Loading...
HomeMy WebLinkAboutASPRO - Runway 18-36 Rehab FAA #3-19-0094-059-2026 - 3.16.2026 CONTRACT FOR IMPROVEMENTS TO THE WATERLOO REGIONAL AIRPORT CONSISTING OF RUNWAY 18-36 REHABILITATION WITHIN RUNWAY 12-30 SAFETY AREA FAA#3-19-0094-059-2026 AT THE WATERLOO REGIONAL AIRPORT WATERLOO,IOWA THIS AGREEMENT,made and entered into this \kP day of Kt rah ,2026,by and between the Waterloo Regional Airport for the City of Waterloo, Black Hawk County, Iowa,hereinafter referred to as the "Owner" and ASPRO.Inc.,a corporation organized and existing under the laws of the State of Iowa,hereinafter referred to as the "Contractor." WITNESSETH: That the Contractor for and in consideration of Two Million One Hundred Forty-Seven Thousand Seven Hundred Fifty Dollars($2,147,750.00),based on the unit bid prices payable as set forth in the Specifications constituting a part of this Contract,hereby agrees to construct in accordance with the Plans,Specifications and Special Provisions therefore,and in the location designated on the Plans,the various items of work awarded said Contractor on the day of ,2026,as follows,being numbered one through sixteen(1-16) as shown in schedule of prices bid in the attached Proposal which is a part of this Contract. Said Specifications and Plans are hereby made a part of and the basis of this Agreement and a true copy of said Plans and Specifications is now with the Waterloo Regional Airport in the office of the Director of Aviation,Waterloo,Iowa,under date of February 12,2026. 1. That in consideration of the foregoing,the Owner hereby agrees to pay the Contractor promptly and according to the requirements of the Specifications, the amounts set forth, subject to the conditions as set forth in the Specifications. 2. That it is understood that the parties named herein are the only persons interested in this Contract and principals. 3. That the Contractor has examined the site of the proposed work,Plans, Specifications, Special Provisions and Contract Documents in order that he might become familiar with the character,quality and quantity of the work to be performed,the materials to be furnished and the requirements of the Specifications,Special Provisions and Contract Documents. 4. It is hereby further agreed that any reference herein to the"Contract"shall include all"Contract Documents" for the Waterloo Regional Airport,FAA Project No.3-19-0094-059-2026 and said"Contract Documents"are hereby made a part of this agreement as fully as if set out at length herein,and that this contract is limited to the items in the proposal as signed by the"Contractor"and included in the"Contract Documents." 5. That in the event any surety upon any bond furnished in connection with this Contract becomes unacceptable to the Owner,or if any such surety shall fail to furnish reports as to his financial condition from time to time as requested by the Owner,the Contractor agrees to furnish promptly such additional security as may be required from time to time to protect the interests of the Owner or of persons supplying labor or materials in the prosecution of the work contemplated by the Contract. 6. That the Contractor shall not commence any work to be performed under this Contract until he has obtained from responsible insurance companies, all insurance required, as set forth in the General Provisions and that the Contractor shall maintain this insurance in full force and effect until the work to be performed under this Contract has been accepted by the Owner. FAA AIP#3-19-0094-059-2026 C-1 Waterloo Regional Airport AECOM Project#60747512 Runway 18-36 Rehab within RSA 7. That the Contractor shall not start working on any alterations requiring a supplemental agreement until the agreement setting forth the adjusted price shall be executed by the Owner and the Contractor. 8. That the Contractor,at all times,shall observe and comply with all federal,state,territory or possession and local laws,codes,ordinances and regulations in any manner affecting the conduct of the work,and the Contractor and his surety shall indemnify and save harmless the Owner and all his officers,Engineer,agents and servants against claims or liability arising from or based on the violation of any such law,ordinance,deregulation,order or decree, whether by himself or his employees. 