by any indemnified party. The provisions of this Section shall survive the expiration or termination of this Agreement. 14. Materiality of Developer's Promises, Covenants, Representations, and Warranties. Each and every promise, covenant, representation, and warranty set forth in this Agreement on the part of Developer to be performed is a material term of this Agreement, and each and every such promise, covenant, representation, and warranty constitutes a material inducement for City to enter this Agreement. Developer acknowledges that without such promises, covenants, representations, and warranties, City would not have entered this Agreement. Upon breach of any promise or covenant, or in the event of the incorrectness or falsity of any representation or warranty, City 7 may, at its sole option and in addition to any other right or remedy available to it, terminate this Agreement and declare it null and void. 15. Performance by City. Developer acknowledges and agrees that all of the obligations of City under this Agreement shall be subject to, and performed by City in accordance with, all applicable statutory, common law or constitutional provisions and procedures consistent with City's lawful authority. All covenants, stipulations, promises, agreements and obligations of City contained in this Agreement shall be deemed to be the covenants, stipulations, promises, agreements and obligations of City and not of any governing body member, officer, employee or agent of City in the individual capacity of such person. 16. No Third-Party Beneficiaries. No rights or privileges of any party hereto shall inure to the benefit of any contractor, subcontractor, material supplier, or any other person or entity, and no such contractor, subcontractor, material supplier, or other person or entity shall be deemed to be a third-party beneficiary of any of the provisions of this Agreement. 17. Notices. Any notice under this Agreement shall be in writing and shall be delivered in person, by overnight air courier service, by United States registered or certified mail, postage prepaid, or by facsimile (with an additional copy delivered by one of the foregoing means), and addressed: (a) if to City, at 715 Mulberry Street, Waterloo, Iowa 50703, fax number 319-291-4571, Attention: Mayor, with copies to the City Attorney and the Community Planning and Development Director. (b) if to Developer, at 22325 Mapes Road, Perris, California 92570. Delivery of notice shall be deemed to occur (i) on the date of delivery when delivered in person, (ii) one (1) business day following deposit for overnight delivery to an overnight air courier service which guarantees next day delivery, (iii) four (4) business days following the date of deposit if mailed by United States registered or certified mail, postage prepaid, or (iv) when transmitted by facsimile so long as the sender obtains written electronic confirmation from the sending facsimile machine that such transmission was successful. A party may change the address for giving notice by any method set forth in this Section. 18. No Joint Venture. Nothing in this Agreement shall, or shall be deemed or construed to, create or constitute any joint venture, partnership, agency, employment, or any other relationship between the City and Developer nor to create any liability for one party with respect to the liabilities or obligations of the other party or any other person. 19. Amendment, Modification, and Waiver. No amendment, modification, or waiver of any condition, provision, or term of this Agreement shall be valid or of any effect unless made in writing, signed by the party or parties to be bound or by the duly 8 authorized representative of same, and specifying with particularity the extent and nature of the amendment, modification, or waiver. Any waiver by any party of any default by another party shall not affect or impair any rights arising from any subsequent default. 20. Severability; Reformation. Each provision, section, sentence, clause, phrase, and word of this Agreement is intended to be severable. If any portion of this Agreement shall be deemed invalid or unenforceable, whether in whole or in part, the offending provision or part thereof shall be deemed severed from this Agreement and the remaining provisions of this Agreement shall not be affected thereby and shall continue in full force and effect. If, for any reason, a court finds that any portion of this Agreement is invalid or unenforceable as written, but that by limiting such provision or portion thereof it would become valid and enforceable, then such provision or portion thereof shall be deemed to be written, and shall be construed and enforced, as so limited. 21. Interpretation. This Agreement shall not be construed more strictly against one party than against the other merely by virtue of the fact that it may have been prepared by counsel for one of the parties, it being recognized that the parties hereto and their respective attorneys have contributed substantially and materially to the preparation of each and every provision of this Agreement. 22. Captions. All captions, headings, or titles in the paragraphs or sections of this Agreement are inserted only as a matter of convenience and/or reference, and they shall in no way be construed as limiting, extending, or describing either the scope or intent of this Agreement or of any provisions hereof. 23. Binding Effect. This Agreement shall be binding and shall inure to the benefit of the parties and their respective successors, assigns, and legal representatives. 24. Counterparts. This Agreement may be executed in one or more counterparts, each of which, including signed counterparts delivered by facsimile or other electronic means, shall be deemed an original and all of which, taken together, shall constitute one and the same instrument. 25. Entire Agreement. This Agreement, together with the exhibits attached hereto, constitutes the entire agreement of the parties and supersedes all prior or contemporaneous negotiations, discussions, understandings, or agreements, whether oral or written, with respect to the subject matter hereof. 26. Time of Essence. Time is of the essence of this Agreement. IN WITNESS WHEREOF, the parties have executed this Development Agreement by their duly authorized representatives as of the date first set forth above. 