Loading...
HomeMy WebLinkAboutBoulder Contracting, - Contract and bonds - Cont. No. 1106 - 5.20.2024FORM OF CONTRACT FOR THE CONSTRUCTION OF FY 2025 SIDEWALK RAMP & TRAIL REPAIR PROGRAM — ZONE 4 CITY OF WATERLOO, IOWA CONTRACT NO. 1106 20th This contract made and entered into this day of May , 2024, by and between the City of Waterloo, Iowa, a Municipal Corporation, (hereinafter referred to as City), and BOULDER CONTRACTING, LLC , of GRUNDY CENTER , IOWA , (hereinafter referred to as Contractor), WITNESSETH: PAR. 1 PAR. 2 PAR. 3 PAR. 4 PAR. 5 PAR. 6 PAR. 7 Contractor agrees to build and construct the FY 2025 SIDEWALK RAMP & TRAIL REPAIR PROGRAM — ZONE 4, CONTRACT NO. 1106, and furnish all necessary tools, equipment, materials, and labor necessary to do all the work called for in the plans and specifications in a workmanship -like manner and for the prices set forth in Contractor's proposal, which was accepted by the City, and which is understood and agreed to be a part of this contract. It is understood and agreed that the resolution adopted by the City Council ordering the construction of the improvement, the Notice to Contractors as published, the Instruction to Bidders, the Form of Proposal, the Construction and Maintenance Bonds, the Council Proceedings relating to this matter, and the Plans and Specifications shall all be considered as forming a part of the contract the same as though they were each set out in said contract. The Contractor agrees to furnish at its own cost and expense, all necessary materials and labor for said work and to construct said improvements in a thorough, substantial, and workmanlike manner, and in strict accordance with the requirements of this contract, and of the plans and specifications made a part hereof by reference, and to the satisfaction and approval of the City and its engineer. The Contractor agrees to perform said work and install said improvements on the terms set out in bid or proposal to the City which has been accepted by the City and which is by reference made a part of this contract. The Contractor agrees to commence said work within ten (10) working days after receipt of "Notice to Proceed" and complete it on or before OCTOBER 25, 2024 , unless an extension of time is granted in writing by the Council of the City. Should the Contractor fail to complete said improvements in strict accordance with the terms and conditions of this contract, or the plans and specifications therefor promptly by the date herein specified, the City may pay such additional sums as it may be required to pay by reason of the failure of said contractor and deduct any and all such sums from any amount then due the Contractor. The Contractor agrees to comply with and obey all ordinances of the City of Waterloo, Iowa, relating to the obstruction of streets and alleys, keeping open passage ways for water, traffic, and protecting any excavations in any street or alley, and maintaining proper and sufficient barricades with lights and signals during all hours of darkness, to see that the backfilling is properly done, and agrees to keep the FORM OF CONTRACT Page 1 of 4 PAR. 8 PAR. 9 PAR. 10 PAR. 11 City whole and defend any and all suits that may be brought against the City by reason of any injuries that may be sustained by any person or property allegedly caused by the Contractor, or his agents, while work is done pursuant to this agreement. The Contractor agrees that in the event a law suit is brought against the City for damages allegedly sustained by reason of any act, omission or negligence of the Contractor or its agents, or on account of any injuries allegedly sustained by reason of any obstruction, hole depression or barrier placed or dug by the defendant or its agents, in the doing of the work herein contracted for, that it will defend said suit and save the City harmless therein, and in case judgment is rendered against the City, the Contractor agrees to pay the same promptly. The Contractor agrees to carry public liability insurance in a solvent company in a sufficient amount to protect the City and those who use the streets of the City. The City shall have the right to appoint one or more construction reviewers who shall review the progress of the work in detail; also, to make any test or any material to be used in such work. No material shall be used in any work until the same has first been approved by the construction reviewer. Such construction reviewer shall have full authority to pass judgment upon all materials and upon the mariner of doing the work, and their