Loading...
HomeMy WebLinkAboutTERMINAL BUILDING CARPET AXOM Terminal Building Carpet - TERMINAL IMPROVEMENTS Waterloo Regional Airport IDOT CSVI PROJECT NO. 9I190AL0200 IDOT CONTRACT NO. 20601 _.... i ERLOO REGIONAL AIRPORT CRUISE A NEW ALTER DE. Prepared For. City of Waterloo 715 Mulberry Street Waterloo, Iowa 50703 Prepared By: AECOM 501 Sycamore Street, Suite 222 P.O. Box 1497 Waterloo, Iowa 50704-1497 May 28, 2019 • Terminal Building Carpet - TERMINAL IMPROVEMENTS -- WATERLOO REGIONAL AIRPORT In the City of Waterloo, Iowa IDOT CSVI PROJECT NO. 91190AL0200 IDOT CONTRACT NO. 20601 Prepared For: City of Waterloo, Iowa Prepared By: AECOM May 2019 I hereby certify that this engineering document was prepared by me or under my direct personal supervision and that I am a duly licensed } 'k"`yj sfr'$= Professional Engineer under the laws of the state of Iowa. ��pggq} 1. 8\..T Ittt' *' .t .� May 28, 2019 * DAVID B. DA ID B. HUGHES PE Date 13037 * * License No. 13037 ,$yt ********** ' '/ My license renewal date is December 31, 2019. '`'t>, 1 O w Pages or sheets covered by this seal: Terminal Building Carpet - TERMINAL IMPROVEMENTS WATERLOO REGIONAL AIRPORT CONTRACT DOCUMENTS TABLE OF CONTENTS 1. NOTICE TO BIDDERS NTB-1-4 2. NOTICE OF PUBLIC HEARING NPH 1-2 3. INSTRUCTIONS TO BIDDERS IB 1-10 4. FORM OF BID OR PROPOSAL FB 1-2 5. SALES TAX EXEMPTION INFORMATION FORM STE 1 6. FORM OF BID BOND BB 1 7. NON-COLLUSION AFFIDAVITS NCA 1-2 8. TARGETED SMALL BUSINESS (TSB) PRE-BID CONTACT INFORMATION TSB-1 9. EQUAL OPPORTUNITY CLAUSE EO 1-2 10. TITLE VI CIVIL RIGHTS TVI 1 11. BIDDER STATUS FORM 1-2 12. AFFIRMATIVE ACTION PROGRAM 1-9 12. POTENTIAL ITEMS OF WORK FOR MBE/WBE PARTICIPATION M 1 SUBCONTRACTOR'S BID REQUEST FORM, M 2 LETTER FORM FOR SUBCONTRACTOR QUOTES, M 3 MBE/WBE SCOPE LETTER, M 4 MBE AND/OR WBE PREBID CONTACT INFORMATION FORM M 5-6 13. WATERLOO/CEDAR FALLS MINORITY AND WOMEN BUSINESSES ENTERPRISE CONSTRUCTION AND MAINTENANCE CONTRACTOR'S GUIDE 1-4 14. STATEMENT OF BIDDER'S QUALIFICATIONS SBQ 1-2 15. TARGETED SMALL BUSINESS (TSB) CONTRACT PROVISION TSB 1-6 16. GENERAL SPECIAL PROVISIONS GSP 1-5 17. SPECIAL PROVISIONS SP 1-4 Section 09 68 00 - Carpet 09 68 00-1-9 16. GENERAL SPECIFICATIONS FOR CONSTRUCTION GS 1-13 17. SUPPLEMENTAL GENERAL SPECIFICATIONS FOR CONSTRUCTION SGS 1 TABLE OF CONTENTS CSVI 91190AL0200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 18. FORM OF CONTRACT C 1-3 19. FORM OF PERFORMANCE BOND PFB 1-2 - 20. FORM OF PAYMENT BOND PB 1-2 APPENDIX - PLAN SHEETS PHOTOGRAPHS OF EXISTING CONDITIONS _. TABLE OF CONTENTS CSVI 91190AL0200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 NOTICE TO BIDDERS For the Taking of Construction Bids For the Terminal Building Carpet - TERMINAL IMPROVEMENTS WATERLOO REGIONAL AIRPORT In the City of Waterloo, Iowa IDOT CSVI PROJECT NO. 91190AL0200 IDOT CONTRACT NO. 20601 RECEIVING OF BIDS Sealed proposals will be received by the City Clerk of the City of Waterloo, Iowa, at her office in the City Hall of the said City on the 27th of June, 2019, until 1:00 p.m. for the construction of the Terminal Building Carpet - TERMINAL IMPROVEMENTS, as described in detail in the plans and specifications now on file in the Office of the City Clerk. OPENING OF BIDS All proposals received will be opened in the First Floor Conference Room at City Hall, in the City of — Waterloo, Iowa, on the 27th day of June, 2019, at 1:00 p.m., and the proposals will be acted upon at such later time and place as may then be fixed by the City Council. PRE-BID MEETING A pre-bid meeting for this project will NOT be held, but contractors are urged to make a site visit and familiarize themselves with existing conditions. Bidders shall arrange an individual site visit prior to Bidding by contacting the Airport Director at (319)291-4483. PUBLIC HEARING The Council of said City will conduct a public hearing on the proposed plans, specifications, form of — contract, and estimate of cost for the construction of the above-described improvement project at 5:30 p.m. on July 1, 2019, said hearing to be held in the Harold E. Getty Council Chambers in City Hall in said City. SCOPE OF WORK The project is to replace carpet in the first floor area of the Terminal Building. BEGINNING AND COMPLETION DATES The work under the proposed contract shall be commenced within ten (10) working days after receipt of "Notice to Proceed" and all items shall be completed on or before November 1, 2019. METHOD OF PAYMENT TO CONTRACTOR The Contractor will be paid against bi-monthly estimates in cash on the basis of ninety-five percent (95%) of the