Loading...
HomeMy WebLinkAboutRock Star Real Estate DA (RECORDED) 1027 W 3rd and 128 Lincoln 1-06-252025-02368 RECORDED: 02/ 20/ 2025 02:44:35 PM RECORDING FEE: $62.00 REVENUE TAX: § COMBINED FEE: $62.00 SANDIE L. SMITH, RECORDER BLACK HAWK COUNTY, IOWA Preparer: Christopher S. Wendland, P.O. Box 596, Waterloo, Iowa 50704 (319) 234-5701 After recording, return to Community Planning & Development, 715 Mulberry Street, Waterloo, IA 50703. DEVELOPMENT AGREEMENT 1 Ibis Develop�??� greement (the "Agreement") is entered into as of by and between Rock Star Real Estate, L.L.C. ("Developer"), and the City of Waterloo, Iowa ("City"). RECITALS A. Developer is willing and able to finance and rehabilitate existing properties owned by City that are located at 1027 W. 3rd St, Waterloo, Iowa, and 128 Lincoln St., Waterloo, Iowa (the "Properties"), legally described as set forth on Exhibit "A" attached hereto. B. City considers development within the City a benefit to the community and is willing for the overall good and welfare of the community to provide financial incentives so as to encourage that goal. City believes that rehabilitation of the Properties is in the best interests of the City and in accordance with the public purposes and provisions of the applicable State and local laws and requirements under which the project has been undertaken and is being assisted. AGREEMENT NOW, THEREFORE, in consideration of the mutual covenants set forth herein, the parties agree as follows: 1. Sale of Property; Title. Subject to the terms hereof, City shall convey the Properties to Developer for the aggregate sum of $25,200.00 (the "Purchase Price") (allocated as $20,100.00 for 1027 W. 3rd Street and $5,100.00 for 128 Lincoln Street), of which $2,000.00 shall be paid in certified funds to City to be held in trust as earnest money and applied at closing to the Purchase Price. Conveyance shall be by quit claim deed, free and clear of all encumbrances arising by or through City except: (a) easements, servitudes, conditions and restrictions of record; (b) current and future real estate real property taxes and assessments subject to the agreements made herein; (c) general utility and right-of-way easements serving the Properties; and (d) restrictions imposed by the City zoning ordinances and other applicable law. City shall have no duty to convey title to Developer until Developer delivers to City reasonable and satisfactory proof of financial ability to undertake and carry on the Project (defined below), which may take the form of a lending commitment letter. Developer may, at its own expense, obtain whatever form of title evidence it desires. If title is unmarketable or subject to matters not acceptable to Developer, and if City does not remedy or remove such objectionable matters in timely fashion following written notice of such objections from Developer, Developer may terminate this Agreement, in which case City shall refund the earnest money to Developer as promptly as possible. City shall provide any title documents it has in its possession, including any abstracts, to assist in title review. 2. Improvements by Developer. Developer acknowledges that it has had a reasonable opportunity to inspect the Properties and to conduct other due diligence related to the Project. Developer agrees to accept the Properties in their "AS IS" condition, without any warranty from City, expressed or implied, as to the condition of the Properties, their marketability, or their fitness for any particular purpose. At its own cost Developer shall (a) remove and properly dispose of all debris and unwanted personal property from the dwellings, (b) renovate the existing structures to a finished state for single-family residential purposes, and (c) make other improvements to the buildings and grounds, including but not limited to sidewalk, and shall be responsible for removal of all construction debris, proper leveling or shaping of groundscape, and grassing and/or landscaping (construction and finishing as so described are referred to collectively as the "Improvements"). The Improvements shall be constructed in accordance with the terms of this Agreement, all applicable City, state, and federal building codes and shall comply with all applicable City ordinances and other applicable law. Developer shall submit specific plans, building designs and site plans for City review and approval before the commencement of construction and shall not substantially deviate from such plans, specifications or designs. Developer will use its best efforts to obtain, or cause to be obtained, in a timely manner, all required permits, licenses and approvals, and will meet, in a timely manner, all requirements of all applicable local, state, and federal laws and regulations which must be obtained or met before the Improvements may be lawfully constructed, including but not limited to all final permit inspections. The Properties, the Improvements, and all other work to make the project site usable for Developer's purposes as contemplated by this Agreement are collectively referred to as the "Project." 3. Timeliness of Construction; Possibility of Reverter. The parties agree that Developer's commitment to cause the Project to be undertaken and to renovate the Properties and complete the Improvements in a timely manner constitutes a material inducement for the City to sell the Properties to Developer and to extend the incentives provided for in this Agreement, and that without said commitment City would not do so. A. Deadlines to commence and complete. Subject to Unavoidable Delays (defined below), Developer must obtain a building permit and begin 2 renovation of one of the dwellings within six (6) months after the date of conveyance of title (the "Start Date") and must Substantially Complete construction of Improvements within eighteen (18) months after the last date of conveyance (the "Completion Deadline"). For purposes of this Agreement, "Substantially Complete" means the date on which the Improvements have been completed to the extent necessary for the City to issue a certificate of occupancy relating thereto and the City has verified that Project elements for which no permit was necessary have been Substantially Completed. All deadlines are subject to Unavoidable Delays as defined in paragraph B below. The City's Community Planning and Development Director may, but shall not be required to, consent to an extension of time of up to six (6) months for construction of the Improvements. Any additional or longer time extensions will require consent of the City Council. B. Events triggering termination and/or reverter. If Developer does not begin or Substantially Complete construction of the Improvements on the schedule(s) stated above, subject to Unavoidable Delays, then City may terminate this Agreement as set forth in Section 12, and City shall then have no further obligation to Developer under this Agreement. If development has commenced within the required period, as the same may be extended, and is subsequently stopped or delayed as a result