judgment on rejecting any materials, substance, or manner of work shall be final unless it is revoked or modified by the City Engineer. Any material, which has been rejected by the construction reviewer, shall be at once removed from the line of work and shall not be again taken thereon or placed with the material proposed to be used without the written consent of the City Engineer. The Contractor shall maintain no cause of action against the City on account of delays and prosecution of work, but if said work is delayed by the City, the Contractor shall have such extra time for completion of the job as was lost by reason of the delay caused by the City. PAR The Contractor agrees to pay punctually all just claims of labor, material, men, or subcontractors who shall perform labor or furnish materials entering into this improvement. It is agreed that the City need not pay the Contractor until all such claims are paid by the Contractor. It is agreed that the City shall not be liable for said labor, material, or men under this contract. PAR. 13 PAR. 14 The Contractor agrees to furnish the City, simultaneously with this contract, a bond on a form to be provided by the City in the amount provided by law as stated in the Notice to Bidders, which shall be for the benefit of the City, and any and all persons injured by the breach of any of the terms of this contract. Said bond shall be filed with the City Clerk and shall be subject to the approval of the City Council, and is by reference made a part of this contract. The Contractor agrees that should it abandon work under this contract or cease the prosecution thereof for a period of thirty (30) consecutive days without reasonable cause, and should it fail to proceed with said work within ten (10) days after a notice to continue or carry it on has been mailed to it at the address given herein by the City, or after such notice has been served on it, then the City may proceed to complete said work, using any material, tools, or machinery found along said line of work, doing the work either by contract or as it may elect, and the Contractor and the sureties on its bond shall be liable to the City for the costs and expenses so paid out. Said costs shall be retained by the City from any compensation due, or to become due the Contractor, and may be recovered by the City in an action upon Contractor's bond. FORM OF CONTRACT Page 2 of 4 PAR. 15 In consideration of the full compliance on the part of the Contractor with all the provisions, stipulations, and conditions hereof, or contained in the various instruments made a part of this contract by reference, and upon completion and acceptance of said work, the City agrees to pay to the Contractor, in the manner set out in the Notice to Contractors, the amount of money due the Contractor for work performed and accepted, at the unit prices set out in the Contractor's proposal, which has been accepted by the City. PAR. 16 The total amount of the contract, based on the Engineer's estimates of quantities and the Contractor's unit bid prices, and for which 100% surety bond is required is $238 017.43. PAR. 17 After the completion of said work, the Contractor agrees to remove all debris and clean-up said streets, and to save the City harmless from any damage allegedly resulting from a failure to clean up and remove the debris or put the street back in a proper condition for travel. PAR. 18 This contract is not divisible, but in the event of a conflict between this contract and the various instruments incorporated by reference, this contract shall govern. PAR. 19 PAR. 20 PAR. 21 Before the Contractor shall be entitled to receive final payment for work done under this contract, it shall execute and file a bond in the penal sum of not less than 100% of the total amount of the contract, same to be known as "Maintenance Bond," and which bond must be approved by the City Council, and which bond is in addition to the bond given by the Contractor to guarantee the completion of the work. The Contractor shall maintain all work done hereunder in good order for the period of two (2) years from and after the date it is accepted by the Council of the City of Waterloo, Iowa. Said maintenance shall be made without expense to the City or the abutting property. In the event of the failure or default of the Contractor to remedy any or all defects appearing in said work within a period of two (2) years from the date of its acceptance by said Council, and after having been given ten (10) days' notice so to do by registered letter deposited