9. That it is further understood and agreed by the parties to this Contract that the above work shall be commenced within 15 days after"Notice to Proceed"and shall be completed according to the terms of the entire contract within sixty(60)calendar days from the date established in the Notice to Proceed.Failure to complete within the allotted time will result in assessment of liquidated damages in the amount of$500.00 per calendar day for each day in excess of the authorized contract time. In addition,the Runway 18-36 and Runway 12-30 closures for Phase 1 work shall be limited to fifteen(15)calendar days.Failure to complete Phase 1 work and re-open Runway 18-36 and Runway 12-30 to traffic within the allotted time will result in assessment of liquidated damages in the amount of$10,000 per calendar day for each day in excess of the fifteen(15)calendar days allotted in the contract. 10. The Contractor and Owner understand and agree that time is of essence for completion of the Work and that the Owner will suffer additional expense and financial loss if said work is not completed within the authorized Contract Time. Furthermore, the Contractor and Owner recognize and understand the difficulty, delay, and expense in establishing the exact amount of actual financial Ioss and additional expense. Accordingly,in place of requiring such proof,the Contractor expressly agrees to pay the Owner as liquidated damages the non-penal sum of $500.00 per day for each calendar day required in excess of the authorized Contract Time for the overall contract. Furthermore,the Contractor understands and agrees that: a. the Owner has the right to deduct from any moneys due the Contractor,the amount of said liquidated damages; b. the Owner has the right to recover the amount of said liquidated damages from the Contractor,Surety,or both, 11. The Contractor understands and agrees that all certifications made by the Contractor within the Proposal shall apply under this Agreement as if fully rewritten herein. The Contractor further certifies the following: a. Certification of Eligibility(29 CFR Part 5.5) (1) By Entering into this contract,the Contractor certifies that neither he or she nor any person or firm who has an interest in the Contractor's firm is a person or firm ineligible to be awarded Government contracts by virtue of Section 3(a)of the Davis-Bacon Act or 29 CFR 5.12(a)(1); (2) No part of this contract shall be subcontracted to any person or firm ineligible for award of a Government contract by virtue of Section 3(a)of the Davis-Bacon Act or 29 CFR 5.12(a)(1); (3) The penalty for making false statements is prescribed in the U.S.Criminal Code 18 U.S.C. b. Certification of Non-Segregated Facilities(41 CFR Part 60-1.8) The federally assisted construction Contractor,certifies that it does not maintain or provide,for its employees, any segregated facilities at any of its establishments and that it does not permit its employees to perform their services at any location,under its control,where segregated facilities are maintained. The Bidder certifies that it will not maintain or provide,for its employees,segregated facilities at any of its establishments and that it will not permit its employees to perform their services at any location under its control where segregated facilities are maintained. The Bidder agrees that a breach of this certification is a violation of the Equal Opportunity Clause,which is to be incorporated in the contract. As used in this certification,the term"segregated facilities"means any waiting rooms,work areas,restrooms, and washrooms,restaurants and other eating areas, timeclocks, locker rooms and other storage or dressing areas,parking lots,drinking fountains,recreation or entertaimnent areas,transportation,and housing facilities provided for employees which are segregated on the basis of race,color,religion,or national origin because of FAA AIP#3-19-0094-059-2026 C-2 Waterloo Regional Airport AECOM Project#60747512 Runway 18-36 Rehab within RSA habit, local custom, or any other reason. The Bidder agrees that(except where it has obtained identical certifications from proposed subcontractors for specific time periods)it will obtain identical certifications from proposed subcontractors prior to the award of subcontracts exceeding$10,000 which are not exempt from the provisions of the Equal Opportunity Clause and that it will retain such certifications in its files. 