of an act of God, war, civil disturbance, court order, labor dispute, fire, or other cause beyond the reasonable control of Developer (each an "Unavoidable Delay"), the requirement that construction be completed by the Completion Deadline shall be tolled for a period of time equal to the period of Unavoidable Delay. As promptly as possible, Developer shall notify City in writing of the occurrence of any Unavoidable Delay and shall again notify City in writing when the Unavoidable Delay has ended. If City terminates this Agreement as provided in Section 12, City shall have no further obligations to Developer under this Agreement, including but not limited to any legal or equitable obligation to reimburse Developer for any costs expended by Developer with respect to the Project or to compensate Developer for any value added to the Properties by any Improvements or to refund the Purchase Price in whole or in part. In connection with termination of the Agreement as set forth herein, City may demand reconveyance of the Property in addition to exercising any other available remedies. 4. Reverter of Title; Indemnity. In the event of any reverter of title, Developer agrees that it shall, at its own expense, promptly execute all documents, including but not limited to a special warranty deed, or take such other actions as the City may reasonably request to effectuate said reverter and to deliver to City title to the Properties that is free and clear of any lien, claim, charge, security interest, mortgage or encumbrance (collectively, "Liens") arising by or through Developer. Developer shall pay in full, so as to discharge or satisfy, all Liens on or against either of the Properties. In connection with any reverter of title, Developer shall not be entitled to a refund of the Purchase Price. Appointment of Attorney in Fact: If Developer fails to deliver such 3 documents, including but not limited to a special warranty deed, to City within thirty (30) days after written demand by City, then City shall be authorized to execute, on Developer's behalf and as its attorney -in -fact, the special warranty deed required by this Section, and for such limited purpose Developer does hereby constitute and appoint City as its attorney -in -fact. Developer further agrees that it shall indemnify City and hold it harmless with respect to any demand, claim, cause of action, damage, cost, expense, liability or injury made, suffered, or incurred as a result of or in connection with the Project, or Developer's failure to carry on or complete same, or any Lien or Liens on or against either of the Properties of any type or nature whatsoever that attaches to either of the Properties by virtue of Developer's ownership of same. If City files suit to enforce the terms of this Agreement and prevails in such suit, then Developer shall be liable for all legal expenses, including but not limited to reasonable attorneys' fees, incurred by City. Developer's duties of indemnity pursuant to this Section shall survive the expiration, termination or cancellation of this Agreement for any reason. 4.1. Utilities. Developer will be responsible for obtaining or extending water, sewer, telephone, telecommunications, electricity, gas and other utility services from street right of way to any location on the Properties and for payment of any associated connection fees. 5. City Incentives. To aid the Project, City agrees to provide the following assistance: A. Partial Purchase Price Refund. Within thirty (30) days after Developer has Substantially Completed the Improvements and has obtained final inspection on all permits obtained for the Project, City will refund $10,000.00 of the Purchase Price to Developer. B. Grant. Concurrently with partial refund of the Purchase Price pursuant to paragraph A above, City will make a $10,000.00 infill housing incentive grant to Developer within thirty (30) days after the Improvements are Substantially Completed. 6. No Encumbrances; Limited Exception. Until the Improvements are Substantially Completed, Developer agrees that it shall not create, incur, or suffer to exist any Liens on the Properties, other than such mortgage or mortgages as may be reasonably necessary to finance Developer's completion of the Improvements and of which Developer notifies City before Developer executes any such mortgage. Developer may not mortgage the Properties or any part thereof for any purpose except in connection with financing of the Improvements. Any mortgage in violation of this Section shall be void. 7. No Assignment or Conveyance. Developer agrees that it will not sell, convey, assign or otherwise transfer its interest in the Properties prior to completion of 4 the Project, whether in whole or in part, to any other person or entity without the prior written consent of City. Reasonable grounds for the City to withhold its consent shall include but are not limited to the inability of the proposed transferee to demonstrate to the City's satisfaction that it has the financial ability to observe all of the terms to be performed by Developer under this Agreement. 8. Additional Covenants of Developer. In addition to the other promises, covenants and agreements of Developer as provided elsewhere in this Agreement, Developer agrees as follows: A. Until the Improvements have been Substantially Completed, Developer shall make such reports to City, in such detail and at such times as may be reasonably requested by City, as to the actual progress of Developer with respect to construction of the Improvements. B. Developer will comply with all applicable land development laws and City and county ordinances, and all laws, rules and regulations relating to its businesses, other than laws, rules and regulations where the failure to comply with the same, or where the sanctions and penalties resulting therefrom, would not have a material adverse effect on the business, property, operations, or condition, financial or otherwise, of Developer. C. Developer will cooperate fully with the City in resolution of any traffic, parking, trash removal or public safety problems which may arise in connection with the construction and operation of the Improvements. D. Developer shall make no sale or conveyance of the Properties or any portion thereof without City's prior written consent. 