in the United States Post Office in said town, addressed to said contractor at the address herein given, then the City may proceed to remedy such defects. The costs and expenses thereof to be recovered from the Contractor and the sureties on its maintenance bond by an action brought in any court of competent jurisdiction. The Contractor shall give notice to said City by registered letter directed to the Mayor or City Clerk/Auditor thereof not more than four (4) and not less than three (3) months prior to the expiration of the term during which the Contractor is required to maintain said improvements, in good repair by the terms of its Contract. The liability of the Contractor and of the sureties on its bond for maintenance of the said improvements shall continue until three (3) months after such notice has been given to the City, and, in any event, until two (2) years after the acceptance of the work. FORM OF CONTRACT Page 3 of 4 CITY /OAF WATERLOO, IOWA Quliva_[ i n /mil r,1 omirauv �L(,fAL Mayor Kelley FeCehle City Clerk DIGITALLY SIGNED BOULDER CONTRACTING, LLC Contractor BY: Title: aww 20th May 24 Approved by the City Council of the City of Waterloo, Iowa, this day of , 20. ATTEST: Kelley Felchle DIGITALLY FORM OF CONTRACT , City Clerk Waterloo, Iowa Page 4 of 4 Bond Number: 402197F PERFORMANCE BOND KNOW ALL MEN BY THESE PRESENTS: That we, Boulder Contracting, LLC of Grundy Center, Iowa (the "Principal"), and Westfield Insurance Company of Westfield Center, Ohio (the "Surety"), are held and firmly bound unto the City of Waterloo, Iowa (the "Obligee"), in the penal sum of Two Hundred Thirty Eight Thousand Seventeen & 43/100 Dollars ($ 238,017.43 ), lawful money of the Uni M,2t6Nior the payment of said sum in connection with a contract (the "Contract") dated on or about for the purpose of FY 2025 Sidewalk Ramp & Trail Repair Program - Zone 4, Contract No. 1106 . The Contract is incorporated herein by reference as though fully set forth herein. Whenever the Principal shall be and is declared by the Obligee to be in default under the Contract, with the Obligee having performed its obligations in the Contract, then the Surety, acknowledging that time is of the essence, may promptly remedy the default, or shall promptly undertake to: 1. Complete the Contract in accordance with its terms and conditions; or 2. Obtain one or more bids for completing the Contract in accordance with its terms and conditions, and upon determination by the Surety of the lowest responsible bidder, or negotiated proposal, or, if the Obligee elects, upon determination by the Obligee and the Surety jointly of the lowest responsible bidder, or negotiated proposal, arrange for a contract between such party and the Obligee. The Surety will make available as work progresses sufficient funds to pay the cost of completion less the balance of the Contract price. The cost of completion includes responsibilities of the Principal for correction of defective work and completion of the Contract, the Obligee's legal and design professional costs resulting directly from the Principal's default, and liquidated damages or actual damages if no liquidated damages are specified in the Contract. The term "balance of the Contract price" means the total amount payable by the Obligee to the Principal under the Contract and any amendments thereto, less the amount properly paid by the Obligee to the Principal; or 3. Determine the amount for which it is liable to the Obligee and pay the Obligee that amount as soon as practicable. In the event this bond is enforced, Principal and Surety agree to indemnify Obligee and hold Obligee harmless from and against any and all costs of enforcement, including but not limited to reasonable attorneys' fees and expenses. Every Surety on this bond shall be deemed and held, any contract to the contrary notwithstanding, to consent to each and all of the following matters, without notice: 1. To any extension of time to the Contract in which to perform the Contract. 2. To any change in the plans, specifications, or Contract when such change does not involve an increase of more than twenty percent (20%) of the total Contract price, and shall then be released only as to such excess increase. 