Loading...
HomeMy WebLinkAboutHabitat DA for 4 lots-(RECORDED) 10-21-24 2024-23947 RECORDED: 11/26/2024 01:47:20 PM RECORDING FEE:$62.00 REVENUE TAX:$ COMBINED FEE:$62.00 SANDIE L.SMITH,RECORDER BLACK HAWK COUNTY,IOWA Preparer: Christopher S.Wendland, P.O. Box 596,Waterloo, Iowa 50704 (319)234-5701 After recording, return to Community Planning&Development, 715 Mulberry Street, Waterloo, IA 50703. DEVELOPMENT AGREEMENT Octdkeivelopment Agreement (the "Agreement") is entered into as of , 2024 by and between Iowa Heartland Habitat for Humanity ("Company"), and the City of Waterloo, Iowa ("City"). RECITALS A. Company is willing and able to finance and construct or rehabilitate single- family dwellings and related improvements on various properties located in the City of Waterloo, including infill lots in established residential neighborhoods as identified on Exhibit "A" attached hereto (the "Properties"). Each separate property is referred to as a "Project Site." B. City considers infill residential development within the City a benefit to the community and is willing for the overall good and welfare of the community to provide financial incentives to encourage that goal. City believes that such development is in the vital and best interests of the City and in accordance with the public purposes and provisions of the applicable State and local laws and requirements under which the Project (defined below) is being undertaken and is being assisted. AGREEMENT NOW, THEREFORE, in consideration of the mutual covenants set forth herein, the parties agree as follows: 1. Sale of Property; Title. Subject to the terms hereof, City shall convey the Properties to Company for the sum of$1.00 (the "Purchase Price"). Conveyance shall be by quit claim deed, free and clear of all encumbrances arising by or through City except: (a) easements, servitudes, conditions and restrictions of record; (b) current and future real estate real property taxes and assessments subject to the agreements made herein; (c) general utility and right-of-way easements serving the Property; and (d) restrictions imposed by the City zoning ordinances and other applicable law. Company may, at its own expense, obtain whatever form of title evidence it desires. If title is unmarketable or subject to matters not acceptable to Company, and if City does not remedy or remove such objectionable matters in timely fashion following written notice of such objections from Company, Company may terminate this Agreement without further obligation. City shall provide any title documents it has in its possession, including any abstracts, to assist in title review. 2. Improvements by Company. Company acknowledges that it has had a reasonable opportunity to inspect each of the Properties and to conduct other due diligence related to the Project. Company agrees to accept the Properties in their "AS IS" condition, without any warranty from City, expressed or implied, as to the condition of each Property, its marketability, or its fitness for any particular purpose. At its own expense Company shall construct upon each Project Site one (1) single-family home as further described and depicted in plan to be submitted to City, except that with respect to parcels 8913-24-303-007 and 8913-24-303-018 Company shall maintain such Properties as greenspace in accordance with City ordinances until such time as it chooses to build a new dwelling thereon. No more than one home shall be constructed on each Project Site, and each Project Site upon which a home will be constructed shall be completed to a finished state, including installation of sidewalks, driveways and garages, removal of all construction debris, proper leveling or shaping of groundscape, and grassing and/or landscaping (construction and finishing as so described are referred to as the "Improvements"). The Improvements shall be constructed in accordance with the terms of this Agreement, all applicable City, state, and federal building codes and shall comply with all applicable City ordinances and other applicable law. Company shall submit specific plans, building designs and site plans for City review and approval before the commencement of construction and shall not substantially deviate from such plans, specifications or designs. Company will use its best efforts to obtain, or cause to be obtained, in a timely manner, all required permits, licenses and approvals, and will meet, in a timely manner, all requirements of all applicable local, state, and federal laws and regulations which must be obtained or met before the Improvements may be lawfully constructed. The Properties, the Improvements, and all site preparation and development-related work to be undertaken and completed by Company under this Agreement are collectively referred to as the "Project." 3. Timeliness of Construction; Possibility of Reverter. The parties agree that Company's commitment to cause the Project to be undertaken and to construct the Improvements in a timely manner constitutes a material inducement for the City to convey the Properties to Company and to extend the incentives provided for in this Agreement, and that without said commitment City would not do so. A. Deadlines to commence and complete. Subject to Unavoidable Delays (defined below), Company must Substantially Complete construction within two (2) years from the date that the Properties are conveyed to Company (the "Completion Deadline"). For purposes of this Agreement, "Substantially Complete" means the date on which the Improvements on a Project Site have been completed to the extent necessary for the City to issue a certificate of occupancy relating thereto and the City has verified that Project elements for which no permit was necessary have been substantially completed. All deadlines are subject to Unavoidable Delays as defined in paragraph B below. The City's Community Planning and Development Director may, but shall not be required to, consent to an extension of time of up to six (6) months for the construction of any phase of the Improvements. Any additional or longer time extensions will require consent of the City Council. The provisions of this Section 3 shall apply separately to each Project Site. B. Events triggering termination and/or reverter of title. If Company does not begin or Substantially Complete construction of the Improvements at a Project Site on the schedule stated above, subject to Unavoidable Delays, then City may terminate this Agreement with respect to such Project Site as set forth in Section 13, and City shall then have no further obligation to Company under this Agreement with respect to such Project Site. If development has commenced within the required period, as the same may be extended, and is subsequently stopped or delayed as a result of an act of God, war, civil disturbance, court order, labor dispute, fire, or other cause beyond the reasonable control of Company (each an "Unavoidable Delay"), the requirement that construction be completed by the Completion Deadline shall be tolled for a period of time equal to the period of Unavoidable Delay. As promptly as possible, Company shall notify City in writing of the occurrence of any Unavoidable Delay and shall again notify City in writing when the Unavoidable Delay has ended. If City terminates this Agreement with respect to a Project Site as provided in Section 13, City shall have no further obligations to Company under this Agreement, including but not limited to any legal or equitable obligation to reimburse Company for any costs expended by Company with respect to the Project Site or to compensate Company for any value added to the Project Site by any Improvements. In connection with termination of the Agreement as set forth herein, City may demand reconveyance of any Project Site on which Improvements have not been Substantially Completed, in addition to exercising any other available remedies. 