Loading...
HomeMy WebLinkAboutTwin Card Holdings, Inc. - DA-MAA -(RECORDED) 5/19/2025 2025-13353 RECORDED:09/11/2025 02:40:59 PM RECORDING FEE:$72.00 REVENUE TAX:$ COMBINED FEE:$72.00 SANDIE L.SMITH,RECORDER BLACK HAWK COUNTY,IOWA V c& •4uf n 4-0 ' i cJ WCti-ear ce Prepared by Austin J. McMahon,222 First Street East, Independence, IA 50644 Phone(319)291-4366 DEVELOPMENT AGREEMENT This Development Agreement (the "Agreement") is entered into as of cl Er! , 2025 by and between Twin Card Holdings LLC (the "Company") and the CICy of Waterloo, Iowa (the "City"). RECITALS A. Company is the owner of real property legally described as set forth on Exhibit "A" attached hereto (the "Property"), and Company is willing and able to undertake, or cause to be undertaken, the financing and construction of a building and related improvements or rehabilitation on the Property. B. City considers economic development within the City a benefit to the community and is willing for the overall good and welfare of the community to provide financial incentives so as to encourage that goal, and the City further believes that the project is in the vital and best interests of the City and that the project and such incentives are in accordance with the public purposes and provisions of applicable State and local laws and requirements under which the project has been undertaken and is being assisted AGREEMENT NOW, THEREFORE, in consideration of the mutual covenants set forth herein, the parties agree as follows: 1. Improvements by Company. Company shall construct a 4,500 square foot building (collectively, the "Improvements"). Company agrees that the Improvements shall be constructed in accordance with the terms of this Agreement, the urban revitalization plan applicable to the Property, and all applicable City, state, and federal building codes and shall comply with all applicable City ordinances and other applicable law. City may require that Company submit specific building designs and site plans for City review and approval. Company will use its best efforts to obtain, or cause to be obtained, in a timely manner, all required permits, licenses and approvals, and will meet, a`� in a timely manner, all requirements of all applicable local, state, and federal laws and regulations which must be obtained or met before the Improvements may be lawfully constructed. The Property,the Improvements,and all development-related work to make the Property usable for Company's purposes as contemplated by this Agreement are collectively referred to as the"Project." 2. Timeliness of Construction; Possibility of Termination. The parties agree that Company's commitment to undertake the Project and to construct the Improvements in a timely manner constitutes a material inducement for the City to offer the incentives provided for in this Agreement, and that without said commitment City would not do so. A. Deadlines to commence and complete. Company must begin construction of the Improvements within four (4) months after the date of this Agreement and Substantially Complete construction within fourteen (14) months after the date of this Agreement(the"Completion Deadline"). For purposes of this Agreement,"Substantially Complete"means the date on which the Improvements have been completed to the extent necessary for City to issue a certificate of occupancy relating thereto and City has also verified that any Project element for which no permit was necessary has been Substantially Completed. All deadlines are subject to Unavoidable Delays as defined in paragraph B below. B. Events triggering termination. If Company does not Substantially Complete construction of the Improvements on the schedule stated above, then City may terminate this Agreement as set forth in Section 11,and City shall then have no further obligation under this Agreement. In any circumstance where Company's progress on the Project fails to meet the schedule stated above,then City's Community Planning and Development Director may, but shall not be required to, consent to an extension of time of up to six (6) months for the construction of the Improvements,and if an extension is granted but construction of the Improvements has not begun within such extended period,then any further time extensions will require consent of the City Council. If development has commenced within the required period, as the same may be extended, and is subsequently stopped or delayed as a result of an act of God, war, civil disturbance,court order,labor dispute,fire,or other cause beyond the reasonable control of Company (each an "Unavoidable Delay"), the requirement that construction be completed by the Completion Deadline shall be tolled for a period of time equal to the period of Unavoidable Delay. 3. Utilities. Company will be responsible for extending water, sewer, telephone, telecommunications, electricity, gas and other utility services, if any, to the Property and for payment of any associated connection fees. 4. Minimum Assessment Agreement. Company acknowledges and agrees that it will pay when due all taxes and assessments, general or special, and all other charges whatsoever levied upon or assessed or placed against the Property. Company further agrees that prior to the date set forth in Section 2 of the Minimum Assessment 2 Agreement (the "MAA") attached hereto as Exhibit "B" it will not seek or cause a reduction in the taxable valuation for the Property as improved pursuant to this Agreement, which shall be fixed for assessment purposes, below the amount of$135,000.00 (the "Minimum Actual Value"), through: (a) willful destruction of the Property, the Improvements, or any part of either; (b) a request to the assessor of Black Hawk County; or (c) any proceedings, whether administrative, legal, or equitable, with any administrative body or court within the City, Black Hawk County, the State of Iowa, or the federal government. Company agrees to execute and deliver the MAA concurrently with its execution and delivery of this Agreement. 5. City Incentives. City agrees to provide the following incentives in support of the Project: A. Tax Abatement. Because the Property is located in a designated Consolidated Urban Revitalization Area (CURA), the Property is eligible for tax exemption consistent with and to the extent provided for in Iowa law, provided that Company meets all requirements to qualify for such exemption. 6. Additional Covenants of Company. In addition to the other promises, covenants and agreements of Company as provided elsewhere in this Agreement, Company agrees as follows with respect to the Improvements: A. Company agrees during construction of the Improvements and thereafter until the MAA termination date to maintain, as applicable, builder's risk, property damage, and liability insurance coverages with respect to the Improvements in such amounts as are customarily carried by like organizations engaged in activities of comparable size and liability exposure, and shall provide evidence of such coverages to the City upon request. B. Until the Improvements are Substantially Completed, Company shall make such reports to City, in such detail and at such times as may be reasonably requested by City, as to the actual progress of Company with respect to construction of the Improvements. C. During construction of the Improvements and thereafter until the MAA termination date, Company will cooperate fully with the City in resolution of any traffic, parking, trash removal or public safety problems which may arise in connection with the construction and operation of the Improvements. 