3. That no provision of this bond or of any other contract shall be valid which limits to less than one (1) year from the time of the acceptance of the work the right to sue on this bond for defect in workmanship or material not discovered or known to the Obligee at the time such work was accepted. PEFORMANCE BOND Page 1 of 2 If the Principal performs the Contract, then this bond shall be null and void; otherwise it shall remain in full force and effect. In no event shall the Surety's total obligation exceed the penal amount of this bond. Terms used herein shall include, as appropriate, the singular or plural number, or the masculine, feminine or neuter gender. IN Vgli ffn J-IEREOF, the undersigned Principal and Surety have executed this Performance Bond as of PRINCIPAL Boulder Contracting, LLC Name By: Title: SURETY Westfield Insurance Company Name By: Title: Joseph I. Schrnit, Attorney -in -Fact [attach Power of Attorney] NOTE: Date of BOND must not be prior to date of Contract. If CONTRACTOR is Partnership, all partners should execute BOND. If this project includes Federal Funds, the following applies to the payment bond: IMPORTANT: Surety companies executing bonds must appear on the Treasury Department's most current list (Circular 570 as amended) and be authorized to transact business in the State where the project is located. PEFORMANCE BOND Page 2 of 2 Bond Number: 402197F PAYMENT BOND KNOW ALL MEN BY THESE PRESENTS: that Boulder Contracting, LLC (Name of Contractor) 606 East lst Street, P.O. Box 310, Grundy Center, Iowa 50638 (Address of Contractor) Corporation , hereinafter called Principal, and, (Corporation, Partnership or Individual) Westfield Insurance Company (Name of Surety) P.O. Box 5001, Westfield Center, Ohio 44251-5001 (Address of Surety) hereinafter called Surety, are held and firmly bound unto City of Waterloo, Iowa (Name of Owner) 715 Mulberry Street, Waterloo, Iowa 50703 (Address of owner) hereinafter called OWNER, in the penal sum of Two Hundred Thirty Eight Thousand Seventeen & 43/100 Dollars,($ 238,017.43 ) in lawful money of the United States, for the payment of which sum well and truly to be made, we bind ourselves, successors, and assigns, jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGMRN is such that ereas, the Pri pal entered into a certain contract with the OWNER, dated the day of ay 20 , a copy of which is hereto attached and made a part hereof for the construction of: FY 2025 Sidewalk Ramp & Trail Repair Program - Zone 4, Contract No. 1106 NOW, THEREFORE, if the Principal shall promptly make payment to all persons, firms, SUBCONTRACTORS, and corporations furnishing materials for or performing labor in the prosecution of the WORK provided for in such contract, and any authorized extension or modification thereof, including all amounts due for materials, lubricants, oil, gasoline, coal and coke, repairs an machinery, equipment and tools, consumed or used in connection with the construction of such WORK, and all insurance premiums on said WORK, and for all labor, performed in such WORK whether by SUBCONTRACTOR or otherwise, then this obligation shall be void; otherwise to remain in full force and effect. PROVIDED, FURTHER, that the said Surety for value received hereby stipulates and agrees that no change, extension of time, alteration or addition to the terms of the contract or to the WORK to be performed thereunder or the SPECIFICATIONS accompanying the same shall in any wise affect its obligation on this BOND, and it does hereby waive notice of any such change, extension of time, alteration or addition to the terms of the contract or to the WORK or to the SPECIFICATIONS. PAYMENT BOND Page 1 of 2 PROVIDED, FURTHER, that no final settlement between the OWNER and the CONTRACTOR shall abridge the right of any beneficiary hereunder, whose claim may be unsatisfied. IN WITNESS HEREOF, this instrument is executed in three (3) counterparts, each one of which, (nt er) day of y shall be deemed an original, this the 20th ATTEST: (Principal) Secretary (SEAL) Witness as to Principal (Address) ATTEST: s as to SuretyJuliana Bartlett, Sr. Bonds Account Manager 4200 University Ave., Ste. 200 (Address) West Des Moines, Iowa 50266 20 24. Boulder Contracting, LLC (Principal) By: (s) 606 East lst Street, P.O. Box 310 (Address) Grundy Center, Iowa 50638 Westfield Insurance Company Surety Josep I. S hmlt, Attorney•in-Fact 4200 University Ave., Ste. 200 (Address) West Des Moines, Iowa 50266 NOTE: Date of BOND must not be prior to date of Contract. If CONTRACTOR is Partnership, all partners should execute BOND. If this project includes Federal Funds, the following applies to the payment bond: IMPORTANT: Surety companies executing bonds must appear on the Treasury Department's most current list (Circular 570 as amended) and be authorized to transact business in the State where the project is located. PAYMENT