4. Reverter of Title; Indemnity. In the event of any reverter of title pursuant to Section 3, Company agrees that it shall, at its own expense, promptly execute all documents, including but not limited to a special warranty deed, or take such other actions as the City may reasonably request to effectuate said reverter and to deliver to City title to the Project Site free and clear of any lien, claim, charge, security interest, mortgage or encumbrance (collectively, "Liens") arising by or through Company. Company shall pay in full, so as to discharge or satisfy, all Liens on or against the Project Site. In connection with any reverter of title, Company shall not be entitled to a refund of the Purchase Price. Appointment of Attorney in Fact: If Company fails to deliver such documents, including but not limited to a special warranty deed, to City within thirty (30) days after written demand by City, then City shall be authorized to execute, on Company's behalf and as its attorney-in-fact, the special warranty deed or other documents required by this Section, and for such limited purpose Company does hereby constitute and appoint City as its attorney-in-fact. Company further agrees that it shall indemnify City and hold it harmless with respect to any demand, claim, cause of action, damage, cost, expense, liability or injury made, suffered, or incurred as a result of or in connection with the Project, or Company's failure to carry on or complete same, or any Lien or Liens on or against the Project Site of any type or nature whatsoever that attaches to the Project Site by virtue of Company's ownership of same. If City files suit to enforce the terms of this Agreement and prevails in such suit, then Company shall be liable for all legal expenses, including but not limited to reasonable attorneys' fees, incurred by City. Company's duties of indemnity pursuant to this Section shall survive the expiration, termination or cancellation of this Agreement for any reason. 5. Utilities. Company will be responsible for extending water, sewer, telephone, telecommunications, electricity, gas and other utility services from street right of way to any location on a Project Site and for payment of any associated connection fees. 6. City Incentives. To aid the Project, City agrees to provide the following assistance: A. Infill Housing Grant. As provided in the City's infill housing policy, City will pay Company a grant of$5,000.00 within thirty (30) days after Company has Substantially Completed the Improvements on a Project Site and has obtained final inspection on all permits obtained for Improvements on that Project Site. The maximum incentive payable to Company is $10,000.00. 7. No Encumbrances; Limited Exception. Until the Improvements are Substantially Completed, Company agrees that it shall not create, incur, or suffer to exist any Liens on any of the Properties, other than such mortgage or mortgages as may be reasonably necessary to finance Company's completion of the Improvements and of which Company notifies City before Company executes any such mortgage. Company may not mortgage a Project Site or any part thereof for any purpose except in connection with financing of the Improvements upon such Project Site. Any other mortgage shall be void. 8. No Assignment or Conveyance. Company agrees that it will not sell, convey, assign or otherwise transfer, in whole or in part, its interest in any Project Site prior to completion of the Project thereon, to any other person or entity without the prior written consent of City. Reasonable grounds for the City to withhold its consent shall include but are not limited to the inability of the proposed transferee to demonstrate to the City's satisfaction that it has the financial ability to observe all of the terms to be performed by Company under this Agreement. 9. Additional Covenants of Company. In addition to the other promises, covenants and agreements of Company as provided elsewhere in this Agreement, Company agrees as follows: A. Until the Improvements have been Substantially Completed, Company shall make such reports to City, in such detail and at such times as may be reasonably requested by City, as to the actual progress of Company with respect to construction of the Improvements. B. Company will comply with all applicable land development laws and City and county ordinances, and all laws, rules and regulations relating to its businesses, other than laws, rules and regulations where the failure to comply with the same, or where the sanctions and penalties resulting therefrom, would not have a material adverse effect on the business, property, operations, or condition, financial or otherwise, of Company. C. Company will cooperate fully with the City in resolution of any traffic, parking, trash removal or public safety problems which may arise in connection with the construction and operation of the Improvements. D. Company agrees during construction of the Improvements to maintain, as applicable, builder's risk, property damage, and liability insurance coverages with respect to the Improvements in such amounts as are customarily carried by like companies engaged in activities of comparable size and liability exposure, and shall provide evidence of such coverages to the City upon request. 10. Representations and Warranties of City. City hereby represents and warrants as follows: A. City is not prohibited from consummating the transaction contemplated in this Agreement by any law, regulation, agreement, instrument, restriction, order or judgment. B. Each person who executes and delivers this Agreement and all documents to be delivered hereunder is and shall be authorized to do so on behalf of City. 11. Representations and Warranties of Company. Company hereby represents and warrants as follows: A. It is duly organized, validly existing, and in good standing under the laws of the state of its organization and is duly qualified and in good standing under the laws of the State of Iowa. B. It has all requisite power and authority to own and operate its properties, to carry on its business as now conducted and as presently proposed to be conducted, and to enter into and perform its obligations under this Agreement. C. This Agreement has been duly and validly authorized, executed and delivered by Company and, assuming due authorization, execution and delivery by the other parties hereto, is in full force and effect and is a valid and legally binding instrument of Company that is