3 D. Company will comply with all applicable land development laws and City and county ordinances, and all laws, rules and regulations relating to its businesses, other than laws, rules and regulations where the failure to comply with the same or the sanctions and penalties resulting therefrom, would not have a material adverse effect on the business, property, operations, or condition, financial or otherwise, of Company. E. Until the MAA termination date, Company will maintain, preserve and keep the Property, including but not limited to the Improvements, in good repair and working order, ordinary wear and tear excepted, and from time to time will make all necessary repairs, replacements, renewals and additions. F. The Property will have a taxable value as set forth in the MAA and any amendments thereto, and Company agrees that the minimum actual value of the Property and completed Improvements as stated in the MAA and any amendments thereto will be a reasonable estimate of the actual value of the Property and Improvements for ad valorem property tax purposes. Company agrees that it will spend enough in construction of the Improvements that, when combined with the value of the Property and related site improvements, will equal or exceed the assessor's minimum actual value for the Property and Improvements as set forth in the MAA and any amendments thereto. G. Until the MAA termination date Company agrees that (1) it will not undertake, in any other municipality in Black Hawk County, the construction or rehabilitation of any commercial property as a primary location for Company's business operations of the type to be conducted on the Property, and (2) it will make no conveyance, lease or other transfer of the Property or any interest therein that would cause the Property or any part thereof to be classified as exempt from taxation or subject to centralized assessment or taxation by the State of Iowa. H. Company shall pay, or cause to be paid, when due, all real property taxes and assessments payable with respect to any and all parts of the Property conveyed to it. Company agrees that (1) it will not seek administrative review or judicial review of the applicability or constitutionality of any Iowa tax statute or regulation relating to the taxation of real property included within the Property that is determined by any tax official to be applicable to the Property or to Company, or raise the inapplicability or constitutionality of any such tax statute or regulation as a defense in any proceedings of any type or nature, including but not limited to delinquent tax proceedings, and (2) it will not seek any tax deferral, credit or abatement, either presently or prospectively authorized under Iowa Code Chapter 403 or 404, or any other state law, of the taxation of real property included within the Property. 7. Representations and Warranties of City. City hereby represents and warrants as follows: 4 A. City is not prohibited from consummating the transaction contemplated in this Agreement by any law, regulation, agreement, instrument, restriction, order or judgment. B. Each person who executes and delivers this Agreement and all documents to be delivered hereunder is and shall be authorized to do so on behalf of City. 8. Representations and Warranties of Company. Company hereby represents and warrants as follows: A. It has all requisite power and authority to own and operate its properties, to carry on its business as now conducted and as presently proposed to be conducted, and to enter into and perform its obligations under this Agreement. B. This Agreement has been duly and validly executed and delivered by Company and, assuming due authorization, execution and delivery by the other parties hereto, is in full force and effect and is a valid and legally binding instrument of Company that is enforceable in accordance with its terms, except as the same may be limited by bankruptcy, insolvency, reorganization or other laws relating to or affecting creditors' rights generally. C. The execution and delivery of this Agreement, the consummation of the transactions contemplated hereby, and the fulfillment of or compliance with the terms and conditions of this Agreement are not prevented by, limited by, in conflict with, or result in a violation or breach of, the terms, conditions or provisions of any contractual restriction, evidence of indebtedness, agreement or instrument of whatever nature to which Company is now a party or by which it or its property is bound, nor do they constitute a default under any of the foregoing. D. There are no actions, suits or proceedings pending or threatened against or affecting Company in any court or before any arbitrator or before or by any governmental body in which there is a reasonable possibility of an adverse decision which could materially adversely affect the business (present or prospective), financial position, or results of operations of Company or which in any manner raises any questions affecting the validity of the Agreement or Company's ability to perform its obligations under this Agreement. E. The financing commitments, which Company will proceed with due diligence to obtain, to finance the construction of the Improvements will be sufficient to enable Company to successfully complete construction of the Improvements as contemplated in this Agreement, subject to additional costs incurred due to Unavoidable Delays. 9. Indemnification. Company hereby releases City, its elected officials, officers, employees, and agents (collectively, the "indemnified parties") from, covenants and agrees that the indemnified parties shall not be liable for, and agrees to indemnify, 5 defend and hold harmless the indemnified parties against, any loss or damage to property or any injury to or death of any person occurring at or about the Property. The indemnified parties shall not be liable for any damage or injury to the persons or property of Company or its members, managers, employees, contractors or agents, or any other person who may be about the Property or the Improvements, due to any act of negligence or willful misconduct of any person, other than any act of negligence or willful misconduct on the part of any such indemnified party or its officers, employees or agents. The provisions of this Section shall survive the expiration or termination of this Agreement. 10. Default. The following shall be "Events of Default" under this Agreement, and the term "Event of Default" shall mean any one or more of the following events that continues beyond any applicable cure periods: A. Failure by Company to cause the construction of the Improvements to be commenced and completed pursuant to the terms, conditions and limitations of this Agreement; B. Failure by Company to pay, before delinquency, all ad valorem property taxes levied on or against any of the Property; C. Failure by any party hereto to substantially observe or perform any covenant, condition, obligation or agreement on its part to be observed or performed under this Agreement; D. Company (1) files any petition in bankruptcy or for any reorganization, arrangement, composition, readjustment, liquidation, dissolution, or similar relief under the federal bankruptcy law or any similar state law; (2) makes an assignment for the benefit of its creditors; (3) admits in writing its inability to pay its debts generally as they become due; (4) is adjudicated a bankrupt or insolvent; or if a petition or answer proposing the adjudication of Company as a bankrupt or its reorganization under any present or future federal bankruptcy act or any similar federal or state law shall be filed in any court and such petition or answer shall not be discharged or denied within ninety (90) days after the filing thereof; or a receiver, trustee or liquidator of Company, or part thereof, shall be appointed in any proceedings brought against Company and shall not be discharged within ninety (90) days after such appointment, or if Company shall consent to or acquiesce in such appointment; or (5) defaults under any mortgage applicable to any of Property. E. Any representation or warranty made by Company in this Agreement, or made by Company in any written statement or certificate furnished by Company pursuant to this Agreement, shall prove to have been incorrect, incomplete or misleading in any material respect on or as of the date of the issuance or making thereof. 11. Remedies. 6 A. Default by Company. Whenever any Event of Default in respect of Company occurs and is continuing, the City may terminate this Agreement. Before exercising such remedy, City shall give 30 days' written notice to Company of the Event of Default, provided that by the conclusion of such period the Event of Default shall not have been cured, or the Event of Default cannot reasonably be cured within 30 days and Company shall not have provided assurances reasonably satisfactory to the City that the Event of Default will be cured as soon as reasonably possible. Upon termination, City may exercise any and all remedies available at law, equity, contract or otherwise for recovery of any sums paid by City to Company, if any, before the date of termination as set forth in this Agreement. B. Default by City. Whenever any Event of Default in respect of City occurs and is continuing, Company may take such action against City to require it to specifically perform its obligations hereunder. Before exercising such remedy, Company shall give 30 days' written notice to City of the Event of Default, provided that by the conclusion of such period the Event of Default shall not have been cured, or if the Event of Default cannot reasonably be cured within 30 days and City shall not have provided assurances reasonably satisfactory to the Company that the Event of Default will be cured as soon as reasonably possible. C. Remedies under this Agreement shall be cumulative and in addition to any other right or remedy given under this Agreement or existing at law or in equity or by statute. Waiver as to any particular default, or delay or omission in exercising any right or power accruing upon any default, shall not be construed as a waiver of any other or any subsequent default and shall not impair any such right or power. 