BOND Page 2 of 2 THIS POWER OF ATTORNEY SUPERCEDES ANY PREVIOUS POWER BEARING THIS SAME POWER # AND ISSUED PRIOR TO 06/20/22, FOR ANY PERSON OR PERSONS NAMED BELOW. General POWER NO, 1429172 00 Power Westfield Insurance Co. of Attorney Westfield National Insurance Co. Ohio Farmers Insurance Co. Westfield Center, Ohio CERTIFIED COPY Know All Men by These Presents, That WESTFIELD INSURANCE COMPANY, WESTFIELD NATIONAL INSURANCE COMPANY and OHIO FARMERS INSURANCE COMPANY, corporations, hereinafter referred to individually as a 'Company" and collectively as "Companies," duly organized and existing under the laws of the State of Ohio, and having its principal office in Westfield Center, Medina County, Ohio, do by these presents make, constitute and appoint JOSEPH I. SCHMIT, JEFFREY R. BAKER, GREG T. LAMAIR, E. A. VONHARZ, BRANDON HORBACH, JOINTLY OR SEVERALLY of WEST DES MOINES and State of IA its true and lawful Attorney(s)-in-Fact, with full power and authority hereby conferred in its name, place and stead, to execute, acknowledge and deliver any and all bonds, recognizances, undertakings, or other instruments or contracts of suretyship in any penal lim t. - - - - - - - - - ------------ - - - - - - - - - ------- - - - - - - - - - - - - - - " - - . LIMITATION: THIS POWER OF ATTORNEY CANNOT BE USED TO EXECUTE NOTE GUARANTEE, MORTGAGE DEFICIENCY, MORTGAGE GUARANTEE, OR BANK DEPOSITORY BONDS. and to bind any of the Companies thereby as fully and to the same extent as if such bonds were signed by the President, sealed with the corporate seal of the applicable Company and duly attested by its Secretary, hereby ratifying and confirming all that the said Attorney(s)-in-Fact may do in the premises. Said appointment is made under and by authority of the following resolution adopted by the Board of Directors of each of the WESTFIELD INSURANCE COMPANY, WESTFIELD NATIONAL INSURANCE COMPANY and OHIO FARMERS INSURANCE COMPANY: 'Be It Resolved, that the President, any Senior Executive, any Secretary or any Fidelity & Surety Operations Executive or other Executive shall be and is hereby vested with full power and authority to appoint any one or more suitable persons as Attorney(s)-in-Fact to represent and act for and on behalf of the Company sub ect to the following provisions: The Attorney -in -Fact. may be g ven full power and authority for and in the name of and on behalf of the Company, to execute, acknowledge and deliver, any and all bonds, recognizance; contracts, agreements of indemnity and other conditional or obligatory undertakings and any and all notices and documents canceling or terminating the Company's liability thereunder, and any such instruments so executed by any such Attorney -in -Fact shall be as binding upon the Company as if signed by the President and sealed and attested by the Corporate Secretary." "Be it Further Resolved, that the signature of any such designated person and the seal of the Company heretofore or hereafter affixed to any power of attorney or any certificate relating thereto by facsimile, and any power of attorney or certificate bearing facsimile signatures or facsimile seal shall be valid and binding upon the Company with respect to any bond or undertaking to which it is attached: (Each adopted at a meeting held on February 8, 2000). In Witness Whereof, WESTFIELD INSURANCE COMPANY, WESTFIELD NATIONAL INSURANCE COMPANY and OHIO FARMERS INSURANCE COMPANY have caused these presents to be signed by their National Surety Leader and Senior Executive and their corporate seals to be hereto affixed this 20th day of JUNE A.D., 2022 . Corporate ,a°'a4YRAN"'x, °'S1nN^L/N'•..................... \NSU WESTFIELD INSURANCE COMPANY seals ,tQ r,. •••••••..cal. Si.,,`'aa,.•-••••••.,.y.G ;• ?, RA,yc•� WESTFIELD NATIONAL INSURANCE COMPANY Mixed y` j tea. T'•Yp ,•a:'' '-,P g •�' _a OHIO FARMERS i RA Mrr COMPANY '1i( SEAL i ' • SEAI, a u. CNIRTEgFp' a ) (r..