enforceable in accordance with its terms, except as the same may be limited by bankruptcy, insolvency, reorganization or other laws relating to or affecting creditors' rights generally. D. The execution and delivery of this Agreement, the consummation of the transactions contemplated hereby, and the fulfillment of or compliance with the terms and conditions of this Agreement are not prevented by, limited by, in conflict with, or result in a violation or breach of, the terms, conditions or provisions of the articles of organization or operating agreement of Company or of any contractual restriction, evidence of indebtedness, agreement or instrument of whatever nature to which Company is now a party or by which it or its property is bound, nor do they constitute a default under any of the foregoing. E. There are no actions, suits or proceedings pending or threatened against or affecting Company in any court or before any arbitrator or before or by any governmental body in which there is a reasonable possibility of an adverse decision which could materially adversely affect the business (present or prospective), financial position, or results of operations of Company or which in any manner raises any questions affecting the validity of the Agreement or Company's ability to perform its obligations under this Agreement. 12. Default. The following shall be "Events of Default" under this Agreement, and the term "Event of Default" shall mean any one or more of the following events that continues beyond any applicable cure periods: A. Failure by Company to cause the Improvements to be commenced and completed pursuant to the terms, conditions and limitations of this Agreement; B. Transfer by Company of any interest (either directly or indirectly) in the Improvements, the Properties, or this Agreement, without the prior written consent of City, except as expressly authorized by this Agreement; C. Failure by any party hereto to substantially observe or perform any covenant, condition, obligation or agreement on its part to be observed or performed under this Agreement; D. Company (1) files any petition in bankruptcy or for any reorganization, arrangement, composition, readjustment, liquidation, dissolution, or similar relief under the federal bankruptcy law or any similar state law; (2) makes an assignment for the benefit of its creditors; (3) admits in writing its inability to pay its debts generally as they become due; (4) is adjudicated a bankrupt or insolvent; or if a petition or answer proposing the adjudication of Company as a bankrupt or its reorganization under any present or future federal bankruptcy act or any similar federal or state law shall be filed in any court and such petition or answer shall not be discharged or denied within ninety (90) days after the filing thereof; or a receiver, trustee or liquidator of Company, or part thereof, shall be appointed in any proceedings brought against Company and shall not be discharged within ninety (90) days after such appointment, or if Company shall consent to or acquiesce in such appointment; or (5) defaults under any mortgage applicable to the Property; or E. Any representation or warranty made by Company in this Agreement, or made by Company in any written statement or certificate furnished by Company pursuant to this Agreement, shall prove to have been incorrect, incomplete or misleading in any material respect on or as of the date of the issuance or making thereof. 13. Remedies. A. Default by Company. Whenever any Event of Default in respect of Company occurs and is continuing, the City may terminate this Agreement, in whole or as to any particular Project Site. Before exercising such remedy, City shall give 30 days' written notice to Company of the Event of Default, provided that by the conclusion of such period the Event of Default shall not have been cured, or the Event of Default cannot reasonably be cured within 30 days and Company shall not have provided assurances reasonably satisfactory to the City that the Event of Default will be cured as soon as reasonably possible. Upon termination, City may exercise any and all remedies available at law, equity, contract or otherwise for recovery of any sums paid by City to Company before the date of termination or to recover ownership of Project Sites as set forth in this Agreement. B. Default by City. Whenever any Event of Default in respect of City occurs and is continuing, Company may take such action against City to require it to specifically perform its obligations hereunder. Before exercising such remedy, Company shall give 30 days' written notice to City of the Event of Default, provided that by the conclusion of such period the Event of Default shall not have been cured, or if the Event of Default cannot reasonably be cured within 30 days and City shall not have provided assurances reasonably satisfactory to the Company that the Event of Default will be cured as soon as reasonably possible. C. Remedies under this Agreement shall be cumulative and in addition to any other right or remedy given under this Agreement or existing at law or in equity or by statute. Waiver as to any particular default, or delay or omission in exercising any right or power accruing upon any default, shall not be construed as a waiver of any other or any subsequent default and shall not impair any such right or power. 14. Indemnification and Releases. A. Company hereby releases City, its elected officials, officers, employees, and agents (collectively, the "indemnified parties") from, covenants and agrees that the indemnified parties shall not be liable for, and agrees to indemnify, defend and hold harmless the indemnified parties against, any loss or damage to property or any injury to or death of any person occurring at or about the Properties arising after Company's acquisition of same or resulting from any defect in the Improvements. The indemnified parties shall not be liable for any damage or injury to the persons or property of Company or its directors, officers, employees, contractors or agents, or any other person who may be on or about the Properties or the Improvements, due to any act of negligence or willful misconduct of any person, other than any act of negligence or willful misconduct on the part of any such indemnified party or its officers, employees or agents. B. Except for any willful misrepresentation, any willful misconduct, or any unlawful act of the indemnified parties, Company agrees to protect and defend the indemnified parties, now or forever, and further agrees to hold the indemnified parties harmless, from any claim, demand, suit, action or other proceedings or any type or nature whatsoever, by any person or entity whatsoever that arises or purportedly arises from (1) any violation of any agreement or condition of this Agreement (except with respect to any suit, action, demand or other proceeding brought by Company against the City to enforce its rights under this Agreement), or (2) the acquisition and condition of the Properties and the construction, installation, ownership, and operation of the Improvements, or (3) otherwise as a result of or in connection with the Project or Company's failure to carry on or complete same. C. The indemnification obligations under this Section shall include attorneys' fees and expenses incurred by any indemnified party. The provisions of this Section shall survive the expiration or termination of this Agreement. 