12. Materiality of Company's Promises, Covenants, Representations, and Warranties. Each and every promise, covenant, representation, and warranty set forth in this Agreement on the part of Company to be performed is a material term of this Agreement, and each and every such promise, covenant, representation, and warranty constitutes a material inducement for City to enter this Agreement. Company acknowledges that without such promises, covenants, representations, and warranties, City would not have entered this Agreement. Upon breach of any promise or covenant, or in the event of the incorrectness or falsity of any representation or warranty, City may, at its sole option and in addition to any other right or remedy available to it, terminate this Agreement and declare it null and void. 13. Performance by City. Company acknowledges and agrees that all of the obligations of City under this Agreement shall be subject to, and performed by City in accordance with, all applicable statutory, common law or constitutional provisions and procedures consistent with City's lawful authority. All covenants, stipulations, promises, agreements and obligations of City contained in this Agreement shall be deemed to be the covenants, stipulations, promises, agreements and obligations of City and not of any governing body member, officer, employee or agent of City in the individual capacity of such person. 7 14. No Third-Party Beneficiaries. No rights or privileges of any party hereto shall inure to the benefit of any contractor, subcontractor, material supplier, or any other person or entity, and no such contractor, subcontractor, material supplier, or other person or entity shall be deemed to be a third-party beneficiary of any of the provisions of this Agreement. 15. Notices. Any notice under this Agreement shall be in writing and shall be delivered in person, by overnight air courier service, by United States registered or certified mail, postage prepaid, or by facsimile (with an additional copy delivered by one of the foregoing means), and addressed: (a) if to City, at 715 Mulberry Street, Waterloo, Iowa 50703, facsimile number 319-291-4571, Attention: Mayor, with copies to the City Attorney and the Community Planning and Development Director. (b) if to Company, at Twin Card Holdings LLC, 2120 Main Street, Cedar Falls, Iowa 50613, Attention: Jared Honermann and Jones Law Firm c/o Gary Jones, Cedar Falls, Iowa. Delivery of notice shall be deemed to occur (i) on the date of delivery when delivered in person, (ii) one (1) business day following deposit for overnight delivery to an overnight air courier service which guarantees next day delivery, (iii) three (3) business days following the date of deposit if mailed by United States registered or certified mail, postage prepaid, or (iv) when transmitted by facsimile so long as the sender obtains written electronic confirmation from the sending facsimile machine that such transmission was successful. A party may change the address for giving notice by any method set forth in this Section. 16. No Joint Venture. Nothing in this Agreement shall, or shall be deemed or construed to, create or constitute any joint venture, partnership, agency, employment, or any other relationship between the City and Company nor to create any liability for one party with respect to the liabilities or obligations of the other party or any other person. 17. Amendment, Modification, and Waiver. No amendment, modification, or waiver of any condition, provision, or term of this Agreement shall be valid or of any effect unless made in writing, signed by the party or parties to be bound or by the duly authorized representative of same, and specifying with particularity the extent and nature of the amendment, modification, or waiver. Any waiver by any party of any default by another party shall not affect or impair any rights arising from any subsequent default. 18. Severability; Reformation. Each provision, section, sentence, clause, phrase, and word of this Agreement is intended to be severable. If any portion of this Agreement shall be deemed invalid or unenforceable, whether in whole or in part, the offending provision or part thereof shall be deemed severed from this Agreement and the remaining provisions of this Agreement shall not be affected thereby and shall continue in full force and effect. If, for any reason, a court finds that any portion of this Agreement is invalid or unenforceable as written, but that by limiting such provision or portion thereof 8 it would become valid and enforceable, then such provision or portion thereof shall be deemed to be written, and shall be construed and enforced, as so limited. 19. Captions. All captions, headings, or titles in the paragraphs or sections of this Agreement are inserted only as a matter of convenience and/or reference, and they shall in no way be construed as limiting, extending, or describing either the scope or intent of this Agreement or of any provisions hereof. 20. Interpretation. This Agreement shall not be construed more strictly against one party than against the other merely by virtue of the fact that it may have been prepared by counsel for one of the parties, it being recognized that the parties hereto and their respective attorneys have contributed substantially and materially to the preparation of each and every provision of this Agreement. 21. Binding Effect. This Agreement shall be binding and shall inure to the benefit of the parties and their respective successors, assigns, and legal representatives. 22. Counterparts. This Agreement may be executed in multiple counterparts, each of which shall be deemed an original and all of which, taken together, shall constitute one and the same instrument. 23. Entire Agreement. This Agreement, together with the exhibits attached hereto, constitutes the entire agreement of the parties and supersedes all prior or contemporaneous negotiations, discussions, understandings, or agreements, whether oral or written, with respect to the subject matter hereof. 24. Time of Essence. Time is of the essence of this Agreement. IN WITNESS WHEREOF, the parties have executed this Development Agreement by their duly authorized representatives as of the date first set forth above. CITY OF WATERLOO, IOWA Twin Card Holdin s LLC By: n v1 tea., By: Quentin M. Hart, Mayor Jared Honer nn Managing Member Attest: elley Fel e, City Clerk 9 EXHIBIT "A" Legal Description of Property Lots 8, 9 and Northeasterly 60 feet in even width of Lot 10, all in Block 39, in the Original Plat, on the West Side of the Cedar River, in the City of Waterloo, Black Hawk County, Iowa. EXHIBIT "B" MINIMUM ASSESSMENT AGREEMENT This Minimum Assessment Agreement (the "Agreement") is entered into as of t.,L 5 , 2025, by and among the CITY OF WATERLOO, IOWA ("City"), TWIN CARD ROLDINGS LLC ("Company"), and the COUNTY ASSESSOR of the City of Waterloo, Iowa ("Assessor"). WITNESSETH: WHEREAS, on or before the date hereof the City and Company have entered into a development agreement (the "Development Agreement") regarding certain real property (the "Property"), described in Exhibit "A" thereto, located in the City; and WHEREAS, it is contemplated that pursuant to the Development Agreement, the Company will undertake the development of a property within a designated urban revitalization area of the City, including the construction of certain improvements as described in the Development Agreement (the "Minimum Improvements") on the Property (the "Project"); and WHEREAS, pursuant to Iowa Code § 404.3C, the City and the Company desire to establish a minimum actual value for the Property and the Minimum Improvements to be constructed thereon by Company