12. It is further understood that any action in court against the Contractor or sureties on his bond because of damage to property or individuals by said Contractor or his workmen,or because of the violation of any provisions of the Specifications,or on account of the failure of said Contractor to fully comply with these provisions, shall be brought in the District Court of the State of Iowa in and for Black Hawk County. 13. Second Party shall maintain all work done hereunder in good order for a period of 12 months from and after the date it is accepted by the Waterloo Regional Airport,City of Waterloo,Iowa,which maintenance shall be without expense to First Party or the abutting property. In the event of the failure or default of Second Party to remedy any or all defects appearing in said work within a period of 12 months from the date of its acceptance by said Board and after having been given fifteen(15)days'notice so to do by registered letter deposited in the United States Post Office in said City, addressed to said Contractor at the address herein given,then First Party may proceed to remedy such defects and the cost and expenses thereof may be recovered from said Second Party and the sureties on its bond by action brought in any court of competent jurisdiction,but such suit may be brought in the District Court of Black Hawk County,Iowa. IN WITNESS WHEREOF,the parties hereto have set their hands for the purpose herein expressed to this and three other instruments of like tenor,as of the I to day of JAarckl,2026. CITY OF WATERLOO By Mayor ATTEST: - tidaty CI 4\.1 CA e.r c CONTRACTOR ASPRO.Inc. /, ""1 Firm Name By ,` Pre 1 UFe n 4 Signature l Title 3La3 Tea Po AoxZb20 `,I CIL-Yj 0ot24 6070Ij Business Address Witness Witness FAA AIP#3-19-0094-059-2026 C-3 Waterloo Regional Airport AECOM Project#60747512 Runway 18-36 Rehab within RSA Bond Amount:2383755 PERFORMANCE BOND KNOW ALL MEN BY THESE PRESENTS: That we, ASPRO, Inc., as PRINCIPAL, also referred to as CONTRACTOR,and Swiss Re Corporate Solutions America Insurance Corporation as SURETY,are held and firmly bound unto Waterloo Regional Airport,2790 Livingston Lane,Waterloo,Iowa 50703 as OWNER,in the full sum of Two Million One Hundred Forty-Seven Thousand Seven Hundred Fifty Dollars($2,147,750.00)for the payment of which,well and truly to be made,we bind ourselves,our heirs,executors,administrators,successors and assigns,jointly and severally,by these presents. WHEREAS,the above-bound Principal has entered into a contract with the OWNER dated the day of_ ,2026,for Runway 18-36 Rehabilitation within Runway 12-30 Safety Area, including: • Rehabilitation of Runway 18/36 and Runway 12-30 intersection with 4-inch mill and overlay of the pavement within the Runway Safety Areas. • Grooving of the new runway pavement. • Pavement marking for the new pavement. • Restoration along the edge of the new pavement. This work and all other incidentals shall be performed as shown on the Drawings and described in the Specifications. NOW,THEREFORE,the conditions of this obligation are such that if the above-bound PRINCIPAL shall faithfully and fully comply with the terms and conditions of said contract,including,but not limited to,any obligations created by way of warranties and/or guarantees for workmanship and materials which warranty and/or guarantee may extend for a period of time beyond completion of said contract,and such alternations or additions as may be made therein or in the plans and specifications,and shall indemnify and save the OWNER harmless against any claims for using any form of material, process,composition or anything which is patented,and likewise indemnify and save the OWNER harmless against all claims for damages by reason or any default or negligence,want of skill or care on the part of