15. Materiality of Company's Promises, Covenants, Representations, and Warranties. Each and every promise, covenant, representation, and warranty set forth in this Agreement on the part of Company to be performed is a material term of this Agreement, and each and every such promise, covenant, representation, and warranty constitutes a material inducement for City to enter this Agreement. Company acknowledges that without such promises, covenants, representations, and warranties, City would not have entered this Agreement. Upon breach of any promise or covenant, or in the event of the incorrectness or falsity of any representation or warranty, City may, at its sole option and in addition to any other right or remedy available to it, terminate this Agreement and declare it null and void. 16. Performance by City. Company acknowledges and agrees that all of the obligations of City under this Agreement shall be subject to, and performed by City in accordance with, all applicable statutory, common law or constitutional provisions and procedures consistent with City's lawful authority. All covenants, stipulations, promises, agreements and obligations of City contained in this Agreement shall be deemed to be the covenants, stipulations, promises, agreements and obligations of City and not of any governing body member, officer, employee or agent of City in the individual capacity of such person. 17. No Third-Party Beneficiaries. No rights or privileges of any party hereto shall inure to the benefit of any contractor, subcontractor, material supplier, or any other person or entity, and no such contractor, subcontractor, material supplier, or other person or entity shall be deemed to be a third-party beneficiary of any of the provisions of this Agreement. 18. Notices. Any notice under this Agreement shall be in writing and shall be delivered in person, by overnight air courier service, by United States registered or certified mail, postage prepaid, or by facsimile (with an additional copy delivered by one of the foregoing means), and addressed: (a) if to City, at 715 Mulberry Street, Waterloo, Iowa 50703, Attention: Mayor, with copies to the Community Planning and Development Director. (b) if to Company, at 803 W. 5th Street, Waterloo, Iowa 50702, Attention: Executive Director. Delivery of notice shall be deemed to occur (i) on the date of delivery when delivered in person, (ii) one (1) business day following deposit for overnight delivery to an overnight air courier service which guarantees next day delivery, or (iii) three (3) business days following the date of deposit if mailed by United States registered or certified mail, postage prepaid. A party may change the address for giving notice by any method set forth in this Section. 19. No Joint Venture. Nothing in this Agreement shall, or shall be deemed or construed to, create or constitute any joint venture, partnership, agency, employment, or any other relationship between the City and Company nor to create any liability for one party with respect to the liabilities or obligations of the other party or any other person. 20. Amendment, Modification, and Waiver. No amendment, modification, or waiver of any condition, provision, or term of this Agreement shall be valid or of any effect unless made in writing, signed by the party or parties to be bound or by the duly authorized representative of same, and specifying with particularity the extent and nature of the amendment, modification, or waiver. Any waiver by any party of any default by another party shall not affect or impair any rights arising from any subsequent default. 21. Severability; Reformation. Each provision, section, sentence, clause, phrase, and word of this Agreement is intended to be severable. If any portion of this Agreement shall be deemed invalid or unenforceable, whether in whole or in part, the offending provision or part thereof shall be deemed severed from this Agreement and the remaining provisions of this Agreement shall not be affected thereby and shall continue in full force and effect. If, for any reason, a court finds that any portion of this Agreement is invalid or unenforceable as written, but that by limiting such provision or portion thereof it would become valid and enforceable, then such provision or portion thereof shall be deemed to be written, and shall be construed and enforced, as so limited. 22. Interpretation. This Agreement shall not be construed more strictly against one party than against the other merely by virtue of the fact that it may have been prepared by counsel for one of the parties, it being recognized that the parties hereto and their respective attorneys have contributed substantially and materially to the preparation of each and every provision of this Agreement. 23. Captions. All captions, headings, or titles in the paragraphs or sections of this Agreement are inserted only as a matter of convenience and/or reference, and they shall in no way be construed as limiting, extending, or describing either the scope or intent of this Agreement or of any provisions hereof. 24. Binding Effect. This Agreement shall be binding and shall inure to the benefit of the parties and their respective successors, assigns, and legal representatives. 25. Counterparts. This Agreement may be executed in one or more counterparts, each of which, including signed counterparts delivered by facsimile or other electronic means, shall be deemed an original and all of which, taken together, shall constitute one and the same instrument. 26. Entire Agreement. This Agreement, together with the exhibits attached hereto, constitutes the entire agreement of the parties and supersedes all prior or contemporaneous negotiations, discussions, understandings, or agreements, whether oral or written, with respect to the subject matter hereof. 27. Time of Essence. Time is of the essence of this Agreement. IN WITNESS WHEREOF, the parties have executed this Development Agreement by their duly authorized representatives as of the date first set forth above. CITY OF WATERLOO, IOWA IOWA HEARTLAND HABITAT FOR HUMANITY By: 67C1e/16/Z �(CGl E By: Quentin Hart, Mayor Ali Parrish, Executive Director Attest: Kelley Ee(ch(e Kelley Felchle, City Clerk EXHIBIT "A" Description of Properties 1. Parcel No. 8913-24-158-011 —The North Forty-seven (47) feet of the West Twenty (20) feet of Lot No. Five (5); and the North Forty-seven (47) feet of Lot No. Six (6), all in Block No. Twenty (20), in Railroad Addition to Waterloo, Iowa. 2. Parcel No. 8913-24-159-006 — Railroad Addition, Waterloo, the North 31 feet of the South 59 feet of Lot 7 in Block 21, the North 31 feet of the South 59 feet of the West 40 feet of Lot 8 in Block 21. 3. Parcel No. 8913-24-303-007 — East Half of the North 45 feet of lot No. 2 in Block No. 66 in the Cooley Addition to Waterloo, Iowa. (greenspace lot) 4. Parcel No. 8913-24-303-009 — Cooley Addition, Waterloo, the South 50 feet of lot 2 block 66 and the south 50 feet of the east 30 feet of lot 3 in Block 66. 