• SEAL/ �: gym` :gt / a.t a•.. , otar , , 1848 ; t. ao'• off: State of Ohio "" Will ""."0001 By: County of Medina ss.: Gary W. Itumper, Naliona]'"Surety Leader and Senior Executive On this 20th day of JUNE A.D., 2022 , before me personally came Gary W. Stumper to me known, who, being by me duly sworn, did depose and say, that he resides in Medina, OH; that he is National Surety Leader and Senior Executive of WESTFIELD INSURANCE COMPANY, WESTFIELD NATIONAL INSURANCE COMPANY and OHIO FARMERS INSURANCE COMPANY, the companies described in and which executed the above instrument; that he knows the seals of said Companies; that the seals affixed to said instrument are such corporate seals; that they were so affixed by order of the Boards of Directors of said Companies; and that he signed his name thereto by like order. Notarial Seal Affixed State of Ohio - v, /r WI 10 David A. Kotnik, Attorney at Law, Notary Public County of Medina ss.: '••., q t w• ÷ My Commission Does Not Expire (Sec. 147.03 Ohio Revised Code) Te OF .,.. I, Frank A. Carrino, Secretary of WESTFIELD INSURANCE COMPANY, WESTFIELD NATIONAL INSURANCE COMPANY and OHIO FARMERS INSURANCE COMPANY, do hereby certify that the above and foregoing is a true and correct copy of a Power of Attorney, executed by said Companies, which is still in full force and effect; and furthermore, the resolutions of the Boards of Directors, set out in the Power of Attorney are in fu I force and effect. In Witness Whereof, I have hereunto set my hand and affixed the seals of said Companies at Westfield Center, Ohio, this day of A.D., .1440.011 '.coaURAp...,'Giro3.,aF.„. .yps oa r O: Iit i Ym s.•'6NItRTERfO 9 • BPOAC2 (combined) (03-22) ,_44e,1NSUq,�y A Frank A. Car itto, Secretary Secretary ACORO® CERTIFICATE OF LIABILITY INSURANCE DATE (MMIDD/YYYY) 5/9/2024 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policypes) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of tl e policy, certain policies may require an endorsement. A statement on this certificate does not confer rights fo the certificate holder in lieu of such endorsement(s). PRODUCER Holmes Murphy & Associates - CR 201 First Street SE, Suite 700 Cedar Rapids IA 52401 INSURED Boulder Contracting, LLC 606 E. 1st St. Grundy Center, IA 50638 BOUCONPC CONTACT NAME: Kelli DeVries PHONE NC. No. Extl: 319-896-7661 I (NC, No): E-MAIL ADDRESS: kdevres@holmesmurphy.com INSURERS) AFFORDING COVERAGE NAICF INSURER Travelers Prpperty Casualty Co. America 25674 INSURER B: Travelers Indemnity Co of CT 25682 INSURER C: Phoenix Insurance Company 25623 INSURER D INSURER E : INSURER F COVERAGES CERTIFICATE NUMBER: 2074031610 REVISION NUMBER: INSR THIS INDICATED. CERTIFICATE EXCLUSIONS LTR IS TO CERTIFY NOTWITHSTANDING MAY BE AND CONDITIONS - THAT THE POLICIES ANY REQUIREMENT, ISSUED OR MAY OF SUCH OF INSURANCE PERTAIN, POLICIES. ADDL INSR SUBR WVD LISTED BELOW HAVE BEEN TERM OR CONDITION OF ANY THE INSURANCE AFFORDED BY LIMITS SHOWN MAY HAVE BEEN - POLICY NUMBER ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, PAID CLAIMS. POLICY EXP IMM/DiY DYYY1 I LIMITS CONTRACT THE POLICIES REDUCED BY 1 POLICY EFT (MMIY !DDYYY) TYPE OF INSURANCE C X 11 COMMERCIAL GENERAL LIABILITY Y 4TC03W380051PHX24 3/1/2024 3/1/2025 EACH OCCURRENCE $1,000,000 '_ -_ j CLAIMS MADE `X_ OCCUR D0..1AGE PREMISES(Eaacur TO RENTED ce)_ $300000 1 I,000 MED EXP (Any one person) $ 10,000 PERSONAL S. ADV INJURY $ 1,000,000 GENT. AGGREGATE LIMIT APPLIES PER. GENERAL AGGREGATE $2,000000 I POLICY X i fIECT X LOC i PRODUCTS . COMPIOPAGG $ 2,000,000 OTHER: 1 $ A AUTOMOBILELIABILITY 8103W343276242SG 3/1/2024 3/1/2025 I COMBINED Ea accident) SINGLE LIMIT S1,000000 X 1 ANY AUTO I BODILY INJURY (Per person) $ OWNED AUTOS ONLY SCHEDULED NOTES iRODILY NJURY (Per accident) _, NON -OWNED i PROPERTY DAMAGE AUTOS ONLY AUTOS AUTOS ONLY I(Per widen) S S A X UMBRELLA LIAB X OCCUR CUP? S91457924NF 3/1/2024 3/1/2025 EACH OCCURRENCE $8,000,000 EXCESS LIAB jI I CLAIMS -MADE AGGREGATE $ 81000,000 DEL) RETENTION$ $ B WORKERS COMPENSATION AND EMPLOYERS' LIABILITY YIN UB3W3805612425G 3/1/2024 3/1/2025 IX STATUTE ORH ANVPROPRIETOR'PARTNER/EXECUTI�VE 1 E.L EACH ACCIDENT S500,000 Y OFFICEWMEMBER EXCLUDED? (MandatoryInIn NH) N/A 1 E.L DISEASE - EA EMPLOYEE S 500,000 It yes, desuibe undet- --_- __-- _- DESCRIPTION OF OPERATIONS below 1 E.L DISEASE - POLICY LIMIT $ 500,000 1 DESCRIPTION OF OPERATIONS / LOCATIONS ! VEHICLES (ACORD 101, Additional Remarks Schedule, may bo attached if more space is requited) Pro ect Reference: Sidewalk Ramp & Trail Repair Program Contract #: 1106 Excluded Officers: Luke Kjormoe, Kittle Kjormoe, Kimberly Lynch, & Justin Lynch City of Waterloo, Iowa is Additional Insured on General Liability as required by written contract with the insured, per policy terms and conditions. 30 days notice of cancellation will be provided per policy terms and conditions, CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED PO City of Waterloo 715 Mulberry Street Waterloo IA 50703 USA SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. AUTHORIZED REPRESENTATIVE C-no t. ACORD 25 (2016/03) © 1988-2015 ACORD CORPORATION. All rights reserved, The ACORD name and logo a e registered marks of ACORD