9. Representations and Warranties of City. City hereby represents and warrants as follows: A. City is not prohibited from consummating the transaction contemplated in this Agreement by any law, regulation, agreement, instrument, restriction, order or judgment. B. Each person who executes and delivers this Agreement and all documents to be delivered hereunder is and shall be authorized to do so on behalf of City. 10. Representations and Warranties of Developer. Developer hereby represents and warrants as follows: A. It has all requisite power and authority to own and operate its properties, to carry on its business as now conducted and as presently proposed 5 to be conducted, and to enter into and perform its obligations under this Agreement. B. This Agreement has been duly and validly authorized, executed and delivered by Developer and, assuming due authorization, execution and delivery by the other parties hereto, is in full force and effect and is a valid and legally binding instrument of Developer that is enforceable in accordance with its terms, except as the same may be limited by bankruptcy, insolvency, reorganization or other laws relating to or affecting creditors' rights generally. C. The execution and delivery of this Agreement, the consummation of the transactions contemplated hereby, and the fulfillment of or compliance with the terms and conditions of this Agreement are not prevented by, limited by, in conflict with, or result in a violation or breach of, any contractual restriction, evidence of indebtedness, agreement or instrument of whatever nature to which Developer is now a party or by which it or its property is bound, nor do they constitute a default under any of the foregoing. D. There are no actions, suits or proceedings pending or threatened against or affecting Developer in any court or before any arbitrator or before or by any governmental body in which there is a reasonable possibility of an adverse decision which could materially adversely affect the business (present or prospective) or financial position of Developer or which in any manner raises any questions affecting the validity of the Agreement or Developer's ability to perform its obligations under this Agreement. 11. Default. The following shall be "Events of Default" under this Agreement, and the term "Event of Default" shall mean any one or more of the following events that continues beyond any applicable cure periods: A. Failure by Developer to cause the Improvements to be commenced and completed pursuant to the terms, conditions and limitations of this Agreement; B. Transfer by Developer of any interest (either directly or indirectly) in the Improvements, the Properties, or this Agreement, without the prior written consent of City, except as expressly authorized by this Agreement; C. Failure by any party hereto to substantially observe or perform any covenant, condition, obligation or agreement on its part to be observed or performed under this Agreement; D. Any representation or warranty made by Developer in this Agreement, or made by Developer in any written statement or certificate furnished by Developer pursuant to this Agreement, shall prove to have been 6 incorrect, incomplete or misleading in any material respect on or as of the date of the issuance or making thereof; E. Developer (1) files any petition in bankruptcy or for any reorganization, arrangement, composition, readjustment, liquidation, dissolution, or similar relief under the federal bankruptcy law or any similar state law; (2) makes an assignment for the benefit of its creditors; (3) admits in writing its inability to pay its debts generally as they become due; (4) is adjudicated a bankrupt or insolvent; or if a petition or answer proposing the adjudication of Developer as a bankrupt or its reorganization under any present or future federal bankruptcy act or any similar federal or state law shall be filed in any court and such petition or answer shall not be discharged or denied within ninety (90) days after the filing thereof; or a receiver, trustee or liquidator of Developer, or part thereof, shall be appointed in any proceedings brought against Developer and shall not be discharged within ninety (90) days after such appointment, or if Developer shall consent to or acquiesce in such appointment; or (5) defaults under any mortgage applicable to the Properties. 12. Remedies. A. Default by Developer. Whenever any Event of Default in respect of Developer occurs and is continuing, the City may terminate this Agreement. Before exercising such remedy, City shall give 30 days' written notice to Developer of the Event of Default, provided that by the conclusion of such period the Event of Default shall not have been cured, or the Event of Default cannot reasonably be cured within 30 days and Developer shall not have provided assurances reasonably satisfactory to the City that the Event of Default will be cured as soon as reasonably possible. Upon termination, City may exercise any and all remedies available at law, equity, contract or otherwise to recover ownership of the Properties as set forth in this Agreement. B. Default by City. Whenever any Event of Default in respect of City occurs and is continuing, Developer may take such action against City to require it to specifically perform its obligations hereunder. Before exercising such remedy, Developer shall give 30 days' written notice to City of the Event of Default, provided that by the conclusion of such period the Event of Default shall not have been cured, or if the Event of Default cannot reasonably be cured within 30 days and City shall not have provided assurances reasonably satisfactory to the Developer that the Event of Default will be cured as soon as reasonably possible. C. Remedies under this Agreement shall be cumulative and in addition to any other right or remedy given under this Agreement or existing at law or in equity or by statute. Waiver as to any particular default, or delay or omission in exercising any right or power accruing upon any default, shall not be construed 7 as a waiver of any other or any subsequent default and shall not impair any such right or power. 13. Indemnification and Releases. A. Developer hereby releases City, its elected officials, officers, employees, and agents (collectively, the "indemnified parties") from, covenants and agrees that the indemnified parties shall not be liable for, and agrees to indemnify, defend and hold harmless the indemnified parties against, any loss or damage to properties or any injury to or death of any person occurring at or about the Properties or resulting from any defect in the Improvements. The indemnified parties shall not be liable for any damage or injury to the persons or property of Developer or its employees, contractors or agents, or any other person who may be on or about the Properties or the Improvements, due to any act of negligence or willful misconduct of any person, other than any act of negligence or willful misconduct on the part of any such indemnified party or its officers, employees or agents. B. Except for any willful misrepresentation, any willful misconduct, or any unlawful act of the indemnified parties, Developer agrees to protect and defend the indemnified parties, now or forever, and further agrees to hold the indemnified parties harmless, from any claim, demand, suit, action or other proceedings or any type or nature whatsoever, by any person or entity whatsoever that arises or purportedly arises from (1) any violation of any agreement or condition of this Agreement (except with respect to any suit, action, demand or other proceeding brought by Developer against the City to enforce its rights under this Agreement), or (2) the acquisition and condition of the Properties and the construction, installation, ownership, and operation of the Improvements, or (3) otherwise as a result of or in connection with the Project or Developer's failure to carry on or complete same. C. The indemnification obligations under this Section shall include attorneys' fees and expenses incurred by any indemnified party. The provisions of this Section shall survive the expiration or termination of this Agreement. 