5. Parcel No. 8913-24-303-018 — Cooley Addition, Waterloo, the West 30 feet of Lot 9 in Block 66. (greenspace lot) Preparer: Christopher S. Wendland, P.O. Box 596, Waterloo, Iowa 50704 (319) 234-5701 After recording, return to Community Planning & Development, 715 Mulberry Street, Waterloo, IA 50703. DEVELOPMENT AGREEMENT Octc3- 641Ivelopment Agreement (the "Agreement") is entered into as of , 2024 by and between Iowa Heartland Habitat for Humanity ("Company"), and the City of Waterloo, Iowa ("City"). RECITALS A. Company is willing and able to finance and construct or rehabilitate single- family dwellings and related improvements on various properties located in the City of Waterloo, including infill lots in established residential neighborhoods as identified on Exhibit "A" attached hereto (the "Properties"). Each separate property is referred to as a "Project Site." B. City considers infill residential development within the City a benefit to the community and is willing for the overall good and welfare of the community to provide financial incentives to encourage that goal. City believes that such development is in the vital and best interests of the City and in accordance with the public purposes and provisions of the applicable State and local laws and requirements under which the Project (defined below) is being undertaken and is being assisted. AGREEMENT NOW, THEREFORE, in consideration of the mutual covenants set forth herein, the parties agree as follows: 1. Sale of Property; Title. Subject to the terms hereof, City shall convey the Properties to Company for the sum of $1.00 (the "Purchase Price"). Conveyance shall be by quit claim deed, free and clear of all encumbrances arising by or through City except: (a) easements, servitudes, conditions and restrictions of record; (b) current and future real estate real property taxes and assessments subject to the agreements made herein; (c) general utility and right-of-way easements serving the Property; and (d) restrictions imposed by the City zoning ordinances and other applicable law. Company may, at its own expense, obtain whatever form of title evidence it desires. If title is unmarketable or subject to matters not acceptable to Company, and if City does not remedy or remove such objectionable matters in timely fashion following written notice of such objections from Company, Company may terminate this Agreement without further obligation. City shall provide any title documents it has in its possession, including any abstracts, to assist in title review. 2. Improvements by Company. Company acknowledges that it has had a reasonable opportunity to inspect each of the Properties and to conduct other due diligence related to the Project. Company agrees to accept the Properties in their "AS IS" condition, without any warranty from City, expressed or implied, as to the condition of each Property, its marketability, or its fitness for any particular purpose. At its own expense Company shall construct upon each Project Site one (1) single-family home as further described and depicted in plan to be submitted to City, except that with respect to parcels 8913-24-303-007 and 8913-24-303-018 Company shall maintain such Properties as greenspace in accordance with City ordinances until such time as it chooses to build a new dwelling thereon. No more than one home shall be constructed on each Project Site, and each Project Site upon which a home will be constructed shall be completed to a finished state, including installation of sidewalks, driveways and garages, removal of all construction debris, proper leveling or shaping of groundscape, and grassing and/or landscaping (construction and finishing as so described are referred to as the "Improvements"). The Improvements shall be constructed in accordance with the terms of this Agreement, all applicable City, state, and federal building codes and shall comply with all applicable City ordinances and other applicable law. Company shall submit specific plans, building designs and site plans for City review and approval before the commencement of construction and shall not substantially deviate from such plans, specifications or designs. Company will use its best efforts to obtain, or cause to be obtained, in a timely manner, all required permits, licenses and approvals, and will meet, in a timely manner, all requirements of all applicable local, state, and federal laws and regulations which must be obtained or met before the Improvements may be lawfully constructed. The Properties, the Improvements, and all site preparation and development -related work to be undertaken and completed by Company under this Agreement are collectively referred to as the "Project." 3. Timeliness of Construction; Possibility of Reverter. The parties agree that Company's commitment to cause the Project to be undertaken and to construct the Improvements in a timely manner constitutes a material inducement for the City to convey the Properties to Company and to extend the incentives provided for in this Agreement, and that without said commitment City would not do so. A. Deadlines to commence and complete. Subject to Unavoidable Delays (defined below), Company must Substantially Complete construction within two (2) years from the date that the Properties are conveyed to Company (the "Completion Deadline"). For purposes of this Agreement, "Substantially Complete" means the date on which the Improvements on a Project Site have been completed to the extent necessary for the City to issue a certificate of occupancy relating thereto and the City has verified that Project elements for which no permit was necessary have been substantially completed. All deadlines are subject to Unavoidable Delays as defined in paragraph B below. The City's Community Planning and Development Director may, but shall not be required to, consent to an extension of time of up to six (6) months for the construction of any phase of the Improvements. Any additional or longer time extensions will require consent of the City Council. The provisions of this Section 3 shall apply separately to each Project Site. B. Events triggerinq termination and/or reverter of title. If Company does not begin or Substantially Complete construction of the Improvements at a Project Site on the schedule stated above, subject to Unavoidable Delays, then City may terminate this Agreement with respect to such Project Site as set forth in Section 13, and City shall then have no further obligation to Company under this Agreement with respect to such Project Site. If development has commenced within the required period, as the same may be extended, and is subsequently stopped or delayed as a result of an act of God, war, civil disturbance, court order, labor dispute, fire, or other cause beyond the reasonable control of Company (each an "Unavoidable Delay"), the requirement that construction be completed by the Completion Deadline shall be tolled for a period of time equal to the period of Unavoidable Delay. As promptly as possible, Company shall notify City in writing of the occurrence of any Unavoidable Delay and shall again notify City in writing when the Unavoidable Delay has ended. If City terminates this Agreement with respect to a Project Site as provided in Section 13, City shall have no further obligations to Company under this Agreement, including but not limited to any legal or equitable obligation to reimburse Company for any costs expended by Company with respect to the Project Site or to compensate Company for any value added to the Project Site by any Improvements. In connection with termination of the Agreement as set forth herein, City may demand reconveyance of any Project Site on which Improvements have not been Substantially Completed, in addition to exercising any other available remedies. 