pursuant to the Development Agreement, which shall be effective upon substantial completion of the Project and from then until this Agreement is terminated pursuant to the terms herein and which is intended to reflect the minimum actual value of the land and buildings as to the Project only; and WHEREAS, the City and the Assessor have reviewed the preliminary plans and specifications for the Minimum Improvements which the parties contemplate will be erected as a part of the Project. NOW, THEREFORE, the parties hereto, in consideration of the promises, covenants, and agreements made by each other, do hereby agree as follows: 1. Upon substantial completion of construction of the Minimum Improvements by Company, the minimum actual taxable value which shall be fixed for assessment purposes for the Property and Minimum Improvements to be constructed thereon by Company as a part of the Project shall not be less than $135,000.00 (the "Minimum Actual Value") until termination of this Agreement. The parties hereto agree that construction of the Minimum Improvements will be substantially completed by the date set forth in the Development Agreement, and in any case if the Minimum Improvements are not substantially completed by December 31 , 2026 the parties agree to execute an amendment to this Agreement that will extend the date specified in Section 2 below. 2. The Minimum Actual Value herein established shall be of no further force and effect, and this Minimum Assessment Agreement shall terminate, on December 31 , 2036. The Minimum Actual Value shall be maintained during such period regardless of: (a) any failure to complete the Minimum Improvements; (b) destruction of all or any portion of the Minimum Improvements; (c) diminution in value of the Property or the Minimum Improvements; or (d) any other circumstance, whether known or unknown and whether now existing or hereafter occurring. 3. Company shall pay, or cause to be paid, when due, all real property taxes and assessments payable with respect to all and any parts of the Property and the Minimum Improvements pursuant to the provisions of this Agreement and the Development Agreement. Such tax payments shall be made without regard to any loss, complete or partial, to the Property or the Minimum Improvements, any interruption in, or discontinuance of, the use, occupancy, ownership or operation of the Property or the Minimum Improvements by Company or any other matter or thing which for any reason interferes with, prevents or renders burdensome the use or occupancy of the Property or the Minimum Improvements. 4. Company agrees that its obligation to make the tax payments required hereby, to pay the other sums provided for herein, and to perform and observe its other agreements contained in this Agreement shall be absolute and unconditional obligations of Company (not limited to the statutory remedies for unpaid taxes) and that Company shall not be entitled to any abatement or diminution thereof, or set off therefrom, nor to any early termination of this Agreement for any reason whatsoever. 5. Nothing herein shall be deemed to waive the Company's rights under Iowa Code § 404.3C to contest that portion of any actual value assignment made by the Assessor in excess of the Minimum Actual Value established herein. In no event, however, shall the Company seek or cause the reduction of the actual value assigned below the Minimum Actual Value established herein during the term of this Agreement. Nothing herein shall limit the discretion of the Assessor to assign at any time an actual value to the land and Minimum Improvements in excess of the Minimum Actual Value. 6. Company agrees that during the term of this Agreement it will not: (a) seek administrative review or judicial review of the applicability or constitutionality of any Iowa tax statute relating to the taxation of property contained as a part of the Property or the Minimum Improvements determined by any tax official to be applicable to the Property or the Minimum Improvements, or raise the inapplicability or constitutionality of any such tax statute as a defense in any proceedings, including delinquent tax proceedings; or 2 (b) seek any tax deferral, credit or abatement, either presently or prospectively authorized under Iowa Code Chapter 403 or 404, or any other state law, of the taxation of real property, including improvements and fixtures thereon, contained in the Property or the Minimum Improvements; or (c) request the Assessor to reduce the Minimum Actual Value; or (d) appeal to the board of review of the city, county, state or to the Director of Revenue of the State of Iowa to reduce the Minimum Actual Value; or (e) cause a reduction in the actual value or the Minimum Actual Value through any other proceedings. 7. This Agreement shall be promptly recorded by the City with the Recorder of Black Hawk County, Iowa. The City shall pay all costs of recording. 8. Neither the preambles nor provisions of this Agreement are intended to, or shall be construed as, modifying the terms of the Development Agreement. 9. Each provision, section, sentence, clause, phrase, and word of this Agreement is intended to be severable. If any portion of this Agreement shall be deemed invalid or unenforceable, whether in whole or in part, the offending provision or part thereof shall be deemed severed from this Agreement and the remaining provisions of this Agreement shall not be affected thereby and shall continue in full force and effect. If, for any reason, a court finds that any portion of this Agreement is invalid or unenforceable as written, but that by limiting such provision or portion thereof it would become valid and enforceable, then such provision or portion thereof shall be deemed to be written, and shall be construed and enforced, as so limited. 10. This Agreement shall inure to the benefit of and be binding upon the successors and assigns of the parties, including but not limited to future owners of the Project property. IN WITNESS WHEREOF, the parties have executed this Minimum Assessment Agreement by their duly authorized representatives as of the date first set forth above. [signatures on next page] 3 CITY OF WATERLOO, IOWA TWIN CARD HO DINGS LLC By: 2 By: Quentin Hart, Mayor Jared Honer a n Managing Member By: elley F chle, City Clerk STATE OF IOWA ) ss. COUNTY OF BLACK HAWK ) On this day of 1 , 2025, before me, a Notary Public in and for the State of Iowa, personally ppeared Quentin Hart and Kelley Felchle, to me personally known, who being duly sworn, did say that they are the Mayor and City Clerk, respectively, of the City of Waterloo, Iowa, a municipal corporation, created and existing under the laws of the State of Iowa, and that the seal affixed to the foregoing instrument is the seal of said municipal corporation, and that said instrument was signed and sealed on behalf of said municipal corporation by authority and resolution of its City Council, and said Mayor and City Clerk acknowledged said instrument to be the free act and deed of said municipal corporation by it and by them voluntarily executed. 'It BRITNI C PERKINS lic �P - sF Z COMMISSION NO.845529 * * MY jOAN ARYION EXPIRES —IOWA 2026 STATE OF IOWA ) ) ss. COUNTY OF BLACK HAWK ) Subscribed and sworn to before me on L► C \a/ 5 , 2025 by Jared Honermann as Managing Member of Twin Card Holdings L C. TRACIA S ROSS Z a� -- COMMISSION NO.811963 *n ** MY COMMISSSON EXPIRES toy" bid Notary Public 4 .f, ` �is1- CERTIFICATION OF ASSESSOR The undersigned, having reviewed the plans and specifications for the Minimum Improvements to be constructed and the market value assigned to the land upon which the Minimum Improvements are to be constructed for the development, and being of the opinion that the minimum market value contained in the foregoing Minimum Assessment Agreement appears reasonable, hereby certifies as follows: The undersigned Assessor, being legally responsible for the assessment of the property described in the foregoing Minimum Assessment Agreement upon completion of the improvements to be made on it, certifies that the actual value assigned to the land and improvements upon completion shall not be less than One Hundred Thirty-Five Thousand and 00/100 Dollars ($135,000.00) until termination of this Minimum Assessment Agreement pursuant to the terms hereof, subject to adjustment as provided in said agreement. or for Black Hawk County, Iowa Date STATE OF IOWA ) ) ss. COUNTY OF BLACK HAWK ) Subscribed and sworn to before me on 9- J. -:95 , 