14. Materiality of Developer's Promises, Covenants, Representations, and Warranties. Each and every promise, covenant, representation, and warranty set forth in this Agreement on the part of Developer to be performed is a material term of this Agreement, and each and every such promise, covenant, representation, and warranty constitutes a material inducement for City to enter this Agreement. Developer acknowledges that without such promises, covenants, representations, and warranties, City would not have entered this Agreement. Upon breach of any promise or covenant, or in the event of the incorrectness or falsity of any representation or warranty, City may, at its sole option and in addition to any other right or remedy available to it, terminate this Agreement and declare it null and void. 8 15. Performance by City. Developer acknowledges and agrees that all of the obligations of City under this Agreement shall be subject to, and performed by City in accordance with, all applicable statutory, common law or constitutional provisions and procedures consistent with City's lawful authority. All covenants, stipulations, promises, agreements and obligations of City contained in this Agreement shall be deemed to be the covenants, stipulations, promises, agreements and obligations of City and not of any governing body member, officer, employee or agent of City in the individual capacity of such person. 16. No Third -Party Beneficiaries. No rights or privileges of any party hereto shall inure to the benefit of any contractor, subcontractor, material supplier, or any other person or entity, and no such contractor, subcontractor, material supplier, or other person or entity shall be deemed to be a third -party beneficiary of any of the provisions of this Agreement. 17. Notices. Any notice under this Agreement shall be in writing and shall be delivered in person, by overnight air courier service, by United States registered or certified mail, postage prepaid, or by facsimile (with an additional copy delivered by one of the foregoing means), and addressed: (a) if to City, at 715 Mulberry Street, Waterloo, Iowa 50703, fax number 319-291-4571, Attention: Mayor, with copies to the City Attorney and the Community Planning and Development Director. (b) if to Developer, at PO Box 538, Waterloo, Iowa 50704, Attention: Tyler Junker. Delivery of notice shall be deemed to occur (i) on the date of delivery when delivered in person, (ii) one (1) business day following deposit for overnight delivery to an overnight air courier service which guarantees next day delivery, (iii) three (3) business days following the date of deposit if mailed by United States registered or certified mail, postage prepaid, or (iv) when transmitted by facsimile so long as the sender obtains written electronic confirmation from the sending facsimile machine that such transmission was successful. A party may change the address for giving notice by any method set forth in this Section. 18. No Joint Venture. Nothing in this Agreement shall, or shall be deemed or construed to, create or constitute any joint venture, partnership, agency, employment, or any other relationship between the City and Developer nor to create any liability for one party with respect to the liabilities or obligations of the other party or any other person. 19. Amendment, Modification, and Waiver. No amendment, modification, or waiver of any condition, provision, or term of this Agreement shall be valid or of any effect unless made in writing, signed by the party or parties to be bound or by the duly authorized representative of same, and specifying with particularity the extent and nature of the amendment, modification, or waiver. Any waiver by any party of any 9 default by another party shall not affect or impair any rights arising from any subsequent default. 20. Severability; Reformation. Each provision, section, sentence, clause, phrase, and word of this Agreement is intended to be severable. If any portion of this Agreement shall be deemed invalid or unenforceable, whether in whole or in part, the offending provision or part thereof shall be deemed severed from this Agreement and the remaining provisions of this Agreement shall not be affected thereby and shall continue in full force and effect. If, for any reason, a court finds that any portion of this Agreement is invalid or unenforceable as written, but that by limiting such provision or portion thereof it would become valid and enforceable, then such provision or portion thereof shall be deemed to be written, and shall be construed and enforced, as so limited. 21. Interpretation. This Agreement shall not be construed more strictly against one party than against the other merely by virtue of the fact that it may have been prepared by counsel for one of the parties, it being recognized that the parties hereto and their respective attorneys have contributed substantially and materially to the preparation of each and every provision of this Agreement. 22. Captions. All captions, headings, or titles in the paragraphs or sections of this Agreement are inserted only as a matter of convenience and/or reference, and they shall in no way be construed as limiting, extending, or describing either the scope or intent of this Agreement or of any provisions hereof. 23. Binding Effect. This Agreement shall be binding and shall inure to the benefit of the parties and their respective successors, assigns, and legal representatives. 24. Counterparts. This Agreement may be executed in one or more counterparts, each of which, including signed counterparts delivered by facsimile or other electronic means, shall be deemed an original and all of which, taken together, shall constitute one and the same instrument. 25. Entire Agreement. This Agreement, together with the exhibits attached hereto, constitutes the entire agreement of the parties and supersedes all prior or contemporaneous negotiations, discussions, understandings, or agreements, whether oral or written, with respect to the subject matter hereof. 