4. Reverter of Title; Indemnity. In the event of any reverter of title pursuant to Section 3, Company agrees that it shall, at its own expense, promptly execute all documents, including but not limited to a special warranty deed, or take such other actions as the City may reasonably request to effectuate said reverter and to deliver to City title to the Project Site free and clear of any lien, claim, charge, security interest, mortgage or encumbrance (collectively, "Liens") arising by or through Company. Company shall pay in full, so as to discharge or satisfy, all Liens on or against the Project Site. In connection with any reverter of title, Company shall not be entitled to a refund of the Purchase Price. Appointment of Attorney in Fact: If Company fails to deliver such documents, including but not limited to a special warranty deed, to City within thirty (30) days after written demand by City, then City shall be authorized to execute, on Company's behalf and as its attorney -in -fact, the special warranty deed or other documents required by this Section, and for such limited purpose Company does hereby constitute and appoint City as its attorney -in -fact. Company further agrees that it shall indemnify City and hold it harmless with respect to any demand, claim, cause of action, damage, cost, expense, liability or injury made, suffered, or incurred as a result of or in connection with the Project, or Company's failure to carry on or complete same, or any Lien or Liens on or against the Project Site of any type or nature whatsoever that attaches to the Project Site by virtue of Company's ownership of same. If City files suit to enforce the terms of this Agreement and prevails in such suit, then Company shall be liable for all legal expenses, including but not limited to reasonable attorneys' fees, incurred by City. Company's duties of indemnity pursuant to this Section shall survive the expiration, termination or cancellation of this Agreement for any reason. 5. Utilities. Company will be responsible for extending water, sewer, telephone, telecommunications, electricity, gas and other utility services from street right of way to any location on a Project Site and for payment of any associated connection fees. 6. City Incentives. To aid the Project, City agrees to provide the following assistance: A. Infill Housing Grant. As provided in the City's infill housing policy, City will pay Company a grant of $5,000.00 within thirty (30) days after Company has Substantially Completed the Improvements on a Project Site and has obtained final inspection on all permits obtained for Improvements on that Project Site. The maximum incentive payable to Company is $10,000.00. 7. No Encumbrances; Limited Exception. Until the Improvements are Substantially Completed, Company agrees that it shall not create, incur, or suffer to exist any Liens on any of the Properties, other than such mortgage or mortgages as may be reasonably necessary to finance Company's completion of the Improvements and of which Company notifies City before Company executes any such mortgage. Company may not mortgage a Project Site or any part thereof for any purpose except in connection with financing of the Improvements upon such Project Site. Any other mortgage shall be void. 8. No Assignment or Conveyance. Company agrees that it will not sell, convey, assign or otherwise transfer, in whole or in part, its interest in any Project Site prior to completion of the Project thereon, to any other person or entity without the prior written consent of City. Reasonable grounds for the City to withhold its consent shall include but are not limited to the inability of the proposed transferee to demonstrate to the City's satisfaction that it has the financial ability to observe all of the terms to be performed by Company under this Agreement. 9. Additional Covenants of Company. In addition to the other promises, covenants and agreements of Company as provided elsewhere in this Agreement, Company agrees as follows: A. Until the Improvements have been Substantially Completed, Company shall make such reports to City, in such detail and at such times as may be reasonably requested by City, as to the actual progress of Company with respect to construction of the Improvements. B. Company will comply with all applicable land development laws and City and county ordinances, and all laws, rules and regulations relating to its businesses, other than laws, rules and regulations where the failure to comply with the same, or where the sanctions and penalties resulting therefrom, would not have a material adverse effect on the business, property, operations, or condition, financial or otherwise, of Company. C. Company will cooperate fully with the City in resolution of any traffic, parking, trash removal or public safety problems which may arise in connection with the construction and operation of the Improvements. D. Company agrees during construction of the Improvements to maintain, as applicable, builder's risk, property damage, and liability insurance coverages with respect to the Improvements in such amounts as are customarily carried by like companies engaged in activities of comparable size and liability exposure, and shall provide evidence of such coverages to the City upon request. 10. Representations and Warranties of City. City hereby represents and warrants as follows: A. City is not prohibited from consummating the transaction contemplated in this Agreement by any law, regulation, agreement, instrument, restriction, order or judgment. B. Each person who executes and delivers this Agreement and all documents to be delivered hereunder is and shall be authorized to do so on behalf of City. 11. Representations and Warranties of Company. Company hereby represents and warrants as follows: A. It is duly organized, validly existing, and in good standing under the laws of the state of its organization and is duly qualified and in good standing under the laws of the State of Iowa. B. It has all requisite power and authority to own and operate its properties, to carry on its business as now conducted and as presently proposed to be conducted, and to enter into and perform its obligations under this Agreement. C. This Agreement has been duly and validly authorized, executed and delivered by Company and, assuming due authorization, execution and delivery by the other parties hereto, is in full force and effect and is a valid and legally binding instrument of Company that is enforceable in accordance