2025 by T.J. Koenigsfeld, Assessor for Black Hawk County, Iowa. a3-�3^4 TARA JOHNSON o � � Commission Number umber 767467 4. My Commission Expires i ,q,P April 5, 2026 Not ublic Prepared by Austin J. McMahon, 222 First Street East, Independence, IA 50644 Phone(319)291-4366 DEVELOPMENT AGREEMENT This Development Agreement (the "Agreement") is entered into as of rtu IL! , 2025 by and between Twin Card Holdings LLC (the "Company") and the Ct(y of Waterloo, Iowa (the "City"). RECITALS A. Company is the owner of real property legally described as set forth on Exhibit "A" attached hereto (the "Property"), and Company is willing and able to undertake, or cause to be undertaken, the financing and construction of a building and related improvements or rehabilitation on the Property. B. City considers economic development within the City a benefit to the community and is willing for the overall good and welfare of the community to provide financial incentives so as to encourage that goal, and the City further believes that the project is in the vital and best interests of the City and that the project and such incentives are in accordance with the public purposes and provisions of applicable State and local laws and requirements under which the project has been undertaken and is being assisted AGREEMENT NOW, THEREFORE, in consideration of the mutual covenants set forth herein, the parties agree as follows: 1. Improvements by Company. Company shall construct a 4,500 square foot building (collectively, the "Improvements"). Company agrees that the Improvements shall be constructed in accordance with the terms of this Agreement, the urban revitalization plan applicable to the Property, and all applicable City, state, and federal building codes and shall comply with all applicable City ordinances and other applicable law. City may require that Company submit specific building designs and site plans for City review and approval. Company will use its best efforts to obtain, or cause to be obtained, in a timely manner, all required permits, licenses and approvals, and will meet, in a timely manner, all requirements of all applicable local, state, and federal laws and regulations which must be obtained or met before the Improvements may be lawfully constructed. The Property, the Improvements, and all development-related work to make the Property usable for Company's purposes as contemplated by this Agreement are collectively referred to as the "Project." 2. Timeliness of Construction; Possibility of Termination. The parties agree that Company's commitment to undertake the Project and to construct the Improvements in a timely manner constitutes a material inducement for the City to offer the incentives provided for in this Agreement, and that without said commitment City would not do so. A. Deadlines to commence and complete. Company must begin construction of the Improvements within four (4) months after the date of this Agreement and Substantially Complete construction within fourteen (14) months after the date of this Agreement (the "Completion Deadline"). For purposes of this Agreement, "Substantially Complete" means the date on which the Improvements have been completed to the extent necessary for City to issue a certificate of occupancy relating thereto and City has also verified that any Project element for which no permit was necessary has been Substantially Completed. All deadlines are subject to Unavoidable Delays as defined in paragraph B below. B. Events triggering termination. If Company does not Substantially Complete construction of the Improvements on the schedule stated above, then City may terminate this Agreement as set forth in Section 11, and City shall then have no further obligation under this Agreement. In any circumstance where Company's progress on the Project fails to meet the schedule stated above, then City's Community Planning and Development Director may, but shall not be required to, consent to an extension of time of up to six (6) months for the construction of the Improvements, and if an extension is granted but construction of the Improvements has not begun within such extended period, then any further time extensions will require consent of the City Council. If development has commenced within the required period, as the same may be extended, and is subsequently stopped or delayed as a result of an act of God, war, civil disturbance, court order, labor dispute, fire, or other cause beyond the reasonable control of Company (each an "Unavoidable Delay"), the requirement that construction be completed by the Completion Deadline shall be tolled for a period of time equal to the period of Unavoidable Delay. 3. Utilities. Company will be responsible for extending water, sewer, telephone, telecommunications, electricity, gas and other utility services, if any, to the Property and for payment of any associated connection fees. 4. Minimum Assessment Agreement. Company acknowledges and agrees that it will pay when due all taxes and assessments, general or special, and all other charges whatsoever levied upon or assessed or placed against the Property. Company further agrees that prior to the date set forth in Section 2 of the Minimum Assessment 2 Agreement (the "MAA") attached hereto as Exhibit "B" it will not seek or cause a reduction in the taxable valuation for the Property as improved pursuant to this Agreement, which shall be fixed for assessment purposes, below the amount of$135,000.00 (the "Minimum Actual Value"), through: (a) willful destruction of the Property, the Improvements, or any part of either; (b) a request to the assessor of Black Hawk County; or (c) any proceedings, whether administrative, legal, or equitable, with any administrative body or court within the City, Black Hawk County, the State of Iowa, or the federal government. Company agrees to execute and deliver the MAA concurrently with its execution and delivery of this Agreement. 5. City Incentives. City agrees to provide the following incentives in support of the Project: A. Tax Abatement. Because the Property is located in a designated Consolidated Urban Revitalization Area (CURA), the Property is eligible for tax exemption consistent with and to the extent provided for in Iowa law, provided that Company meets all requirements to qualify for such exemption. 6. Additional Covenants of Company. In addition to the other promises, covenants and agreements of Company as provided elsewhere in this Agreement, Company agrees as follows with respect to the Improvements: A. Company agrees during construction of the Improvements and thereafter until the MAA termination date to maintain, as applicable, builder's risk, property damage, and liability insurance coverages with respect to the Improvements in such amounts as are customarily carried by like organizations engaged in activities of comparable size and liability exposure, and shall provide evidence of such coverages to the City upon request. B. Until the Improvements are Substantially Completed, Company shall make such reports to City, in such detail and at such times as may be reasonably requested by City, as to the actual progress of Company with respect to construction of the Improvements. C. During construction of the Improvements and thereafter until the MAA termination date, Company will cooperate fully with the City in resolution of any traffic, parking, trash removal or public safety problems which may arise in connection with the construction and operation of the Improvements. 