said PRINCIPAL or Agents in and about the performance of said contract,and shall comply with all laws pertaining to said work,and shall comply with and perform any and all warranties and/or guarantees provided for in said contact,then this obligation shall be void;otherwise of full force and effect. PROVIDED,further than upon either the default of the PRINCIPAL,or the failure of the said PRINCIPAL to promptly and efficiently prosecute said Work, in any respect, in accordance with the Contract Documents,the above bound SURETY shall either remedy the default of the PRINCIPAL or shall take charge of said Work and complete the Contract at his own expense,pursuant to its terms,receiving,however,any balance of the funds in the hands of said OWNER due under said contract. It shall be the duty of the SURETY to give an unequivocal notice in writing to the OWNER within fifteen(15)days after receipt of a declaration of default of the SURETY'S election either to remedy the default or defaults promptly or to perform the contract promptly,time being of the essence. In said notice of election,the SURETY shall indicate the date on which the remedy or performance will commence,and it shall be the duty of the SURETY to give prompt notice in writing to the OWNER immediately upon completion of(a)the remedy and/or correction of each default,(b)the remedy and/or correction of each item of condemned work, (c) the furnishings of each omitted item of work, and (d) the performance of the contract. The SURETY shall not asset solvency of its PRINCIPAL as justification for its failure to promptly remedy the default or defaults or perform the contract. In the event said PRINCIPAL shall fail or delay the prosecution and completion of said Work and said SURETY shall also fail to act promptly as hereinabove provided,then the OWNER shall cause fifteen(15)days notice of such failure to be given,both to said PRINCIPAL and SURETY,and at the expiration of said fifteen(15)days,if said PRINCIPAL or SURETY do not proceed promptly to execute said Contract,the OWNER shall have the authority to cause said Work to be done and when the same is completed and the cost thereof estimated,the said PRINCIPAL and SURETY shall and hereby agree to pay any excess in the cost of said Work above the agreed price to be paid under said Contract. Upon completion of said Contract pursuant to its terms,if any funds remain due on said Contract,the same shall be paid to said PRINCIPAL and SURETY. FAA AIP#3-19-0094-059-2026 C-4 Waterloo Regional Airport AECOM Project#60747512 Runway 18-36 Rehab within RSA The said PRINCIPAL and SURETY further agree as part of this obligation to pay all such damages of any kind to person or property that may result from a failure in any respect to perform and complete said Contract including,but not limited to.all repair and replacement costs necessary to rectify construction error,architectural and engineering costs and fees, all(but not limited to)consultant fees,all testing and laboratory fees,and all legal fees and litigation costs incurred by the OWNER. The decision of the OWNER,upon any disputed question connected with the execution of said Contract,or any failure or delay in the prosecution of the Work by said PRINCIPAL or SURETY,shall be final and conclusive. The SURETY agrees that other than as is provided in this bond,it may not demand of the OWNER the OWNER shall (a)perform any thing or act,(b)give any notice,(c)furnish any clerical assistance,(d)render any service,(3)furnish any papers or documents,or(f)take any other action of any nature or description which is not required of the OWNER to be done under the contract documents. IN WITNESS WHEREOF,the SURETY and PRINCIPAL have executed this instrument under their several seals this day of ,2026.the name and corporate seal of each corporate party being hereto affixed and these presents duly signed by its undersigned representative,pursuant to authority of its governing body. IN THE PRESENCE OF: PRINCI / L: i s%o/nc. Witness By: &cc) to `^ u ) j f /1 RE Swiss Re Corporat •Iutior�America ' Insurance Co • r i n / ••. fi LIU 04,4 _ Witne r Sara Huston ; S E AL lel . gr By: Jamie Gifford,Attorney-in-Fact 