with its terms, except as the same may be limited by bankruptcy, insolvency, reorganization or other laws relating to or affecting creditors' rights generally. D. The execution and delivery of this Agreement, the consummation of the transactions contemplated hereby, and the fulfillment of or compliance with the terms and conditions of this Agreement are not prevented by, limited by, in conflict with, or result in a violation or breach of, the terms, conditions or provisions of the articles of organization or operating agreement of Company or of any contractual restriction, evidence of indebtedness, agreement or instrument of whatever nature to which Company is now a party or by which it or its property is bound, nor do they constitute a default under any of the foregoing. E. There are no actions, suits or proceedings pending or threatened against or affecting Company in any court or before any arbitrator or before or by any governmental body in which there is a reasonable possibility of an adverse decision which could materially adversely affect the business (present or prospective), financial position, or results of operations of Company or which in any manner raises any questions affecting the validity of the Agreement or Company's ability to perform its obligations under this Agreement. 12. Default. The following shall be "Events of Default" under this Agreement, and the term "Event of Default" shall mean any one or more of the following events that continues beyond any applicable cure periods: A. Failure by Company to cause the Improvements to be commenced and completed pursuant to the terms, conditions and limitations of this Agreement; B. Transfer by Company of any interest (either directly or indirectly) in the Improvements, the Properties, or this Agreement, without the prior written consent of City, except as expressly authorized by this Agreement; C. Failure by any party hereto to substantially observe or perform any covenant, condition, obligation or agreement on its part to be observed or performed under this Agreement; D. Company (1) files any petition in bankruptcy or for any reorganization, arrangement, composition, readjustment, liquidation, dissolution, or similar relief under the federal bankruptcy law or any similar state law; (2) makes an assignment for the benefit of its creditors; (3) admits in writing its inability to pay its debts generally as they become due; (4) is adjudicated a bankrupt or insolvent; or if a petition or answer proposing the adjudication of Company as a bankrupt or its reorganization under any present or future federal bankruptcy act or any similar federal or state law shall be filed in any court and such petition or answer shall not be discharged or denied within ninety (90) days after the filing thereof; or a receiver, trustee or liquidator of Company, or part thereof, shall be appointed in any proceedings brought against Company and shall not be discharged within ninety (90) days after such appointment, or if Company shall consent to or acquiesce in such appointment; or (5) defaults under any mortgage applicable to the Property; or E. Any representation or warranty made by Company in this Agreement, or made by Company in any written statement or certificate furnished by Company pursuant to this Agreement, shall prove to have been incorrect, incomplete or misleading in any material respect on or as of the date of the issuance or making thereof. 13. Remedies. A. Default by Company. Whenever any Event of Default in respect of Company occurs and is continuing, the City may terminate this Agreement, in whole or as to any particular Project Site. Before exercising such remedy, City shall give 30 days' written notice to Company of the Event of Default, provided that by the conclusion of such period the Event of Default shall not have been cured, or the Event of Default cannot reasonably be cured within 30 days and Company shall not have provided assurances reasonably satisfactory to the City that the Event of Default will be cured as soon as reasonably possible. Upon termination, City may exercise any and all remedies available at law, equity, contract or otherwise for recovery of any sums paid by City to Company before the date of termination or to recover ownership of Project Sites as set forth in this Agreement. B. Default by City. Whenever any Event of Default in respect of City occurs and is continuing, Company may take such action against City to require it to specifically perform its obligations hereunder. Before exercising such remedy, Company shall give 30 days' written notice to City of the Event of Default, provided that by the conclusion of such period the Event of Default shall not have been cured, or if the Event of Default cannot reasonably be cured within 30 days and City shall not have provided assurances reasonably satisfactory to the Company that the Event of Default will be cured as soon as reasonably possible. C. Remedies under this Agreement shall be cumulative and in addition to any other right or remedy given under this Agreement or existing at law or in equity or by statute. Waiver as to any particular default, or delay or omission in exercising any right or power accruing upon any default, shall not be construed as a waiver of any other or any subsequent default and shall not impair any such right or power. 14. Indemnification and Releases. A. Company hereby releases City, its elected officials, officers, employees, and agents (collectively, the "indemnified parties") from, covenants and agrees that the indemnified parties shall not be liable for, and agrees to indemnify, defend and hold harmless the indemnified parties against, any loss or damage to property or any injury to or death of any person occurring at or about the Properties arising after Company's acquisition of same or resulting from any defect in the Improvements. The indemnified parties shall not be liable for any damage or injury to the persons or property of Company or its directors, officers, employees, contractors or agents, or any other person who may be on or about the Properties or the Improvements, due to any act of negligence or willful misconduct of any person, other than any act of negligence or willful misconduct on the part of any such indemnified party or its officers, employees or agents. B. Except for any willful misrepresentation, any willful misconduct, or any unlawful act of the indemnified parties, Company agrees to protect and defend the indemnified parties, now or forever, and further agrees to hold the indemnified parties harmless, from any claim, demand, suit, action or other proceedings or any type or nature whatsoever, by any person or entity whatsoever that arises or purportedly arises from (1) any violation of any agreement or condition of this Agreement (except with respect to any suit, action, demand or other proceeding brought by Company against the City to enforce its rights under this Agreement), or (2) the acquisition and condition of the Properties and the construction, installation, ownership, and operation of the Improvements, or (3) otherwise as a result of or in connection with the Project or Company's failure to carry on or complete same. C. The indemnification obligations under this Section shall include attorneys' fees and expenses incurred by any indemnified party. The provisions of this Section shall survive the expiration or termination of this Agreement. 