3 D. Company will comply with all applicable land development laws and City and county ordinances, and all laws, rules and regulations relating to its businesses, other than laws, rules and regulations where the failure to comply with the same or the sanctions and penalties resulting therefrom, would not have a material adverse effect on the business, property, operations, or condition, financial or otherwise, of Company. E. Until the MAA termination date, Company will maintain, preserve and keep the Property, including but not limited to the Improvements, in good repair and working order, ordinary wear and tear excepted, and from time to time will make all necessary repairs, replacements, renewals and additions. F. The Property will have a taxable value as set forth in the MAA and any amendments thereto, and Company agrees that the minimum actual value of the Property and completed Improvements as stated in the MAA and any amendments thereto will be a reasonable estimate of the actual value of the Property and Improvements for ad valorem property tax purposes. Company agrees that it will spend enough in construction of the Improvements that, when combined with the value of the Property and related site improvements, will equal or exceed the assessor's minimum actual value for the Property and Improvements as set forth in the MAA and any amendments thereto. G. Until the MAA termination date Company agrees that (1) it will not undertake, in any other municipality in Black Hawk County, the construction or rehabilitation of any commercial property as a primary location for Company's business operations of the type to be conducted on the Property, and (2) it will make no conveyance, lease or other transfer of the Property or any interest therein that would cause the Property or any part thereof to be classified as exempt from taxation or subject to centralized assessment or taxation by the State of Iowa. H. Company shall pay, or cause to be paid, when due, all real property taxes and assessments payable with respect to any and all parts of the Property conveyed to it. Company agrees that (1) it will not seek administrative review or judicial review of the applicability or constitutionality of any Iowa tax statute or regulation relating to the taxation of real property included within the Property that is determined by any tax official to be applicable to the Property or to Company, or raise the inapplicability or constitutionality of any such tax statute or regulation as a defense in any proceedings of any type or nature, including but not limited to delinquent tax proceedings, and (2) it will not seek any tax deferral, credit or abatement, either presently or prospectively authorized under Iowa Code Chapter 403 or 404, or any other state law, of the taxation of real property included within the Property. 7. Representations and Warranties of City. City hereby represents and warrants as follows: 4 A. City is not prohibited from consummating the transaction contemplated in this Agreement by any law, regulation, agreement, instrument, restriction, order or judgment. B. Each person who executes and delivers this Agreement and all documents to be delivered hereunder is and shall be authorized to do so on behalf of City. 8. Representations and Warranties of Company. Company hereby represents and warrants as follows: A. It has all requisite power and authority to own and operate its properties, to carry on its business as now conducted and as presently proposed to be conducted, and to enter into and perform its obligations under this Agreement. B. This Agreement has been duly and validly executed and delivered by Company and, assuming due authorization, execution and delivery by the other parties hereto, is in full force and effect and is a valid and legally binding instrument of Company that is enforceable in accordance with its terms, except as the same may be limited by bankruptcy, insolvency, reorganization or other laws relating to or affecting creditors' rights generally. C. The execution and delivery of this Agreement, the consummation of the transactions contemplated hereby, and the fulfillment of or compliance with the terms and conditions of this Agreement are not prevented by, limited by, in conflict with, or result in a violation or breach of, the terms, conditions or provisions of any contractual restriction, evidence of indebtedness, agreement or instrument of whatever nature to which Company is now a party or by which it or its property is bound, nor do they constitute a default under any of the foregoing. D. There are no actions, suits or proceedings pending or threatened against or affecting Company in any court or before any arbitrator or before or by any governmental body in which there is a reasonable possibility of an adverse decision which could materially adversely affect the business (present or prospective), financial position, or results of operations of Company or which in any manner raises any questions affecting the validity of the Agreement or Company's ability to perform its obligations under this Agreement. E. The financing commitments, which Company will proceed with due diligence to obtain, to finance the construction of the Improvements will be sufficient to enable Company to successfully complete construction of the Improvements as contemplated in this Agreement, subject to additional costs incurred due to Unavoidable Delays. 9. Indemnification. Company hereby releases City, its elected officials, officers, employees, and agents (collectively, the "indemnified parties") from, covenants and agrees that the indemnified parties shall not be liable for, and agrees to indemnify, 5 defend and hold harmless the indemnified parties against, any loss or damage to property or any injury to or death of any person occurring at or about the Property. The indemnified parties shall not be liable for any damage or injury to the persons or property of Company or its members, managers, employees, contractors or agents, or any other person who may be about the Property or the Improvements, due to any act of negligence or willful misconduct of any person, other than any act of negligence or willful misconduct on the part of any such indemnified party or its officers, employees or agents. The provisions of this Section shall survive the expiration or termination of this Agreement. 10. Default. The following shall be "Events of Default" under this Agreement, and the term "Event of Default" shall mean any one or more of the following events that continues beyond any applicable cure periods: A. Failure by Company to cause the construction of the Improvements to be commenced and completed pursuant to the terms, conditions and limitations of this Agreement; B. Failure by Company to pay, before delinquency, all ad valorem property taxes levied on or against any of the Property; C. Failure by any party hereto to substantially observe or perform any covenant, condition, obligation or agreement on its part to be observed or performed under this Agreement; D. Company (1) files any petition in bankruptcy or for any reorganization, arrangement, composition, readjustment, liquidation, dissolution, or similar relief under the federal bankruptcy law or any similar state law; (2) makes an assignment for the benefit of its creditors; (3) admits in writing its inability to pay its debts generally as they become due; (4) is adjudicated a bankrupt or insolvent; or if a petition or answer proposing the adjudication of Company as a bankrupt or its reorganization under any present or future federal bankruptcy act or any similar federal or state law shall be filed in any court and such petition or answer shall not be discharged or denied within ninety (90) days after the filing thereof; or a receiver, trustee or liquidator of Company, or part thereof, shall be appointed in any proceedings brought against Company and shall not be discharged within ninety (90) days after such appointment, or if Company shall consent to or acquiesce in such appointment; or (5) defaults under any mortgage applicable to any of Property. E. Any representation or warranty made by Company in this Agreement, or made by Company in any written statement or certificate furnished by Company pursuant to this Agreement, shall prove to have been incorrect, incomplete or misleading in any material respect on or as of the date of the issuance or making thereof. 11. Remedies. 6 A. Default by Company. Whenever any Event of Default in respect of Company occurs and is continuing, the City may terminate this Agreement. Before exercising such remedy, City shall give 30 days' written notice to Company of the Event of Default, provided that by the conclusion of such period the Event of Default shall not have been cured, or the Event of Default cannot reasonably be cured within 30 days and Company shall not have provided assurances reasonably satisfactory to the City that the Event of Default will be cured as soon as reasonably possible. Upon termination, City may exercise any and all remedies available at law, equity, contract or otherwise for recovery of any sums paid by City to Company, if any, before the date of termination as set forth in this Agreement. B. Default by City. Whenever any Event of Default in respect of City occurs and is continuing, Company may take such action against City to require it to specifically perform its obligations hereunder. Before exercising such remedy, Company shall give 30 days' written notice to City of the Event of Default, provided that by the conclusion of such period the Event of Default shall not have been cured, or if the Event of Default cannot reasonably be cured within 30 days and City shall not have provided assurances reasonably satisfactory to the Company that the Event of Default will be cured as soon as reasonably possible. C. Remedies under this Agreement shall be cumulative and in addition to any other right or remedy given under this Agreement or existing at law or in equity or by statute. Waiver as to any particular default, or delay or omission in exercising any right or power accruing upon any default, shall not be construed as a waiver of any other or any subsequent default and shall not impair any such right or power. 