9 CITY OF WATERLOO, IOWA DEVE OP By: IP • Quentin Hart, Mayor Marcell 7, Ba",i1 Perez dkini‘ Attest: Kelley Fel le, City Clerk 10 EXHIBIT "A" Property Description The Southeasterly 38 feet of Lots 8 and 9 in Block 9 in "Whitney's Subdivision" in Waterloo, Iowa. EXHIBIT "B" Form of Contract See attached. Prepared by: Christopher S.Wendland, P.O. Box 596, Waterloo, IA, 50704. 319-234-5701 Taxpayer address: Marcelino Bailon Perez; 22325 Mapes Road, Perris, CA 92570 REAL ESTATE CONTRACT This Real Estate Contract (the "Contract"), made and entered into as of , 2024, by and between City of Waterloo, Iowa ("Seller") and Marcelino Bailon Perez ("Buyer"): WITNESSETH, that the Seller sells to the Buyer and the Buyer purchases the following described real estate (the "Property") situated in Black Hawk County, State of Iowa, to-wit: The Southeasterly 38 feet of Lots 8 and 9 in Block 9 in "Whitney's Subdivision" in Waterloo, Iowa. SUBJECT TO (a) easements, servitudes, conditions and restrictions of record; (b) current and future real estate real property taxes and assessments subject to the agreements made herein; (c) general utility and right-of-way easements serving the Property; and (d) restrictions imposed by the City zoning ordinances and other applicable law. INCLUDED in this sale, if located in or on the Property and if owned by Seller, are all equipment, machinery, fixtures, trade fixtures, and all other fixtures not hereinafter specifically reserved by Seller in writing. 1. THE TOTAL PURCHASE PRICE for the Property is Five Thousand and 00/100 Dollars ($5,000.00), payable to Seller at the address designated by Seller from time to time, as follows: (a) Four Thousand Nine Hundred Ninety-Nine Dollars ($4,999.00) upon execution of this Contract. (b) The balance of the purchase price will be due and payable in full on or before August 1, 2025. 2. POSSESSION is to be given Buyer on the date of execution of this Contract by both parties. Seller represents that there are no other parties currently in possession. 3. TAXES AND ASSESSMENTS. The Property is currently exempt from property taxes. Buyer will pay all future general property taxes and special assessments prior to becoming delinquent. 4. INSURANCE. From and after delivery of possession, Buyer shall provide fire and extended coverage insurance on said premises at least equal to $30,000 in a company acceptable to Seller, all policies to protect the interest of both parties hereto as their interests may appear. Buyer shall promptly provide to Seller a certificate of insurance naming Seller as an additional insured. 5. RENTS. Intentionally omitted. 6. TITLE. At the time of final payment hereunder, the Seller shall convey the Property to the Buyer by QUIT CLAIM DEED. Buyer shall be responsible, at its sole cost and expense, to obtain whatever evidence of title that it desires. 7. CARE OF PROPERTY. No improvements placed upon the Property, or now thereon, shall be removed or destroyed until final payment is made, nor shall the Buyer commit waste of the Property. Buyer shall be solely responsible, without claim or recourse to Seller, for any repairs, maintenance, or upkeep that may be necessary in connection with their occupancy and for all costs of utilities and other services to the Property. 8. ADVANCEMENT BY SELLER. If Buyer fails to pay such taxes, special assessments, or insurance as above agreed, Seller may, but need not, pay such taxes, special assessments, insurance, and all sums so expended shall be due and payable on demand; or such sums so expended may, at the election of Seller, be added to the principal amount due hereunder and bear interest until paid at the highest legal rate allowable or 12% per annum, whichever is less, compounded monthly. 9. JOINT TENANCY PRESERVED. Intentionally omitted. 10. ADDITIONAL TERMS. The parties further agree as follows: (a) Seller does not make, and has not made, any representation or warranty concerning the Property or its condition or fitness for use for any particular purpose. The Property is sold to Buyer"AS IS." (b) Buyer may not sell, transfer or assign its interest in this Contract without the prior written consent of Seller. (c) Property is subject to the terms of a certain Development Agreement between the parties. (e) Included in the sale and purchase at no additional consideration are all equipment, fixtures, inventory and other personal property of any type or nature that is located in or upon the Property, all of which are sold to Buyer"AS IS." (f) Buyer acknowledges that it has had a full and fair opportunity to enter upon and inspect the Property and/or to have the Property inspected by contractors of its own choosing. 11. TIME IS OF THE ESSENCE of this Contract. Failure promptly to assert rights of Seller hereunder shall not, however, be a waiver of such rights or a waiver of any existing or subsequent default. 12. DEFAULT. If the Buyer fails to perform any of the terms of this Contract,the Seller may forfeit this Contract as provided by Iowa law governing the forfeiture of real estate contracts, and if this Contract is forfeited, Buyer shall thereafter be considered as a tenant holding over after termination of a lease. Upon completion of such forfeiture, all sums previously paid Seller hereunder and all improvements placed on the Property by Buyer shall become the absolute property of Seller as liquidated damages for the breach of this Contract and as rent for the premises. In the event of compliance with the terms of the notice of forfeiture of this Contract, Buyer shall pay the cost of serving said notice. 13. ACCELERATION. If Buyer fails for thirty days to perform any one or more of the terms of this Contract, the Seller may, without further notice, declare the entire amount of the balance unpaid hereunder immediately due and payable; and thereafter, at the option of the Seller, this Contract may be foreclosed and a receiver may be appointed to take charge of said premises and collect the rents and profits therefrom to be applied as may be directed by the Court, and Buyer agrees to pay reasonable attorney fees therefor. 14. PERSONAL PROPERTY. If this Contract includes the sale of any personal property, then in the event of the forfeiture or foreclosure of this Contract, the personalty shall be considered indivisible from the real estate above described; and any such termination of Buyer's rights in said real estate shall concurrently operate as the forfeiture or foreclosure hereof against all such personal property. 