26. Time of Essence. Time is of the essence of this Agreement. IN WITNESS WHEREOF, the parties have executed this Development Agreement by their duly authorized representatives as of the date first set forth above. [signatures on next page] 10 CITY OF WATERLOO, IOWA ROCK STAR REAL ESTATE, L By: Que tiCtz 9- ar Quentin Hart, Mayor Attest: 7{e[Cey 'Fe[ch[e Kelley Felchle, City Clerk By: Tyler Junker, 11 EXHIBIT "A" Property Description The Southwesterly 45 feet of Lot 4 and the Southwesterly 45 feet of the Northwesterly 23.6 feet of Lot 5, all in Block 1 in Whitney & Sedgwick's Addition to the City of Waterloo, Iowa. Also, Lot 53 except the West 30 feet thereof, Morris Case's Addition to the City of Waterloo, East Side of Cedar River, Black Hawk County, Iowa. Preparer: Christopher S. Wendland, P.O. Box 596, Waterloo, Iowa 50704 (319) 234-5701 After recording, return to Community Planning & Development, 715 Mulberry Street, Waterloo, IA 50703. DEVELOPMENT AGREEMENT 1 /6/2b Dais Develop qc:41- greement (the "Agreement") is entered into as of by and between Rock Star Real Estate, L.L.C. ("Developer"), and the City of Waterloo, Iowa ("City"). RECITALS A. Developer is willing and able to finance and rehabilitate existing properties owned by City that are located at 1027 W. 3rd St, Waterloo, Iowa, and 128 Lincoln St., Waterloo, Iowa (the "Properties"), legally described as set forth on Exhibit "A" attached hereto. B. City considers development within the City a benefit to the community and is willing for the overall good and welfare of the community to provide financial incentives so as to encourage that goal. City believes that rehabilitation of the Properties is in the best interests of the City and in accordance with the public purposes and provisions of the applicable State and local laws and requirements under which the project has been undertaken and is being assisted. AGREEMENT NOW, THEREFORE, in consideration of the mutual covenants set forth herein, the parties agree as follows: 1. Sale of Property; Title. Subject to the terms hereof, City shall convey the Properties to Developer for the aggregate sum of $25,200.00 (the "Purchase Price") (allocated as $20,100.00 for 1027 W. 3rd Street and $5,100.00 for 128 Lincoln Street), of which $2,000.00 shall be paid in certified funds to City to be held in trust as earnest money and applied at closing to the Purchase Price. Conveyance shall be by quit claim deed, free and clear of all encumbrances arising by or through City except: (a) easements, servitudes, conditions and restrictions of record; (b) current and future real estate real property taxes and assessments subject to the agreements made herein; (c) general utility and right-of-way easements serving the Properties; and (d) restrictions imposed by the City zoning ordinances and other applicable law. City shall have no duty to convey title to Developer until Developer delivers to City reasonable and satisfactory proof of financial ability to undertake and carry on the Project (defined below), which may take the form of a lending commitment letter. Developer may, at its own expense, obtain whatever form of title evidence it desires. If title is unmarketable or subject to matters not acceptable to Developer, and if City does not remedy or remove such objectionable matters in timely fashion following written notice of such objections from Developer, Developer may terminate this Agreement, in which case City shall refund the earnest money to Developer as promptly as possible. City shall provide any title documents it has in its possession, including any abstracts, to assist in title review. 2. Improvements by Developer. Developer acknowledges that it has had a reasonable opportunity to inspect the Properties and to conduct other due diligence related to the Project. Developer agrees to accept the Properties in their "AS IS" condition, without any warranty from City, expressed or implied, as to the condition of the Properties, their marketability, or their fitness for any particular purpose. At its own cost Developer shall (a) remove and properly dispose of all debris and unwanted personal property from the dwellings, (b) renovate the existing structures to a finished state for single-family residential purposes, and (c) make other improvements to the buildings and grounds, including but not limited to sidewalk, and shall be responsible for removal of all construction debris, proper leveling or shaping of groundscape, and grassing and/or landscaping (construction and finishing as so described are referred to collectively as the "Improvements"). The Improvements shall be constructed in accordance with the terms of this Agreement, all applicable City, state, and federal building codes and shall comply with all applicable City ordinances and other applicable law. Developer shall submit specific plans, building designs and site plans for City review and approval before the commencement of construction and shall not substantially deviate from such plans, specifications or designs. Developer will use its best efforts to obtain, or cause to be obtained, in a timely manner, all required permits, licenses and approvals, and will meet, in a timely manner, all requirements of all applicable local, state, and federal laws and regulations which must be obtained or met before the Improvements may be lawfully constructed, including but not limited to all final permit inspections. The Properties, the Improvements, and all other work to make the project site usable for Developer's purposes as contemplated by this Agreement are collectively referred to as the "Project." 3. Timeliness of Construction; Possibility of Reverter. The parties agree that Developer's commitment to cause the Project to be undertaken and to renovate the Properties and complete the Improvements in a timely manner constitutes a material inducement for the City to sell the Properties to Developer and to extend the incentives provided for in this Agreement, and that without said commitment City would not do so. A. Deadlines to commence and complete. Subject to Unavoidable Delays (defined below), Developer must obtain a building permit and begin 2 renovation of one of the dwellings within six (6) months after the date of conveyance of title (the "Start Date") and must Substantially Complete construction of Improvements within eighteen (18) months after the last date of conveyance (the "Completion Deadline"). For purposes of this Agreement, "Substantially Complete" means the date on which the Improvements have been completed to the extent necessary for the City to issue a certificate of occupancy relating thereto and the City has verified that Project elements for which no permit was necessary have been Substantially Completed. All deadlines are subject to Unavoidable Delays as defined in paragraph B below. The City's Community Planning and Development Director may, but shall not be required to, consent to an extension of time of up to six (6) months for construction of the Improvements. Any additional or longer time extensions will require consent of the City Council. B. Events triggering termination and/or reverter. If Developer does not begin or Substantially Complete construction of the Improvements on the schedule(s) stated above, subject to Unavoidable Delays, then City may terminate this Agreement as set forth in Section 12, and City shall then have no further obligation to Developer under this Agreement. If development has commenced within the required period, as the same may be extended, and is subsequently stopped or delayed as a result of an act of God, war, civil disturbance, court order, labor dispute, fire, or other cause beyond the reasonable control of Developer (each an "Unavoidable Delay"), the requirement that construction be completed by the Completion Deadline shall be tolled for a period of time equal to the period of Unavoidable Delay. As promptly as possible, Developer shall notify City in writing of the occurrence of any Unavoidable Delay and shall again notify City in writing when the Unavoidable Delay has ended. If City terminates this Agreement as provided in Section 12, City shall have no further obligations to Developer under this Agreement, including but not limited to any legal or equitable obligation to reimburse Developer for any costs expended by Developer with respect to the Project or to compensate Developer for any value added to the Properties by any Improvements or to refund the Purchase Price in whole or in part. In connection with termination of the Agreement as set forth herein, City may demand reconveyance of the Property in addition to exercising any other available remedies. 