12. Materiality of Company's Promises, Covenants, Representations, and Warranties. Each and every promise, covenant, representation, and warranty set forth in this Agreement on the part of Company to be performed is a material term of this Agreement, and each and every such promise, covenant, representation, and warranty constitutes a material inducement for City to enter this Agreement. Company acknowledges that without such promises, covenants, representations, and warranties, City would not have entered this Agreement. Upon breach of any promise or covenant, or in the event of the incorrectness or falsity of any representation or warranty, City may, at its sole option and in addition to any other right or remedy available to it, terminate this Agreement and declare it null and void. 13. Performance by City. Company acknowledges and agrees that all of the obligations of City under this Agreement shall be subject to, and performed by City in accordance with, all applicable statutory, common law or constitutional provisions and procedures consistent with City's lawful authority. All covenants, stipulations, promises, agreements and obligations of City contained in this Agreement shall be deemed to be the covenants, stipulations, promises, agreements and obligations of City and not of any governing body member, officer, employee or agent of City in the individual capacity of such person. 7 14. No Third-Party Beneficiaries. No rights or privileges of any party hereto shall inure to the benefit of any contractor, subcontractor, material supplier, or any other person or entity, and no such contractor, subcontractor, material supplier, or other person or entity shall be deemed to be a third-party beneficiary of any of the provisions of this Agreement. 15. Notices. Any notice under this Agreement shall be in writing and shall be delivered in person, by overnight air courier service, by United States registered or certified mail, postage prepaid, or by facsimile (with an additional copy delivered by one of the foregoing means), and addressed: (a) if to City, at 715 Mulberry Street, Waterloo, Iowa 50703, facsimile number 319-291-4571, Attention: Mayor, with copies to the City Attorney and the Community Planning and Development Director. (b) if to Company, at Twin Card Holdings LLC, 2120 Main Street, Cedar Falls, Iowa 50613, Attention: Jared Honermann and Jones Law Firm do Gary Jones, Cedar Falls, Iowa. Delivery of notice shall be deemed to occur (i) on the date of delivery when delivered in person, (ii) one (1) business day following deposit for overnight delivery to an overnight air courier service which guarantees next day delivery, (iii) three (3) business days following the date of deposit if mailed by United States registered or certified mail, postage prepaid, or (iv) when transmitted by facsimile so long as the sender obtains written electronic confirmation from the sending facsimile machine that such transmission was successful. A party may change the address for giving notice by any method set forth in this Section. 16. No Joint Venture. Nothing in this Agreement shall, or shall be deemed or construed to, create or constitute any joint venture, partnership, agency, employment, or any other relationship between the City and Company nor to create any liability for one party with respect to the liabilities or obligations of the other party or any other person. 17. Amendment, Modification, and Waiver. No amendment, modification, or waiver of any condition, provision, or term of this Agreement shall be valid or of any effect unless made in writing, signed by the party or parties to be bound or by the duly authorized representative of same, and specifying with particularity the extent and nature of the amendment, modification, or waiver. Any waiver by any party of any default by another party shall not affect or impair any rights arising from any subsequent default. 18. Severability; Reformation. Each provision, section, sentence, clause, phrase, and word of this Agreement is intended to be severable. If any portion of this Agreement shall be deemed invalid or unenforceable, whether in whole or in part, the offending provision or part thereof shall be deemed severed from this Agreement and the remaining provisions of this Agreement shall not be affected thereby and shall continue in full force and effect. If, for any reason, a court finds that any portion of this Agreement is invalid or unenforceable as written, but that by limiting such provision or portion thereof 8 it would become valid and enforceable, then such provision or portion thereof shall be deemed to be written, and shall be construed and enforced, as so limited. 19. Captions. All captions, headings, or titles in the paragraphs or sections of this Agreement are inserted only as a matter of convenience and/or reference, and they shall in no way be construed as limiting, extending, or describing either the scope or intent of this Agreement or of any provisions hereof. 20. Interpretation. This Agreement shall not be construed more strictly against one party than against the other merely by virtue of the fact that it may have been prepared by counsel for one of the parties, it being recognized that the parties hereto and their respective attorneys have contributed substantially and materially to the preparation of each and every provision of this Agreement. 21. Binding Effect. This Agreement shall be binding and shall inure to the benefit of the parties and their respective successors, assigns, and legal representatives. 22. Counterparts. This Agreement may be executed in multiple counterparts, each of which shall be deemed an original and all of which, taken together, shall constitute one and the same instrument. 23. Entire Agreement. This Agreement, together with the exhibits attached hereto, constitutes the entire agreement of the parties and supersedes all prior or contemporaneous negotiations, discussions, understandings, or agreements, whether oral or written, with respect to the subject matter hereof. 24. Time of Essence. Time is of the essence of this Agreement. IN WITNESS WHEREOF, the parties have executed this Development Agreement by their duly authorized representatives as of the date first set forth above. CITY OF WATERLOO, IOWA Twin Card Holdin s LLC By:• / ,� By: Quentin M. Hart, Mayor Jared Honer nn Managing ember Attest: elley Fel e, City Clerk 9 EXHIBIT "A" Legal Description of Property Lots 8, 9 and Northeasterly 60 feet in even width of Lot 10, all in Block 39, in the Original Plat, on the West Side of the Cedar River, in the City of Waterloo, Black Hawk County, Iowa. EXHIBIT "B" MINIMUM ASSESSMENT AGREEMENT This Minimum Assessment Agreement (the "Agreement") is entered into as of , 2025, by and among the CITY OF WATERLOO, IOWA("City"), TWIN CARD HOLDINGS LLC ("Company"), and the COUNTY ASSESSOR of the City of Waterloo, Iowa ("Assessor"). WITNESSETH: WHEREAS, on or before the date hereof the City and Company have entered into a development agreement (the "Development Agreement") regarding certain real property (the "Property"), described in Exhibit "A" thereto, located in the City; and WHEREAS, it is contemplated that pursuant to the Development Agreement, the Company will undertake the development of a property within a designated urban revitalization area of the City, including the construction of certain improvements as described in the Development Agreement (the "Minimum Improvements") on the Property (the "Project"); and WHEREAS, pursuant to Iowa Code § 404.3C, the City and the Company desire to establish a minimum actual value for the Property and the Minimum Improvements to be constructed thereon by Company pursuant to the Development Agreement, which shall be effective upon substantial completion of the Project and from then until this Agreement is terminated pursuant to the terms herein and which is intended to reflect the minimum actual value of the land and buildings as to the Project only; and WHEREAS, the City and the Assessor have reviewed the preliminary plans and specifications for the Minimum Improvements which the parties contemplate will be erected as a part of the Project. NOW, THEREFORE, the parties hereto, in consideration of the promises, covenants, and agreements made by each other, do hereby agree as follows: 1. Upon substantial completion of construction of the Minimum Improvements by Company, the minimum actual taxable value which shall be fixed for assessment purposes for the Property and Minimum Improvements to be constructed thereon by Company as a part of the Project shall not be less than $135,000.00 (the "Minimum Actual Value") until termination of this Agreement. The parties hereto agree that construction of the Minimum Improvements will be substantially completed by the date set forth in the Development Agreement, and in any case if the Minimum Improvements are not substantially completed by December 31, 2026 the parties agree to execute an amendment to this Agreement that will extend the date specified in Section 2 below. 