work as it is completed and materials delivered and work approved. Final payment will be made thirty-one (31) days after completion of the work and acceptance by the Council. Before final payment is made, vouchers showing that all subcontractors and workmen and all persons furnishing materials have been fully paid for such materials and labor will be required unless the City is satisfied that material, men and laborers have been paid. The Contractor is hereby notified that if the City does not have cash on hand to pay monthly pay estimates, according to Chapter 384.57 of the Code of Iowa, payment may be made by anticipatory warrants issued bearing a rate of interest not exceeding that permitted by Chapter 74A, Code of Iowa. NOTICE TO BIDDERS CSVI 91109AL0200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 NTB-1 of 4 PLANS AND SPECIFICATIONS Plans and Specifications governing the construction of the proposed improvements have been prepared by AECOM, which plans and specifications, and also the prior proceedings of the City Council referring to — and defining said proposed improvements are hereby made a part of this notice, and the proposed contract by reference shall be executed in compliance therewith. Plans and Specifications are available from AECOM upon receipt of a$25.00 refundable deposit (CHECK ONLY). Deposits will be refunded if the plans are returned in usable condition (i.e. free of highlights, ink markings, tears, stickers, water stains and soiling) to the AECOM Office by the end of the 14th consecutive day after the project has been awarded. No deposits will be refunded for any plans received — after the 14th consecutive day, which includes plans returned via mail service. Plan holders are responsible for ascertaining when the project has been awarded. The deposit policy shall apply to the prime contractor awarded the project for all plans and specifications obtained and distributed by the prime contractor to their subcontractors and suppliers in determining the prime contractor's bid, if the prime contractor wishes for their deposit to be returned. Upon award of project, the prime contractor shall be supplied with the needed number of plans and specifications at no additional cost. CONTRACT AWARD A contract will be awarded to the qualified bidder submitting the lowest total bid. The City reserves the right to reject any or all bids, re-advertise for new bids, and to waive informalities in the bids submitted that might be in the best interest of the City. Bids may be held by the City of Waterloo, Iowa, for a period not to exceed thirty (30) days from the day of the opening of bids for the purpose of reviewing the bids and investigating the qualifications of bidders, prior to awarding the contract. By virtue of statutory authority, a preference will be given to products and provisions grown and coal produced with the State of Iowa and preference will be given to local domestic labor in the construction of the improvement. — PROPOSALS SUBMITTED The bidder shall submit bids on the items listed in the proposal. The bidder shall clearly write or type the unit bid price and the bid item extension (Unit Price x Estimated Qty) in numerals on the blanks provided. Should there be any discrepancy between the unit bid price and extension, the City of Waterloo shall consider the unit bid price as being the valid unit bid price. — The bidder has the option to submit a computer-generated spreadsheet in lieu of the portion of the Form of Bid or Proposal, which includes the Bid Item Number, Description, Unit, Estimated Quantity, Unit Bid Price, Total Bid Price and Total Bid. The computer-generated spreadsheet shall include all of the — information listed in that portion of the Form of Bid or Proposal as well as bear the signature of the Prime Contractor submitting the bid. For the bidders who submit a computer-generated spreadsheet, the TOTAL BID (with alternates, if applicable) shall also be indicated in the space(s) provided on the Form of Bid or Proposal. BID SECURITY REQUIRED All bids must be accompanied in a separate envelope by a certified or cashier's check drawn on an Iowa bank, or a bank chartered under the laws of the United States, a certified share draft drawn on a credit union in Iowa or chartered under the laws of the United States, or bid bond, (on the form furnished by the City) payable to the City of Waterloo, Iowa, in the sum of not less than five percent (5%) of the bid submitted, which certified check, certified share draft or bid bond will be held as security that the Bidder will enter into a Contract for