4;•, 1973 s NOTE: (a) Where the Performance Bond is executed by an attorney-in-fact,there shall be attached to each copy of the Bond a certified copy of Power of Attorney properly executed and dated. (b) Each copy of the Bond shall be countersigned by an authorized agent of the bonding company licensed to do business in the State of Iowa. The title of the person countersigning the Bond shall appear after his or her signature. (c) The seal of the bonding company shall be attached to each copy of the bond. (d) The Contractor's signature on the bond shall correspond with the signature in the contract. (e) The bond shall be accompanied by a corporate resolution(which may be combined with the corporate resolution granting the signing officer authority to execute contracts)granting the corporate officer who executes the Bond the authority to do so. (f) Surety companies executing bonds must appear on the Treasury Department's most current list(Circular 570 as amended)and be authorized to transact business in the State of Iowa. FAA AIP#3-19-0094-059-2026 C-5 Waterloo Regional Airport AECOM Project#60747512 Runway 18-36 Rehab within RSA Bond Number:2383755 PAYMENT BOND KNOW ALL MEN BY THESE PRESENTS: That we, ASPRO, Inc., as PRINCIPAL, also referred to as CONTRACTOR,and Swiss Re Corporate Solutions America Insurance Corporation,as SURETY,are held and firmly bound unto Waterloo Regional Airport,2790 Livingston Lane,Waterloo,Iowa 50703 as OWNER,in the full sum of Two Million One Hundred Forty-Seven Thousand Seven Hundred Fifty Dollars($2,147,750.00),for the use and protection of said OWNER and all subcontractors and all persons supplying labor, materials, machinery and equipment for the performance of the work provided for in the contract hereinafter referred to,for the payment of which,well and truly to be made,we bind ourselves,our heirs,executors,administrators,successors and assigns,jointly and severally,by these presents. WHEREAS,the above-bound Principal has entered into a contract with the OWNER dated the day of ,2026,for Runway 18-36 Rehabilitation within Runway 12-30 Safety Area, including: • Rehabilitation of Runway 18/36 and Runway 12-30 intersection with 4-inch mill and overlay of the pavement within the Runway Safety Areas. • Grooving of the new runway pavement. • Pavement marking for the new pavement. • Restoration along the edge of the new pavement. This work and all other incidentals shall be performed as shown on the Drawings and described in the Specifications. NOW.THEREFORE,the condition of this obligation is such that if the above-bound PRINCIPAL shall promptly make payment to all claimants as hereinafter defined, for all labor and materials supplied in the prosecution of the work provided for in said Contract,then this obligation shall be void;otherwise,it shall remain in full force and effect,subject, however,to the following conditions: 1. The said SURETY to this bond, for value received, hereby stipulates and agrees that no change or changes, extension of time or extensions of time,alteration of alterations or addition or additions to the terms of the contract or to the work to be performed thereunder,or the specifications or drawings accompanying same shall in any wise affect its obligation on this bond,and it does hereby waive notice of any such change or changes,extension of time or extensions of time,alteration or alterations or addition or additions to the terms of the contract or to the work or to the specifications or drawings. 2. A claimant is defined as any subcontractor and any person supplying labor,materials,machinery,or equipment in the prosecution of the work provided for in said contract. Signed and sealed this day of ,2026. IN THE PRESENCE OF: \ PRIN 1.PAL.'AsVinci _\ c>�- r-4.7- s ! / / Witness L._,.0....