2. The Minimum Actual Value herein established shall be of no further force and effect, and this Minimum Assessment Agreement shall terminate, on December 31, 2036. The Minimum Actual Value shall be maintained during such period regardless of: (a) any failure to complete the Minimum Improvements; (b)destruction of all or any portion of the Minimum Improvements; (c) diminution in value of the Property or the Minimum Improvements; or (d) any other circumstance, whether known or unknown and whether now existing or hereafter occurring. 3. Company shall pay, or cause to be paid, when due, all real property taxes and assessments payable with respect to all and any parts of the Property and the Minimum Improvements pursuant to the provisions of this Agreement and the Development Agreement. Such tax payments shall be made without regard to any loss, complete or partial, to the Property or the Minimum Improvements, any interruption in, or discontinuance of, the use, occupancy, ownership or operation of the Property or the Minimum Improvements by Company or any other matter or thing which for any reason interferes with, prevents or renders burdensome the use or occupancy of the Property or the Minimum Improvements. 4. Company agrees that its obligation to make the tax payments required hereby, to pay the other sums provided for herein, and to perform and observe its other agreements contained in this Agreement shall be absolute and unconditional obligations of Company (not limited to the statutory remedies for unpaid taxes) and that Company shall not be entitled to any abatement or diminution thereof, or set off therefrom, nor to any early termination of this Agreement for any reason whatsoever. 5. Nothing herein shall be deemed to waive the Company's rights under Iowa Code § 404.3C to contest that portion of any actual value assignment made by the Assessor in excess of the Minimum Actual Value established herein. In no event, however, shall the Company seek or cause the reduction of the actual value assigned below the Minimum Actual Value established herein during the term of this Agreement. Nothing herein shall limit the discretion of the Assessor to assign at any time an actual value to the land and Minimum Improvements in excess of the Minimum Actual Value. 6. Company agrees that during the term of this Agreement it will not: (a) seek administrative review or judicial review of the applicability or constitutionality of any Iowa tax statute relating to the taxation of property contained as a part of the Property or the Minimum Improvements determined by any tax official to be applicable to the Property or the Minimum Improvements, or raise the inapplicability or constitutionality of any such tax statute as a defense in any proceedings, including delinquent tax proceedings; or 2 (b) seek any tax deferral, credit or abatement, either presently or prospectively authorized under Iowa Code Chapter 403 or 404, or any other state law, of the taxation of real property, including improvements and fixtures thereon, contained in the Property or the Minimum Improvements; or (c) request the Assessor to reduce the Minimum Actual Value; or (d) appeal to the board of review of the city, county, state or to the Director of Revenue of the State of Iowa to reduce the Minimum Actual Value; or (e) cause a reduction in the actual value or the Minimum Actual Value through any other proceedings. 7. This Agreement shall be promptly recorded by the City with the Recorder of Black Hawk County, Iowa. The City shall pay all costs of recording. 8. Neither the preambles nor provisions of this Agreement are intended to, or shall be construed as, modifying the terms of the Development Agreement. 9. Each provision, section, sentence, clause, phrase, and word of this Agreement is intended to be severable. If any portion of this Agreement shall be deemed invalid or unenforceable, whether in whole or in part, the offending provision or part thereof shall be deemed severed from this Agreement and the remaining provisions of this Agreement shall not be affected thereby and shall continue in full force and effect. If, for any reason, a court finds that any portion of this Agreement is invalid or unenforceable as written, but that by limiting such provision or portion thereof it would become valid and enforceable, then such provision or portion thereof shall be deemed to be written, and shall be construed and enforced, as so limited. 10. This Agreement shall inure to the benefit of and be binding upon the successors and assigns of the parties, including but not limited to future owners of the Project property. IN WITNESS WHEREOF, the parties have executed this Minimum Assessment Agreement by their duly authorized representatives as of the date first set forth above. [signatures on next page] 3 CITY OF WATERLOO, IOWA TWIN CARD HO DINGS LLC By: By: Quentin Hart, Mayor Jared Hon a n Managing Member By: elley F chle, City Clerk STATE OF IOWA ) ) ss. COUNTY OF BLACK HAWK ) On this t_j day of C , 2025, before me, a Notary Public in and for the State of Iowa, personally ppeared Quentin Hart and Kelley Felchle, to me personally known, who being duly sworn, did say that they are the Mayor and City Clerk, respectively, of the City of Waterloo, Iowa, a municipal corporation, created and existing under the laws of the State of Iowa, and that the seal affixed to the foregoing instrument is the seal of said municipal corporation, and that said instrument was signed and sealed on behalf of said municipal corporation by authority and resolution of its City Council, and said Mayor and City Clerk acknowledged said instrument to be the free act and deed of said municipal corporation by it and by them voluntarily executed. PI^� PERKINS BRITNI C lic Z ma COMMISSION NO.845529 *°am is MY JAtZSZ 27,2026RES IOWA STATE OF IOWA ) ) ss. COUNTY OF BLACK HAWK ) Subscribed and sworn to before me on 1 \Q� 5 , 2025 by Jared Honermann as Managing Member of Twin Card Holdings LC C. TRA S ROSS Z � � COMMISSION N NO.811963 *nn„,„* MY C2 MMISSION EXPIRES 'OWE 3`2c> Notary Public 4 1 • • • • t, 3a •+ I. to • • 2ECOH ADAPT CERTIFICATION OF ASSESSOR The undersigned, having reviewed the plans and specifications for the Minimum Improvements to be constructed and the market value assigned to the land upon which the Minimum Improvements are to be constructed for the development, and being of the opinion that the minimum market value contained in the foregoing Minimum Assessment Agreement appears reasonable, hereby certifies as follows: The undersigned Assessor, being legally responsible for the assessment of the property described in the foregoing Minimum Assessment Agreement upon completion of the improvements to be made on it, certifies that the actual value assigned to the land and improvements upon completion shall not be less than One Hundred Thirty-Five Thousand and 00/100 Dollars ($135,000.00) until termination of this Minimum Assessment Agreement pursuant to the terms hereof, subject to adjustment as provided in said agreement. Assessor for Black Hawk County, Iowa Date STATE OF IOWA ) ) ss. COUNTY OF BLACK HAWK ) Subscribed and sworn to before me on , 2025 by T.J. Koenigsfeld, Assessor for Black Hawk County, Iowa. Notary Public