4. Reverter of Title; Indemnity. In the event of any reverter of title, Developer agrees that it shall, at its own expense, promptly execute all documents, including but not limited to a special warranty deed, or take such other actions as the City may reasonably request to effectuate said reverter and to deliver to City title to the Properties that is free and clear of any lien, claim, charge, security interest, mortgage or encumbrance (collectively, "Liens") arising by or through Developer. Developer shall pay in full, so as to discharge or satisfy, all Liens on or against either of the Properties. In connection with any reverter of title, Developer shall not be entitled to a refund of the Purchase Price. Appointment of Attorney in Fact: If Developer fails to deliver such 3 documents, including but not limited to a special warranty deed, to City within thirty (30) days after written demand by City, then City shall be authorized to execute, on Developer's behalf and as its attorney -in -fact, the special warranty deed required by this Section, and for such limited purpose Developer does hereby constitute and appoint City as its attorney -in -fact. Developer further agrees that it shall indemnify City and hold it harmless with respect to any demand, claim, cause of action, damage, cost, expense, liability or injury made, suffered, or incurred as a result of or in connection with the Project, or Developer's failure to carry on or complete same, or any Lien or Liens on or against either of the Properties of any type or nature whatsoever that attaches to either of the Properties by virtue of Developer's ownership of same. If City files suit to enforce the terms of this Agreement and prevails in such suit, then Developer shall be liable for all legal expenses, including but not limited to reasonable attorneys' fees, incurred by City. Developer's duties of indemnity pursuant to this Section shall survive the expiration, termination or cancellation of this Agreement for any reason. 4.1. Utilities. Developer will be responsible for obtaining or extending water, sewer, telephone, telecommunications, electricity, gas and other utility services from street right of way to any location on the Properties and for payment of any associated connection fees. 5. City Incentives. To aid the Project, City agrees to provide the following assistance: A. Partial Purchase Price Refund. Within thirty (30) days after Developer has Substantially Completed the Improvements and has obtained final inspection on all permits obtained for the Project, City will refund $10,000.00 of the Purchase Price to Developer. B. Grant. Concurrently with partial refund of the Purchase Price pursuant to paragraph A above, City will make a $10,000.00 infill housing incentive grant to Developer within thirty (30) days after the Improvements are Substantially Completed. 6. No Encumbrances; Limited Exception. Until the Improvements are Substantially Completed, Developer agrees that it shall not create, incur, or suffer to exist any Liens on the Properties, other than such mortgage or mortgages as may be reasonably necessary to finance Developer's completion of the Improvements and of which Developer notifies City before Developer executes any such mortgage. Developer may not mortgage the Properties or any part thereof for any purpose except in connection with financing of the Improvements. Any mortgage in violation of this Section shall be void. 7. No Assignment or Conveyance. Developer agrees that it will not sell, convey, assign or otherwise transfer its interest in the Properties prior to completion of 4 the Project, whether in whole or in part, to any other person or entity without the prior written consent of City. Reasonable grounds for the City to withhold its consent shall include but are not limited to the inability of the proposed transferee to demonstrate to the City's satisfaction that it has the financial ability to observe all of the terms to be performed by Developer under this Agreement. 8. Additional Covenants of Developer. In addition to the other promises, covenants and agreements of Developer as provided elsewhere in this Agreement, Developer agrees as follows: A. Until the Improvements have been Substantially Completed, Developer shall make such reports to City, in such detail and at such times as may be reasonably requested by City, as to the actual progress of Developer with respect to construction of the Improvements. B. Developer will comply with all applicable land development laws and City and county ordinances, and all laws, rules and regulations relating to its businesses, other than laws, rules and regulations where the failure to comply with the same, or where the sanctions and penalties resulting therefrom, would not have a material adverse effect on the business, property, operations, or condition, financial or otherwise, of Developer. C. Developer will cooperate fully with the City in resolution of any traffic, parking, trash removal or public safety problems which may arise in connection with the construction and operation of the Improvements. D. Developer shall make no sale or conveyance of the Properties or any portion thereof without City's prior written consent. 