>„\._.0„,, By: g)ra) 51603 SU Swiss Re Corporate Solutions America Insurance Corporate g�'�sy ` <'3� 9R4 ,,--„,i Sara Huston '- A�- "_ By: Jamie Gifford,Attorney-in-Fact 1 1. ' 9 3 y' :;'ae;.yfSSOU4`:. FAA AlP#3-19-0094-059-2026 C-6 Waterloo Regional Airport AECOM Project#60747512 Runway 18-36 Rehab within RSA NOTE: (a) Where the Payment Bond is executed by an attorney-in-fact,there shall be attached to each copy of the Bond a certified copy of Power of Attorney properly executed and dated. (b) Each copy of the Bond shall be countersigned by an authorized agent of the bonding company licensed to do business in the State of Iowa. The title of the person countersigning the Bond shall appear after his or her signature. (c) The seal of the bonding company shall be attached to each copy of the bond. (d) The Contractor's signature on the bond shall correspond with the signature in the contract. (e) The bond shall be accompanied by a corporate resolution(which may be combined with the corporate resolution granting the signing officer authority to execute contracts)granting the corporate officer who executes the Bond the authority to do so. (f) Surety companies executing bonds must appear on the Treasury Department's most current list(Circular 570 as amended)and be authorized to transact business in the State of Iowa. FAA AIP 43-19-0094-059-2026 C-7 Waterloo Regional Airport AECOM Project#60747512 Runway 18-36 Rehab within RSA ij SWISS RE CORPORATE SOLUTIONS SWISS RE CORPORATE SOLUTIONS AMERICA INSURANCE CORPORATION("SRCSAIC") SWISS RE CORPORATE SOLUTIONS PREMIER INSURANCE CORPORATION("SRCSPIC") WESTPORT INSURANCE CORPORATION("WIC') GENERAL POWER OF ATTORNEY , KNOW ALL MEN BY THESE PRESENTS,THAT SRCSAIC,a corporation duly organized and existing under laws of the State of Missouri,and having its principal office in the City of Kansas City,Missouri,each does hereby make,constitute,and appoint: JAY D.FREIERMUTH,CRAIG E.HANSEN,BRIAN M.DEIMERLY•ANNE CROWNER,TIM MCCULLOH,DIONE R.YOUNG,SETH ROOKER.JENNIFER MARINO• JOSEPH TIERNAN,KATE ZANDERS,SARA HUSTON.JOHN CORD,GRACE DICKINSON,CAMERON BURT.BEN WILLIAMS,JAMIE GIFFORD and ZACH FULLER JOINTLY OR SEVERALLY Its true and lawful Attorney(s)-in-Fact,to make,execute,seal and deliver,for and on its behalf and as its act and deed,bonds,consents of surety,or other writings obligatory in the nature of a bond on behalf of each of said Companies,as surety,on contracts of suretyship as are or may be required or permitted by.law,regulation,contract or otherwise,provided that no bond or undertaking or contract or suretyship executed under this authority shall exceed the amount of: ONE HUNDRED TWENTY FIVE MILLION($125,000,000,00)DOLLARS This Power of Attorney is granted and is signed by facsimile under and by the authority of the following Resolutions adopted by the Boards of Directors of both SRCSAIC and SRCSPIC at meetings duly called and held on the I8°i of November 2021 and WIC by written consent of its Executive Committee dated July 1S,2011: "RESOLVED,that any two of the President,any Managing.Director,any Senior Vice President,any Vice President,the Secretary or any Assistant Secretary be,and each or any of them hereby is,authorized to execute a Power of Attorney qualifying the attorney named in the given Power of Attorney to execute on behalf of the Corporation bonds,undertakings and all contracts of surety,and that each or any of them hereby is authorized to attest to the execution of any such Power of Attorney and to attach therein the seal of the Corporation; and it is FURTHER RESOLVED,that the signature of such officers and the seal of the Corporation may be affixed to any such Power of Attorney or to any certificate relating thereto by facsimile,and any such Power of Attorney or certificate bearing such facsimile signatures or facsimile seal shall be binding upon the Corporation when so affixed and in the future with regard to an bond,undertaking or contract of surety to which it is attached." �tfµr rvti5od6TroNs' 't� iia6 DNSA, By J� �t• ,�,��p,I�� rF.•ry=- ;oQ3•r •es David Salop,Senior Vice :Went o C&Senior Vice President CV`L.e� i�>• J a gyp_. u J �'.�- of SRCSPIC&Senior Vice President of WIC � SEAL. 's tY-, 1973 .41 : s d'•. .y p � •aS8'• F59. 'p�� ,"S:•..J550`;. ''J%ei- By ! tt '•/'f`S• *. 