15. MORTGAGE BY SELLER. Intentionally omitted. 16. CERTIFICATION. Buyer and Seller each certify that they are not acting, directly or indirectly, for or on behalf of any person, group, entity or nation named by any Executive Order or the United States Treasury Department as a terrorist, "Specially Designated National and Blocked Person" or any other banned or blocked person, entity, nation or transaction pursuant to any law, order, rule or regulation that is enforced or administered by the Office of Foreign Assets Control; and are not engaged in this transaction, directly or indirectly on behalf of, any such person, group, entity or nation. Each party hereby agrees to defend, indemnify and hold harmless the other party from and against any and all claims, damages, losses, risks, liabilities and expenses (including attorney's fees and costs) arising from or related to my breach of the foregoing certification. 17. BUYER'S RIGHTS UNDER ENCUMBRANCE. Seller shall pay all interest and principal on all encumbrance of the Property created or suffered by Seller when the same become due, and in the event of a failure 2 on Seller's part to make any such payment before it becomes delinquent, Buyer may pay the same and receive credit hereon for the amount so paid. If Buyer is acquiring the Property from an equity holder, rather than from a titleholder, or in event there is a mortgage against the Property, then, in either of those events, Buyer hereby reserves the right, if reasonably necessary for his protection, to split the payments pro rata among the interested payees. 18. GENERAL TERMS; CONSTRUCTION. This Contract shall be binding upon the heirs, personal representatives, successors and assigns of the respective parties hereto. It represents the entire agreement of the parties and may not be amended without the express written consent of both parties. The singular masculine gender is used to refer to the parties in this Contract. Such terms shall be construed to include the feminine and neuter genders and the plural number, if applicable. 19. COUNTERPARTS. This Contract may be executed in any number of counterparts, all of which, taken together, shall constitute one and the same instrument. SELLER BUYER City of Waterloo, Iowa By: Quentin Hart, Mayor Marcelino Bailon Perez Attest: Kelley Felchle, City Clerk STATE OF IOWA ) ss. BLACK HAWK COUNTY ) On this day of , 2024, before me, a Notary Public in and for the State of Iowa, personally appeared Quentin Hart and Kelley Felchle, to me personally known, who being duly sworn, did say that they are the Mayor and City Clerk, respectively, of the City of Waterloo, Iowa, a municipal corporation, created and existing under the laws of the State of Iowa, and that the seal affixed to the foregoing instrument is the seal of said municipal corporation, and that said instrument was signed and sealed on behalf of said municipal corporation by authority and resolution of its City Council, and said Mayor and City Clerk acknowledged said instrument to be the free act and deed of said municipal corporation by it and by them voluntarily executed. Notary Public [acknowledgments continue on next page] 3 STATE OF CALIFORNIA ) ) ss. COUNTY ) This record was acknowledged before me on , 2024, by Marcelino Bailon Perez. Notary Public 4 Preparer: Christopher S.Wendland. P.O. Box 596,Waterloo, Iowa 50704 (319)234-5701 After recording, return to Community Planning&Development, 715 Mulberry Street, Waterloo, IA 50703. DEVELOPMENT AGREEMENT This Development Agreement (the "Agreement") is entered into as of Moan Is , 202jby and between Marcelino Bailon Perez ("Developer"), and the City of Waterloo, Iowa ("City"). RECITALS A. Developer is willing and able to finance and rehabilitate an existing property located at 215 Locust Street, Waterloo, Iowa (the "Property"), legally described as set forth on Exhibit "A" attached hereto. B. City considers development within the City a benefit to the community and is willing for the overall good and welfare of the community to provide financial incentives so as to encourage that goal. City believes that rehabilitation of the Property is in the best interests of the City and in accordance with the public purposes and provisions of the applicable State and local laws and requirements under which the project has been undertaken and is being assisted. AGREEMENT NOW, THEREFORE, in consideration of the mutual covenants set forth herein, the parties agree as follows: 1. Sale of Property; Title. Subject to the terms hereof, City shall sell the Property to Developer on contract (the "Contract") for the sum of $5,000.00 (the "Purchase Price"). Other terms of sale shall be as set forth in the Contract, the form of which is attached hereto as Exhibit "B." 2. Improvements by Developer. Developer acknowledges that it has had a reasonable opportunity to inspect the Property and to conduct other due diligence related to the Project. Developer agrees to accept the Property in its "AS IS" condition, without any warranty from City, expressed or implied, as to the condition of the Property, its marketability, or its fitness for any particular purpose. At its own cost Developer shall (a) remove and properly dispose of all debris and unwanted personal property from the dwelling, (b) renovate the existing structure to a finished state for single-family residential purposes, and (c) make other improvements to the buildings and grounds, including but not limited to sidewalk, and shall be responsible for removal of all construction debris, proper leveling or shaping of groundscape, and grassing and/or landscaping (construction and finishing as so described are referred to collectively as the "Improvements"). The Improvements shall be constructed in accordance with the terms of this Agreement, all applicable City, state, and federal building codes and shall comply with all applicable City ordinances and other applicable law. Developer shall submit specific plans, building designs and site plans for City review and approval before the commencement of construction and shall not substantially deviate from such plans, specifications or designs. Developer will use its best efforts to obtain, or cause to be obtained, in a timely manner, all required permits, licenses and approvals, and will meet, in a timely manner, all requirements of ail applicable local, state, and federal laws and regulations which must be before the Improvements may be lawfully constructed. The Property, the Improvements, and all other work to make the project site usable for Developer's purposes as contemplated by this Agreement are collectively referred to as the "Project." 