9. Representations and Warranties of City. City hereby represents and warrants as follows: A. City is not prohibited from consummating the transaction contemplated in this Agreement by any law, regulation, agreement, instrument, restriction, order or judgment. B. Each person who executes and delivers this Agreement and all documents to be delivered hereunder is and shall be authorized to do so on behalf of City. 10. Representations and Warranties of Developer. Developer hereby represents and warrants as follows: A. It has all requisite power and authority to own and operate its properties, to carry on its business as now conducted and as presently proposed 5 to be conducted, and to enter into and perform its obligations under this Agreement. B. This Agreement has been duly and validly authorized, executed and delivered by Developer and, assuming due authorization, execution and delivery by the other parties hereto, is in full force and effect and is a valid and legally binding instrument of Developer that is enforceable in accordance with its terms, except as the same may be limited by bankruptcy, insolvency, reorganization or other laws relating to or affecting creditors' rights generally. C. The execution and delivery of this Agreement, the consummation of the transactions contemplated hereby, and the fulfillment of or compliance with the terms and conditions of this Agreement are not prevented by, limited by, in conflict with, or result in a violation or breach of, any contractual restriction, evidence of indebtedness, agreement or instrument of whatever nature to which Developer is now a party or by which it or its property is bound, nor do they constitute a default under any of the foregoing. D. There are no actions, suits or proceedings pending or threatened against or affecting Developer in any court or before any arbitrator or before or by any governmental body in which there is a reasonable possibility of an adverse decision which could materially adversely affect the business (present or prospective) or financial position of Developer or which in any manner raises any questions affecting the validity of the Agreement or Developer's ability to perform its obligations under this Agreement. 11. Default. The following shall be "Events of Default" under this Agreement, and the term "Event of Default" shall mean any one or more of the following events that continues beyond any applicable cure periods: A. Failure by Developer to cause the Improvements to be commenced and completed pursuant to the terms, conditions and limitations of this Agreement; B. Transfer by Developer of any interest (either directly or indirectly) in the Improvements, the Properties, or this Agreement, without the prior written consent of City, except as expressly authorized by this Agreement; C. Failure by any party hereto to substantially observe or perform any covenant, condition, obligation or agreement on its part to be observed or performed under this Agreement; D. Any representation or warranty made by Developer in this Agreement, or made by Developer in any written statement or certificate furnished by Developer pursuant to this Agreement, shall prove to have been 6 incorrect, incomplete or misleading in any material respect on or as of the date of the issuance or making thereof; E. Developer (1) files any petition in bankruptcy or for any reorganization, arrangement, composition, readjustment, liquidation, dissolution, or similar relief under the federal bankruptcy law or any similar state law; (2) makes an assignment for the benefit of its creditors; (3) admits in writing its inability to pay its debts generally as they become due; (4) is adjudicated a bankrupt or insolvent; or if a petition or answer proposing the adjudication of Developer as a bankrupt or its reorganization under any present or future federal bankruptcy act or any similar federal or state law shall be filed in any court and such petition or answer shall not be discharged or denied within ninety (90) days after the filing thereof; or a receiver, trustee or liquidator of Developer, or part thereof, shall be appointed in any proceedings brought against Developer and shall not be discharged within ninety (90) days after such appointment, or if Developer shall consent to or acquiesce in such appointment; or (5) defaults under any mortgage applicable to the Properties. 12. Remedies. A. Default by Developer. Whenever any Event of Default in respect of Developer occurs and is continuing, the City may terminate this Agreement. Before exercising such remedy, City shall give 30 days' written notice to Developer of the Event of Default, provided that by the conclusion of such period the Event of Default shall not have been cured, or the Event of Default cannot reasonably be cured within 30 days and Developer shall not have provided assurances reasonably satisfactory to the City that the Event of Default will be cured as soon as reasonably possible. Upon termination, City may exercise any and all remedies available at law, equity, contract or otherwise to recover ownership of the Properties as set forth in this Agreement. B. Default by City. Whenever any Event of Default in respect of City occurs and is continuing, Developer may take such action against City to require it to specifically perform its obligations hereunder. Before exercising such remedy, Developer shall give 30 days' written notice to City of the Event of Default, provided that by the conclusion of such period the Event of Default shall not have been cured, or if the Event of Default cannot reasonably be cured within 30 days and City shall not have provided assurances reasonably satisfactory to the Developer that the Event of Default will be cured as soon as reasonably possible. C. Remedies under this Agreement shall be cumulative and in addition to any other right or remedy given under this Agreement or existing at law or in equity or by statute. Waiver as to any particular default, or delay or omission in exercising any right or power accruing upon any default, shall not be construed 7 as a waiver of any other or any subsequent default and shall not impair any such right or power. 13. Indemnification and Releases. A. Developer hereby releases City, its elected officials, officers, employees, and agents (collectively, the "indemnified parties") from, covenants and agrees that the indemnified parties shall not be liable for, and agrees to indemnify, defend and hold harmless the indemnified parties against, any loss or damage to properties or any injury to or death of any person occurring at or about the Properties or resulting from any defect in the Improvements. The indemnified parties shall not be liable for any damage or injury to the persons or property of Developer or its employees, contractors or agents, or any other person who may be on or about the Properties or the Improvements, due to any act of negligence or willful misconduct of any person, other than any act of negligence or willful misconduct on the part of any such indemnified party or its officers, employees or agents. B. Except for any willful misrepresentation, any willful misconduct, or any unlawful act of the indemnified parties, Developer agrees to protect and defend the indemnified parties, now or forever, and further agrees to hold the indemnified parties harmless, from any claim, demand, suit, action or other proceedings or any type or nature whatsoever, by any person or entity whatsoever that arises or purportedly arises from (1) any violation of any agreement or condition of this Agreement (except with respect to any suit, action, demand or other proceeding brought by Developer against the City to enforce its rights under this Agreement), or (2) the acquisition and condition of the Properties and the construction, installation, ownership, and operation of the Improvements, or (3) otherwise as a result of or in connection with the Project or Developer's failure to carry on or complete same. C. The indemnification obligations under this Section shall include attorneys' fees and expenses incurred by any indemnified party. The provisions of this Section shall survive the expiration or termination of this Agreement. 