'dt" f3 'd a G.Vr,ri Jacque;Scoi,,r t r Pre.lent•tf.sitr'S.tlf&i ice President ,# •"""• •""'" "'•••, ^•"" of SRCSPIC&S lot to President of tt lf , IN WITNESS WHEREOF,SRCSAIC have caused their official seals to be hereunt ai \ed,and these 1 _ 'nts be signed by their authorized officers this 1 ltgiay of June ,20 25 Swiss Re Corporate Solutions America Insurance Corporation State of Illinois Swiss Re Corporate Solutions Premier Insurance Corporation County of Cook ss Westport Insurance Corporation 11' June 25 On this day of ,20 ,before me,a Notary Public personally appeared David Satorv,Senior Vice President of SRCSAIC and Senior Vice President of SRCSPIC and Senior Vice President of WIC,and Gabriel Jacauez,.Senior Vice President of SRCSAIC and Senior Vice President o SRCSPIC and Senior Vice President of WIC,personally known to me,who being by me duly sworn,acknowledged that they signed the above Power of Attorney o c o a ac ,ow(edged said instrument to be the voluntary act and deed of their respective co anies. OFFICIAL SEAL KAREN M SZWEDA Notary Public,State or Illinois Commission No 978628 aren M. a,Notary M Commission Expires September 26 2027 I,Jeffrey Goldberg,the duly elected Senior Vice President and Assistant Secretary of SRCSAIC and SRCSPIC and WIC do hereby certify that the above and foregoing is a true and correct copy of a Power of Attorney given by said SRCSAIC and SRCSPIC and WIC,which is still in full force and effect. IN WITNESS WHEREOF,I have set my hand and affixed the seals of the Companies this day of .20 26 rec Goldberg,Senior 'ice c Preside Secretary of SRCSAIC and SRCSPIC and WIC ' ® DATE IMM1DDIYYYY) A COI? CERTIFICATE OF LIABILITY INSURANCE 7/9/2026 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER.THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW, THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED,the policy(les)must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION 1S WAIVED,subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER CONTACT NAME; Denise Allex Arthur J.Gallagher Risk Management Services,LLC PHONM.E FAX,WI:605 275-1954 fax,No):605-338 0552 4201 Westown Parkway E-MAIL SuiteSuite 120 ADDRESS: Denise Aliexrarajg.com West Des Moines IA 50266 INSURER(S)AFFORDING COVERAGE NAICif INSURER A:The Cincinnati Insurance Company 10677 INSURED INSURER B: Asro,Inc. P.O.Box 2620 INSURER C: Waterloo IA 50704 INSURER D: INSURER E: INSURER F: COVERAGES CERTIFICATE NUMBER:6819358 REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR ADOL SUER POLICY EFF POLICY EXP • LTR TYPE OF INSURANCE man WVD POLICY NUMBER _„(ylM/DD/YYYY) (MM?DD(YYYYI LIMITS • A X COMMERCIAL GENERAL LIABILITY Y EPP0732423 12/1/2025 12/1/2026 EACH OCCURRENCE $1,000,000 • DAMAGE RENTED . CLAIMS-MADE X OCCUR PREMISESO(Ea occurs nce) $100,000 MED EXP(Any one person) $5,000 PERSONAL&ADV INJURY $1,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $2,000,000 X POLICY X OF X LOC PRODUCTS-COMP/OP AGG $2,000,000 OTHER: Emp Benefits $2,000,000 A AUTOMOBILE LIABILITY EPP 0732423 12/1/2025 12/1/2026 COMBINED SINGLE LIMIT $1,000,000 (Ea accident) X ANY AUTO BODILY INJURY(Per person) $ OWNED SCHEDULED BODILY INJURY(Per accident) $ _AUTOS ONLY AUTOS x HIRED X NON-OWNED PROPERTY DAMAGE $ AUTOS ONLY AUTOS ONLY (Per accident? A X UMBRELLA LIAB X OCCUR EPP 0732423 12/1/2025 12/1/2026 EACH OCCURRENCE $10,000,000 EXCESS LIAB CLAIMS-MADE AGGREGATE $10,000,000 DED X RETENTIONS imnn _ $ A WORKERS COMPENSATION EWC 0732420 1211/2025 12/1/2026 X STATUTE OETRH- AND EMPLOYERS'LIABILITY Y(N ANYPROPRIErOR/PARTN ER/EXECUTIVE E.L.EACH ACCIDENT $500,000 OFFICER/MEMBER EXCLUDED? I I N IA (Mandatory in NH) E.L DISEASE-EA EMPLOYEE $500,000 It yes,describe under DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT $500,000 DESCRIPTION OF OPERATIONS I LOCATIONS/VEHICLES(ACORD 101,Additional Remarks Schedule,may be attached If more space Is required) Waterloo Regional Airport,the City of Waterloo and AECOM Technical Services,Inc.is additional insured on the general liabiNty(CG74820108)policy in regards to Any and All Work Performed. CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN Waterloo Regional Airport ACCORDANCE WITH THE POLICY PROVISIONS. 2790 Livingston Lane Waterloo IA 50703 AUTHOARIZED REPRESENTATIVE USA Art J. caZlccadletee 2i ?1/440t4na.cjeAT emt-Sev'vi,Ge'; LLC ©1988-2015 ACORD CORPORATION. All rights reserved. ACORD 25(2016103) The ACORD name and logo are registered marks of ACORD