3. Timeliness of Construction; Possibility of Contract Forfeiture. The parties agree that Developer's commitment to cause the Project to be undertaken and to renovate the Property and complete the Improvements in a timely manner constitutes a material inducement for the City to sell the Property to Developer and to extend the incentives provided for in this Agreement, and that without said commitment City would not do so. A. Deadlines to commence and complete. Subject to Unavoidable Delays (defined below), Developer must obtain a building permit and begin renovation of the dwelling within four(4) months after Contract execution (the "Start Date") and must Substantially Complete rehabilitation within fourteen (14) months after Contract execution (the "Completion Deadline"). For purposes of this Agreement, "Substantially Complete" means the date on which the Improvements have been completed to the extent necessary for the City to issue a certificate of occupancy relating thereto and the City has verified that Project elements for which no permit was necessary have been Substantially Completed. All deadlines are subject to Unavoidable Delays as defined in paragraph B below. The City's Community Planning and Development Director may, but shah not be required to, consent to an extension of time of up to six (6) months for construction of the Improvements. Any additional or longer time extensions will require consent of the City Council. B. Events triggering termination and/or Contract forfeiture. If Developer does not begin or Substantially Complete construction of the Improvements on the schedule(s) stated above, subject to Unavoidable Delays, 2 then City may terminate this Agreement as set forth in Section 12, and City shall then have no further obligation to Developer under this Agreement. If development has commenced within the required period, as the same may be extended, and is subsequently stopped or delayed as a result of an act of God, war, civil disturbance, court order, labor dispute, fire, or other cause beyond the reasonable control of Developer (each an "Unavoidable Delay"), the requirement that construction be completed by the Completion Deadline shall be tolled for a period of time equal to the period of Unavoidable Delay. As promptly as possible, Developer shall notify City in writing of the occurrence of any Unavoidable Delay and shall again notify City in writing when the Unavoidable Delay has ended. If City terminates this Agreement as provided in Section 12, City shall have no further obligations to Developer under this Agreement, including but not limited to any legal or equitable obligation to reimburse Developer for any costs expended by Developer with respect to the Project or to compensate Developer for any value added to the Property by any Improvements. In connection with termination of the Agreement as set forth herein, City may forfeit the Contract in addition to exercising any other available remedies. 4. Utilities. Developer will be responsible for obtaining or extending water, sewer, telephone, telecommunications, electricity, gas and other utility services from street right of way to any location on the Property and for payment of any associated connection fees and costs of usage after the Contract date. 5. City Incentives. To aid the Project, City agrees to provide the following assistance: A. Partial Purchase Price Refund. Within thirty (30) days after Developer has Substantially Completed the Improvements and has obtained final inspection on all permits obtained for the Project, City will refund the Purchase Price to Developer. B. Grant. Concurrently with refund of the Purchase Price pursuant to paragraph A above, City will make a $5,000.00 infill housing incentive grant to Developer. 6. No Encumbrances; Limited Exception. Until the Improvements are Substantially Completed, Developer agrees that it shall not create, incur, or suffer to exist any Liens on the Property, other than such mortgage or mortgages as may be reasonably necessary to finance Developer's completion of the Improvements and of which Developer notifies City before Developer executes any such mortgage. Developer may not mortgage the Property or any part thereof for any purpose except in connection with financing of the Improvements. Any other mortgage shall be void. 7. No Assignment or Conveyance. Developer agrees that it will not sell, convey, assign or otherwise transfer its interest in the Contract or the Property prior to 3 completion of the Project, whether in whole or in part, to any other person or entity without the prior written consent of City. Reasonable grounds for the City to withhold its consent shall include but are not limited to the inability of the proposed transferee to demonstrate to the City's satisfaction that it has the financial ability to observe all of the terms to be performed by Developer under this Agreement. 8. Additional Covenants of Developer. In addition to the other promises, covenants and agreements of Developer as provided elsewhere in this Agreement, Developer agrees as follows: A. Until the Improvements have been Substantially Completed, Developer shall make such reports to City, in such detail and at such times as may be reasonably requested by City, as to the actual progress of Deveioper with respect to construction of the Improvements. B. Developer will comply with all applicable land development laws and City and county ordinances, and all laws, rules and regulations relating to its businesses, other than laws, rules and regulaticne> where " with the same, or where the sanctions and penalties resulting therefrom, would not have a material adverse effect on the business, property, operations, or condition, financial or otherwise, of Developer. C. Developer will cooperate fully with the City in resolution of any traffic, parking, trash removal or public safety problems which may arise in connection with the construction and operation of the Improvements. 