14. Materiality of Developer's Promises, Covenants, Representations, and Warranties. Each and every promise, covenant, representation, and warranty set forth in this Agreement on the part of Developer to be performed is a material term of this Agreement, and each and every such promise, covenant, representation, and warranty constitutes a material inducement for City to enter this Agreement. Developer acknowledges that without such promises, covenants, representations, and warranties, City would not have entered this Agreement. Upon breach of any promise or covenant, or in the event of the incorrectness or falsity of any representation or warranty, City may, at its sole option and in addition to any other right or remedy available to it, terminate this Agreement and declare it null and void. 8 15. Performance by City. Developer acknowledges and agrees that all of the obligations of City under this Agreement shall be subject to, and performed by City in accordance with, all applicable statutory, common law or constitutional provisions and procedures consistent with City's lawful authority. All covenants, stipulations, promises, agreements and obligations of City contained in this Agreement shall be deemed to be the covenants, stipulations, promises, agreements and obligations of City and not of any governing body member, officer, employee or agent of City in the individual capacity of such person. 16. No Third -Party Beneficiaries. No rights or privileges of any party hereto shall inure to the benefit of any contractor, subcontractor, material supplier, or any other person or entity, and no such contractor, subcontractor, material supplier, or other person or entity shall be deemed to be a third -party beneficiary of any of the provisions of this Agreement. 17. Notices. Any notice under this Agreement shall be in writing and shall be delivered in person, by overnight air courier service, by United States registered or certified mail, postage prepaid, or by facsimile (with an additional copy delivered by one of the foregoing means), and addressed: (a) if to City, at 715 Mulberry Street, Waterloo, Iowa 50703, fax number 319-291-4571, Attention: Mayor, with copies to the City Attorney and the Community Planning and Development Director. (b) if to Developer, at PO Box 538, Waterloo, Iowa 50704, Attention: Tyler Junker. Delivery of notice shall be deemed to occur (i) on the date of delivery when delivered in person, (ii) one (1) business day following deposit for overnight delivery to an overnight air courier service which guarantees next day delivery, (iii) three (3) business days following the date of deposit if mailed by United States registered or certified mail, postage prepaid, or (iv) when transmitted by facsimile so long as the sender obtains written electronic confirmation from the sending facsimile machine that such transmission was successful. A party may change the address for giving notice by any method set forth in this Section. 18. No Joint Venture. Nothing in this Agreement shall, or shall be deemed or construed to, create or constitute any joint venture, partnership, agency, employment, or any other relationship between the City and Developer nor to create any liability for one party with respect to the liabilities or obligations of the other party or any other person. 19. Amendment, Modification, and Waiver. No amendment, modification, or waiver of any condition, provision, or term of this Agreement shall be valid or of any effect unless made in writing, signed by the party or parties to be bound or by the duly authorized representative of same, and specifying with particularity the extent and nature of the amendment, modification, or waiver. Any waiver by any party of any 9 default by another party shall not affect or impair any rights arising from any subsequent default. 20. Severability; Reformation. Each provision, section, sentence, clause, phrase, and word of this Agreement is intended to be severable. If any portion of this Agreement shall be deemed invalid or unenforceable, whether in whole or in part, the offending provision or part thereof shall be deemed severed from this Agreement and the remaining provisions of this Agreement shall not be affected thereby and shall continue in full force and effect. If, for any reason, a court finds that any portion of this Agreement is invalid or unenforceable as written, but that by limiting such provision or portion thereof it would become valid and enforceable, then such provision or portion thereof shall be deemed to be written, and shall be construed and enforced, as so limited. 21. Interpretation. This Agreement shall not be construed more strictly against one party than against the other merely by virtue of the fact that it may have been prepared by counsel for one of the parties, it being recognized that the parties hereto and their respective attorneys have contributed substantially and materially to the preparation of each and every provision of this Agreement. 22. Captions. All captions, headings, or titles in the paragraphs or sections of this Agreement are inserted only as a matter of convenience and/or reference, and they shall in no way be construed as limiting, extending, or describing either the scope or intent of this Agreement or of any provisions hereof. 23. Binding Effect. This Agreement shall be binding and shall inure to the benefit of the parties and their respective successors, assigns, and legal representatives. 24. Counterparts. This Agreement may be executed in one or more counterparts, each of which, including signed counterparts delivered by facsimile or other electronic means, shall be deemed an original and all of which, taken together, shall constitute one and the same instrument. 25. Entire Agreement. This Agreement, together with the exhibits attached hereto, constitutes the entire agreement of the parties and supersedes all prior or contemporaneous negotiations, discussions, understandings, or agreements, whether oral or written, with respect to the subject matter hereof. 26. Time of Essence. Time is of the essence of this Agreement. IN WITNESS WHEREOF, the parties have executed this Development Agreement by their duly authorized representatives as of the date first set forth above. [signatures on next page] 10 CITY OF WATERLOO, IOWA ROCK STAR REAL ESTATE, By: QCGeti tz 9-far Quentin Hart, Mayor Attest: 7(elley Felchle Mai SI�D Kelley Felchle, City Clerk By: Tyler Junker, 11 EXHIBIT "A" Property Description The Southwesterly 45 feet of Lot 4 and the Southwesterly 45 feet of the Northwesterly 23.6 feet of Lot 5, all in Block 1 in Whitney & Sedgwick's Addition to the City of Waterloo, Iowa. Also, Lot 53 except the West 30 feet thereof, Morris Case's Addition to the City of Waterloo, East Side of Cedar River, Black Hawk County, Iowa.