15. Materiality of Company's Promises, Covenants, Representations, and Warranties. Each and every promise, covenant, representation, and warranty set forth in this Agreement on the part of Company to be performed is a material term of this Agreement, and each and every such promise, covenant, representation, and warranty constitutes a material inducement for City to enter this Agreement. Company acknowledges that without such promises, covenants, representations, and warranties, City would not have entered this Agreement. Upon breach of any promise or covenant, or in the event of the incorrectness or falsity of any representation or warranty, City may, at its sole option and in addition to any other right or remedy available to it, terminate this Agreement and declare it null and void. 16. Performance by City. Company acknowledges and agrees that all of the obligations of City under this Agreement shall be subject to, and performed by City in accordance with, all applicable statutory, common law or constitutional provisions and procedures consistent with City's lawful authority. All covenants, stipulations, promises, agreements and obligations of City contained in this Agreement shall be deemed to be the covenants, stipulations, promises, agreements and obligations of City and not of any governing body member, officer, employee or agent of City in the individual capacity of such person. 17. No Third -Party Beneficiaries. No rights or privileges of any party hereto shall inure to the benefit of any contractor, subcontractor, material supplier, or any other person or entity, and no such contractor, subcontractor, material supplier, or other person or entity shall be deemed to be a third -party beneficiary of any of the provisions of this Agreement. 18. Notices. Any notice under this Agreement shall be in writing and shall be delivered in person, by overnight air courier service, by United States registered or certified mail, postage prepaid, or by facsimile (with an additional copy delivered by one of the foregoing means), and addressed: (a) if to City, at 715 Mulberry Street, Waterloo, Iowa 50703, Attention: Mayor, with copies to the Community Planning and Development Director. (b) if to Company, at 803 W. 5th Street, Waterloo, Iowa 50702, Attention: Executive Director. Delivery of notice shall be deemed to occur (i) on the date of delivery when delivered in person, (ii) one (1) business day following deposit for overnight delivery to an overnight air courier service which guarantees next day delivery, or (iii) three (3) business days following the date of deposit if mailed by United States registered or certified mail, postage prepaid. A party may change the address for giving notice by any method set forth in this Section. 19. No Joint Venture. Nothing in this Agreement shall, or shall be deemed or construed to, create or constitute any joint venture, partnership, agency, employment, or any other relationship between the City and Company nor to create any liability for one party with respect to the liabilities or obligations of the other party or any other person. 20. Amendment, Modification, and Waiver. No amendment, modification, or waiver of any condition, provision, or term of this Agreement shall be valid or of any effect unless made in writing, signed by the party or parties to be bound or by the duly authorized representative of same, and specifying with particularity the extent and nature of the amendment, modification, or waiver. Any waiver by any party of any default by another party shall not affect or impair any rights arising from any subsequent default. 21. Severability; Reformation. Each provision, section, sentence, clause, phrase, and word of this Agreement is intended to be severable. If any portion of this Agreement shall be deemed invalid or unenforceable, whether in whole or in part, the offending provision or part thereof shall be deemed severed from this Agreement and the remaining provisions of this Agreement shall not be affected thereby and shall continue in full force and effect. If, for any reason, a court finds that any portion of this Agreement is invalid or unenforceable as written, but that by limiting such provision or portion thereof it would become valid and enforceable, then such provision or portion thereof shall be deemed to be written, and shall be construed and enforced, as so limited. 22. Interpretation. This Agreement shall not be construed more strictly against one party than against the other merely by virtue of the fact that it may have been prepared by counsel for one of the parties, it being recognized that the parties hereto and their respective attorneys have contributed substantially and materially to the preparation of each and every provision of this Agreement. 23. Captions. All captions, headings, or titles in the paragraphs or sections of this Agreement are inserted only as a matter of convenience and/or reference, and they shall in no way be construed as limiting, extending, or describing either the scope or intent of this Agreement or of any provisions hereof. 24. Binding Effect. This Agreement shall be binding and shall inure to the benefit of the parties and their respective successors, assigns, and legal representatives. 25. Counterparts. This Agreement may be executed in one or more counterparts, each of which, including signed counterparts delivered by facsimile or other electronic means, shall be deemed an original and all of which, taken together, shall constitute one and the same instrument. 26. Entire Agreement. This Agreement, together with the exhibits attached hereto, constitutes the entire agreement of the parties and supersedes all prior or contemporaneous negotiations, discussions, understandings, or agreements, whether oral or written, with respect to the subject matter hereof. 27. Time of Essence. Time is of the essence of this Agreement. IN WITNESS WHEREOF, the parties have executed this Development Agreement by their duly authorized representatives as of the date first set forth above. CITY OF WATERLOO, IOWA By: 62ue/Hin CGI'E Quentin Hart, Mayor Attest: Kelley Felclile GIGIIAILY SIGNED Kelley Felchle, City Clerk IOWA HEARTLAND HABITAT FOR HUMANITY -YQ DIGITALLYf^' SIGNED By: Ali Parrish, Executive Director EXHIBIT "A" Description of Properties 1. Parcel No. 8913-24-158-011 — The North Forty-seven (47) feet of the West Twenty (20) feet of Lot No. Five (5); and the North Forty-seven (47) feet of Lot No. Six (6), all in Block No. Twenty (20), in Railroad Addition to Waterloo, Iowa. 2. Reserved. 3. Parcel No. 8913-24-303-007 — East Half of the North 45 feet of lot No. 2 in Block No. 66 in the Cooley Addition to Waterloo, Iowa. (greenspace lot) 4. Parcel No. 8913-24-303-009 — Cooley Addition, Waterloo, the South 50 feet of lot 2 black 66 and the south 50 feet of the east 30 feet of lot 3 in Block 66. 5. Parcel No. 8913-24-303-018 — Cooley Addition, Waterloo, the West 30 feet of Lot 9 in Block 66. (greenspace lot)