9. Representations and Warranties of City. City hereby represents and warrants as follows: A. City is not prohibited from consummating the transaction contemplated in this Agreement by any law, regulation, agreement, instrument, restriction, order or judgment. B. Each person who executes and delivers this Agreement and all documents to be delivered hereunder is and shall be authorized to do so on behalf of City. 10. Representations and Warranties of Developer. Developer hereby represents and warrants as follows: A. It has all requisite power and authority to own and operate its properties, to carry on its business as now conducted and as presently proposed to be conducted, and to enter into and perform its obligations under this Agreement. 4 B. This Agreement has been duly and validly authorized, executed and delivered by Developer and, assuming due authorization, execution and delivery by the other parties hereto, is in full force and effect and is a valid and legally binding instrument of Developer that is enforceable in accordance with its terms, except as the same may be limited by bankruptcy, insolvency, reorganization or other laws relating to or affecting creditors' rights generally. C. The execution and delivery of this Agreement, the consummation of the transactions contemplated hereby, and the fulfillment of or compliance with the terms and conditions of this Agreement are not prevented by, limited by, in conflict with, or result in a violation or breach of, any contractual restriction, evidence of indebtedness, agreement or instrument of whatever nature to which Developer is now a party or by which it or its property is bound, nor do they constitute a default under any of the foregoing. D. There are no actions, suits or proceedings pending or threatened against or affecting Developer in any court or before any arbitrator or before or by any governmental body in which there is a reasonable possibility of an adverse decision which could materially adversely affect the business (present or prospective) or financial position of Developer or which in any manner raises any questions affecting the validity of the Agreement or Developer's ability to perform its obligations under this Agreement. 11. Default. The following shall be "Events of Default" under this Agreement, and the term "Event of Default" shall mean any one or more of the following events that continues beyond any applicable cure periods: A. Failure by Developer to cause the Improvements to be commenced and completed pursuant to the terms, conditions and limitations of this Agreement; B. Transfer by Developer of any interest (either directly or indirectly) in the Improvements, the Property, or this Agreement, without the prior written consent of City, except as expressly authorized by this Agreement; C. Failure by any party hereto to substantially observe or perform any covenant, condition, obligation or agreement on its part to be observed or performed under this Agreement; D. Any representation or warranty made by Developer in this Agreement, or made by Developer in any written statement or certificate furnished by Developer pursuant to this Agreement, shall prove to have been incorrect, incomplete or misleading in any material respect on or as of the date of the issuance or making thereof; 5 E. Developer(1)files any petition in bankruptcy or for any reorganization, arrangement, composition, readjustment, liquidation, dissolution, or similar relief under the federal bankruptcy law or any similar state law; (2) makes an assignment for the benefit of its creditors; (3) admits in writing its inability to pay its debts generally as they become due; (4) is adjudicated a bankrupt or insolvent; or if a petition or answer proposing the adjudication of Developer as a bankrupt or its reorganization under any present or future federal bankruptcy act or any similar federal or state law shall be filed in any court and such petition or answer shall not be discharged or denied within ninety (90) days after the filing thereof; or a receiver, trustee or liquidator of Developer, or part thereof, shall be appointed in any proceedings brought against Developer and shall not be discharged within ninety (90) days after such appointment, or if Developer shall consent to or acquiesce in such appointment; or (5) defaults under any mortgage applicable to the Property; or F. Any representation or warranty made by Developer in this Agreement, or made by Developer in any written statement or certificate furnished by Developer pursuant to this Agreement, shall prove to have been incorrect, incomplete or misleading in any material respect on or as of the date of the issuance or making thereof. 12. Remedies. A. Default by Developer. Whenever any Event of Default in respect of Developer occurs and is continuing, the City may terminate this Agreement. Before exercising such remedy, City shall give 30 days' written notice to Developer of the Event of Default, provided that by the conclusion of such period the Event of Default shall not have been cured, or the Event of Default cannot reasonably be cured within 30 days and Developer shall not have provided assurances reasonably satisfactory to the City that the Event of Default will be cured as soon as reasonably possible. Upon termination, City may exercise any and all remedies available at law, equity, contract or otherwise to recover ownership of the Property as set forth in this Agreement. B. Default by City. Whenever any Event of Default in respect of City occurs and is continuing, Developer may take such action against City to require it to specifically perform its obligations hereunder. Before exercising such remedy, Developer shall give 30 days' written notice to City of the Event of Default, provided that by the conclusion of such period the Event of Default shall not have been cured, or if the Event of Default cannot reasonably be cured within 30 days and City shall not have provided assurances reasonably satisfactory to the Developer that the Event of Default will be cured as soon as reasonably possible. C. Remedies under this Agreement shall be cumulative and in addition to any other right or remedy given under this Agreement or existing at law or in 6 equity or by statute. Waiver as to any particular default, or delay or omission in exercising any right or power accruing upon any default, shall not be construed as a waiver of any other or any subsequent default and shall not impair any such right or power. 13. Indemnification and Releases. • A. Developer hereby releases City, its elected officials, officers, employees, and agents (collectively, the "indemnified parties")from, covenants and agrees that the indemnified parties shall not be liable for, and agrees to indemnify, defend and hold harmless the indemnified parties against, any loss or damage to property or any injury to or death of any person occurring at or about the Property arising after the Contract date or resulting from any defect in the Improvements. The indemnified parties shall not be liable for any damage or injury to the persons or property of Developer or its employees, contractors or agents, or any other person who may be on or about the Property or the Improvements, due to any act of negligence or willful misconduct of any person, other than any act of negligence or willful misconduct on the part of any such indemnified party or its officers, employees or agents. B. Except for any willful misrepresentation, any willful misconduct, or any unlawful act of the indemnified parties, Developer agrees to protect and defend the indemnified parties, now or forever, and further agrees to hold the indemnified parties harmless, from any claim, demand, suit, action or other proceedings or any type or nature whatsoever, by any person or entity whatsoever that arises or purportedly arises from (1) any violation of any agreement or condition of this Agreement (except with respect to any suit, action, demand or other proceeding brought by Developer against the City to enforce its rights under this Agreement), or (2) the acquisition and condition of the Property and the construction, installation, ownership, and operation of the Improvements, or (3) otherwise as a result of or in connection with the Project or Developer's failure to carry on or complete same. C. The indemnification obligations under this Section shall include attorneys' fees and expenses incurred by any indemnified party. The provsins of this Section shall survive the expiration or termination of this Agreement. 14. Materiality of Developer's Promises, Covenants, Representations, and Warranties. Each and every promise, covenant, representation, and warranty set forth in this Agreement on the part of Developer to be performed is a material term of this Agreement, and each and every such promise, covenant, representation, and warranty constitutes a material inducement for City to enter this Agreement. Developer acknowledges that without such promises, covenants, representations, and warranties, City would not have entered this Agreement. Upon breach of any promise or covenant, or in the event of the incorrectness or falsity of any representation or warranty, City 7 may, at its sole option and in addition to any other right or remedy available to it, terminate this Agreement and declare it null and void. 15. Performance by City. Developer acknowledges and agrees that all of the obligations of City under this Agreement shall be subject to, and performed by City in accordance with, all applicable statutory, common law or constitutional provisions and procedures consistent with City's lawful authority. All covenants, stipulations, promises, agreements and obligations of City contained in this Agreement shall be deemed to be the covenants, stipulations, promises, agreements and obligations of City and not of any governing body member, officer, employee or agent of City in the individual capacity of such person. 16. No Third-Party Beneficiaries. No rights or privileges of any party hereto shall inure to the benefit of any contractor, subcontractor, material supplier, or any other person or entity, and no such contractor, subcontractor, material supplier, or other person or entity shall be deemed to be a third-party beneficiary of any of the provisions of this Agreement. 17. Notices. Any notice under this Agreement shall be in writing and shall be delivered in person, by overnight air courier service, by United States registered or certified mail, postage prepaid, or by facsimile (with an additional copy delivered by one of the foregoing means), and addressed: (a) if to City, at 715 Mulberry Street, Waterloo, Iowa 50703, fax number 319-291-4571, Attention: Mayor, with copies to the City Attorney and the Community Planning and Development Director. (b) if to Developer, at 22325 Mapes Road, Perris, California 92570. Delivery of notice shall be deemed to occur (i) on the date of delivery when delivered in person, (ii) one (1) business day following deposit for overnight delivery to an overnight air courier service which guarantees next day delivery, (iii) four (4) business following the date of deposit if mailed by United States registered or certified mail, postage prepaid, or (iv) when transmitted by facsimile so long as the sender obtains written electronic confirmation from the sending facsimile machine that such transmission was successful. A party may change the address for giving notice by any method set forth in this Section. 18. No Joint Venture. Nothing in this Agreement shall, or shall be deemed or construed to, create or constitute any joint venture, partnership, agency, employment, or any other relationship between the City and Developer nor to create any liability for one party with respect to the liabilities or obligations of the other party or any other person. 19. Amendment, Modification, and Waiver. No amendment, modification, or waiver of any condition, provision, or term of this Agreement shall be valid or of any effect unless made in writing, signed by the party or parties to be bound or by the duly 3 authorized representative of same, and specifying with particularity the extent and nature of the amendment, modification, or waiver. Any waiver by any party of any default by another party shall not affect or impair any rights arising from any subsequent default. 20. Severability; Reformation. Each provision, section, sentence, clause, phrase, and word of this Agreement is intended to be severable. If any portion of this Agreement shall be deemed invalid or unenforceable, whether in whole or in part, the offending provision or part thereof shall be deemed severed from this Agreement and the remaining provisions of this Agreement shall not be affected thereby and shall continue in full force and effect. If, for any reason, a court finds that any portion of this Agreement is invalid or unenforceable as written, but that by limiting such provision or portion thereof it would become valid and enforceable, then such provision or portion thereof shall be deemed to be written, and shall be construed and enforced, as so limited. 21. Interpretation. This Agreement shall not be construed more strictly against one party than against the other merely by virtue of the fact that it may have been prepared by counsel for one of the parties, it being recognized that the parties hereto and their respective attorneys have contributed substantially and materially to the preparation of each and every provision of this Agreement. 22. Captions. All captions, headings, or titles in the paragraphs or sections of this Agreement are inserted only as a matter of convenience and/or reference, and they shall in no way be construed as limiting, extending, or describing either the scope or intent of this Agreement or of any provisions hereof. 23. Binding Effect. This Agreement shall be binding and shall inure to the benefit of the parties and their respective successors, assigns, and legal representatives. 24. Counterparts. This Agreement may be executed in one or more counterparts, each of which, including signed counterparts delivered by facsimile or other electronic means, shall be deemed an original and all of which, taken together, shall constitute one and the same instrument. 25. Entire Agreement. This Agreement, together with the exhibits attached hereto, constitutes the entire agreement of the parties and supersedes all prior or contemporaneous negotiations, discussions, understandings, or agreements, whether oral or written, with respect to the subject matter hereof. 26. Time of Essence. Time is of the essence of this Agreement. IN WITNESS WhEREOF, the parties have executed this Development Agreement by their duly authorized representatives as of the date first set forth above. 9 CITY OF WATERLOO, IOWA DEVE OP ' 4 By: _ A Quentin Hart, Mayor M • arceli `` Ba `L� ez -- Per Attest: Kelley Fel le, City Clerk 10 EXHIBIT "A„ Property Description The Southeasterly 38 feet of Lots 8 and 9 in Block 9 in "Whitney's Subdivision" in Waterloo, Iowa. EXHIBIT "B" Form of Contract See attached. Y Prepared by: Christopher S.Wendland, P.O. Box 596,Waterloo, IA 56704. 319-234-5701 Taxpayer address: Marcelino Bailon Perez;22325 Mapes Road, Perris,CA 92570 REAL ESTATE CONTRACT qq This Real Estate Contract(the"Contract"), made and entered into as of O}/ la _, 2024, by and between City of Waterloo, Iowa ("Seller")and Marceline Bailon Perez ('Buyer"): WITNESSETH, that the Seller sells to the Buyer and the Buyer purchases the following described real estate (the"Property")situated in Black Hawk County, State of Iowa, to-wit: The Southeasterly 38 feet of Lots 8 and 9 in Block 9 in "Whitney's Subdivision" in Waterloo, Iowa. SUBJECT TO(a)easements, servitudes, conditions and restrictions of record; (b)current and future real estate reea property taxes and assessments subject to the agreements made herein; (c) general utility and right-of-way easements serving the Property; and(d)restrictions imposed by the City zoning ordinances and other applicable law. INCLUDED in this sale, if located in or on the Property and if owned by Seller, are all equipment,machinery,fixtures, trade fixtures, and all other fixtures not hereinafter specifically reserved by Seller in writing. 1. THE TOTAL PURCHASE PRICE for the Property is Five Thousand and 001100. Dollars ($5 000.00), payable to Seller at the address designated by Seller from time to time, as follows: (a) Four Thousand Nine Hundred Ninety-Nine Dollars ($4 999.00)upon execution of this Contract. (b) The baiance ui the purchase price w:i be due and payable in full on or before August 'i, 2025. 2. POSSESSION is to be given Buyer on the date of execution of this Contract by both parties. Seller represents that there are no other parties currently in possession. 3. TAXES AND ASSESSMENTS. The Property is currently exempt from property taxes. Buyer will pay all future general property taxes and special assessments prior to becoming delinquent. 4. INSURANCE. From and after delivery of possession, Buyer shall provide fire and extended coverage insurance on said premises at least equal to $30,000 in a company acceptable to Seller, all policies to protect the interest of both parties hereto as their interests may appear. Buyer shall promptly provide to Seller a certificate of insurance naming Seller as an additional insured. 5. RENTS. Intentionally omitted. 6. TITLE. At the time of final payment hereunder, the Seller shall convey the Property to the Buyer by QUIT CLAIM DEED. Buyer shall be responsible, at its sole cost and expense, to obtain whatever evidence of title that it desires. 7. CARE OF PROPERTY. No improvements placed upon the Property, or now thereon, shall be removed or destroyed until final payment is made, nor shall the Buyer commit waste of the Property. Buyer shall be solely • responsible, without claim or recourse to Seller, for any repairs, maintenance, or upkeep that may be necessary in connection with their occupancy and for all costs of utilities and other services to the Property. 8. ADVANCEMENT BY SELLER. If Buyer fails to pay such taxes, special assessments, or insurance as above agreed,Seller may, but need not, pay such taxes, special assessments, insurance,and all sums so expended shall be due and payable on demand; or such sums so expended may, at the election of Seller, be added to the principal amount due hereunder and bear interest until paid at the highest legal rate allowable or 12% per annum, whichever is less, compounded monthly. 9. JOINT TENANCY PRESERVED. Intentionally omitted. 10. ADDITIONAL TERMS. The parties further agree as follows: (a) Seller does not make, and has not made,any representation or warranty concerning the Property or its condition or fitness for use for any particular purpose. The Property is sold to Buyer"AS IS." (b) Buyer may not sell, transfer or assign its interest in this Contract without the prior written consent of Seller. (c) Property is subject to the terms of a certain Development Agreement between the parties. (e) Included in the sale and purchase at no additional consideration are all equipment,fixtures,inventory and other personal property of any type or nature that is located in or upon the Property, all of which are sold to Buyer"AS IS." (f) Buyer acknowledges that it has had a full and fair opportunity to enter upon and inspect the Property and/or to have the Property inspected by contractors of its own choosing. 11. TIME IS OF THE ESSENCE of this Contract. Failure promptly to assert rights of Seller hereunder shall not, however, be a waiver of such rights or a waiver of any existing or subsequent default. 12. DEFAULT. If the Buyer fails to perform any of the terms of this Contract,the Seller may forfeit this Contract as provided by Iowa law governing the forfeiture of real estate contracts, and if this Contract is forfeited, Buyer shall thereafter be considered as a tenant holding over after termination of a lease. Upon completion of such forfeiture,all sums previously paid Seller hereunder and all improvements placed on the Property by Buyer shall become the absolute property of Seller as liquidated damages for the breach of this Contract and as rent for the premises. In the event of compliance with the terms of the notice of forfeiture of this Contract, Buyer shall pay the cost of serving said notice. 13. ACCELERATION. If Buyer fails for thirty days to perform any one or more of the terms of this Contract, the Seller may, without further notice, declare the entire amount of the balance unpaid hereunder immediately due and payable; and thereafter, at the option of the Seller, this Contract may be foreclosed and a receiver may be appointed to take charge of said premises and collect the rents and profits therefrom to be applied as may be directed by the Court, and Buyer agrees to pay reasonable attorney fees therefor. 14. PERSONAL PROPERTY. If this Contract includes the sale of any personal property,then in the event of the forfeiture or foreclosure of this Contract,the personalty shall be considered indivisible from the real estate above described; and any such termination of Buyer's rights in said real estate shall concurrently operate as the forfeiture or foreclosure hereof against ail such personal property. 15. MORTGAGE BY SELLER. Intentionally omitted. 16. CERTIFICATION. Buyer and Seller each certify that they are not acting, directly or indirectly, for or on behalf of any person,group,entity or nation named by any Executive Order or the United States Treasury Department as a terrorist, "Specially Designated National and Blocked Person" or any other banned or blocked person, entity, nation or transaction pursuant to any law, order, rule or regulation that is enforced or administered by the Office of Foreign Assets Control; and are not engaged in this transaction, directly or indirectly on behalf of, any such person, group, entity or nation. Each party hereby agrees to defend, indemnify and hold harmless the other party from and against any and all claims, damages, losses, risks, liabilities and expenses (including attorney's fees and costs) arising from or related to my breach of the foregoing certification. 17. BUYER'S RIGHTS UNDER ENCUMBRANCE. Seller shall pay all interest and principal on all encumbrance of the Property created or suffered by Seller when the same become due, and in the event of a failure o 1 on Seller's part to make any such payment before it becomes delinquent, Buyer may pay the same and receive credit hereon for the amount so paid. If Buyer is acquiring the Property from an equity holder,rather than from a titleholder, or in event there is a mortgage against the Property,then, in either of those events, Buyer hereby reserves the right, if reasonably necessary for his protection,to split the payments pro rata among the interested payees. I 18. GENERAL TERMS: CONSTRUCTION. This Contract shall be binding upon the heirs, personal representatives, successors and assigns of the respective parties hereto. It represents the entire agreement of the parties and may not be amended without the express written consent of both parties. The singular masculine gender is used to refer to the parties in this Contract. Such terms shall be construed to include the feminine and neuter genders and the plural number, if applicable. 19. COUNTERPARTS. This Contract may be executed in any umb: o counterparts, all of which, taken together, shall constitute one and the same instrument. SELLER BUYER City of Waterloo, Iowa , By: 1 14-21-4�-� 'I�� Quentin Hart, Mayor Marcelin•a 1.-,r'ere. 111 Attest: �� Kelley Felchle City Clerk STATE OF IOWA ) )ss. BLACK HAWK COUNTY ) On this aS day of 1•kwrv4,1 , 2024, before me, a Notary Public in and for the State of Iowa, personally appeared Quentin Hart and Kelley Felchle,to me personally known, who being duly sworn, did say that they are the Mayor and City Clerk, respectively,of the City of Waterloo, Iowa, a municipal corporation, created and existing under the laws of the State of Iowa, and that the seal affixed to the foregoing instrument is the seal of said municipal corporation, and that said instrument was signed and sealed on behalf of said municipal corporation by authority and resolution of its City Council, and said Mayor and City Clerk acknowledged said instrument to be the free act and deed of said municipal corporation by it and by them voluntarily executed. .ahAn•_C.—_it-tti N ry Pubf ek e NANCYANNE HIGBY i 0 `F COMMISSION N0.853884 i * * MY COMMI3SIONEXPIRES too. a—t1-1oi-7 [acknowledgments continue on next page] I 3 STATE OF CALIFORNIA ) )ss. F VVtr$K ;;OliNTY ) This record was acknowledged before me on O Z,/ 4C� , 2024, by Marcelino Bailon Perez. Sir" k- r M Scar) _ Notary Public J. M.MORTENSEN �e COMM. #2370576 zz C" (; - Notary Public•California O z`- ey Riverside County ' rr,,,,:. _Nteomm.byres Aug 22_2025t 4 • 4-1ti 01s4.)^+A'TOSA}f t?sas.ssjua a 4q3 mfro3 wtot t ACKNOWLEDGMENT A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of California County of R \je cst ct-e On 32_11o12-k1 before me, 3M Aor eh tifo4-av-Lk P� hltt , (here insert name and title of the officer) personally appeared j'4fc 2,l t nCj t3cvi lean r"P ere't_. who proved to me on the basis of satisfactory evidence to be the person(p) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/shed' executed the same in his/her/ i authorized capacity(ies`), and that by his/he 'ii signature( on the instrument the personas}, or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. _ 1.M.MORTENSEN L °. 1+E COMM. #2370576 z T\• A WITNESS my hand and official seal. z r' . Notary Public•California o ` � Riverside County �J�,\ I ‘N. .,.9 I Comm.Expires Aut22.20251 Signature " �"v"�'C ISM S`�t"l (Seal) rCC;n re,. c.+-