the construction of the work and will furnish the required bonds, and in case the successful Bidder shall fail or refuse to enter into the Contract and furnish the required bonds, his bid — security may be retained by said City as agreed upon liquidated damages. If bid bond is used, it must be NOTICE TO BIDDERS CSVI 91109AL0200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 NTB-2 of 4 signed by both the Bidder and the surety or surety's agent. Signature of surety's agent must be supported by accompanying Power of Attorney. PERFORMANCE & PAYMENT BONDS — The successful bidder will be required to furnish a "Performance Bond" and a "Payment Bond" within ten (10) days after forms are presented to him in an amount equal to one hundred percent (100%) of the contract price, said bond to be issued by a responsible surety approved by the City Council and shall guarantee the faithful performance of the contract and the terms and conditions therein contained, and shall guarantee the prompt payment of all materials and labor and protect and save harmless the City from claims of any kind caused by the operations of the contractor. MAINTENANCE BOND Before the Contractor shall be entitled to receive final payment for work done under this contract, it shall execute and file a bond in the penal sum of not less than 100% of the total amount of the contract, same to be known as "Maintenance Bond," and which bond must be approved by the City Council, and which bond is in addition to the bond given by the Contractor to guarantee the completion of the work. CONTRACT COMPLIANCE PROGRAM /SUBCONTRACTING The program proposes numerical projections regarding utilization of Minority Business Enterprise (MBE) and Women Business Enterprise (WBE) as Subcontractors, vendors and suppliers in the performance of — Contracts awarded by the City of Waterloo, Iowa. A goal of at least ten percent (10%) for MBE participation on all City funded construction projects that are estimated at $50,000.00 or more. A goal of at least two percent (2%) for WBE participation on all City funded construction projects that are estimated at $50,000.00 or more. Any project funded in part or in total with federal funds shall follow the respective agencies contract compliance program and goals. The Prime Contractor shall make "good-faith efforts" to meet the Contract Compliance MBE/WBE goals. The -- MBE/WBE subcontractors, suppliers or vendors must provide the Prime Contractor a reasonably competitive price for the service being rendered or the Contractor is not required to accept their bid. PREDETERMINED WAGE RATE Predetermined wage rates do not apply to work on this project. — LIQUIDATED DAMAGES Time is an essential element of this contract. It is important that the work be diligently pursued to completion. If the work is not completed within the specified contract period, plus authorized extensions, the contractor shall pay to the City Liquidated Damages in the amount of five hundred dollars ($500.00) per day, for each day, as further described herein, in excess of the authorized time. — Days beyond the specified completion date for which Liquidated Damages will be charged will be working days that the contractor does, or could have worked, from Monday through Saturday. Sundays will be counted only if work is performed. Partial working days will be considered as a full working day. Days not chargeable for Liquidated Damages will include rain days, Sunday if no work is done, and legal holidays. Working days will cease to be charged when only punch list items remain to be completed. Punch list items do not include contract bid items or approved change/extra work orders. When the Contractor believes the project to be substantially completed, a written notice stating the same shall be submitted to the Engineer and a request made for a Punch List. If the work under the Contract extends beyond the normal construction season for such work the Contractor shall submit to the Engineer in writing a request that working days counted toward the project be suspended until work is resumed the following construction season. This amount is not construed as a penalty. These damages are for the cost to the City of providing the required additional inspection, engineering and contract administration. NOTICE TO BIDDERS CSVI 91109AL0200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 NTB-3 of 4 PRE-CONSTRUCTION CONFERENCE Before the work is commenced on this contract, a conference shall be held for the purpose of discussing the contract. The conference shall be attended by the prime contractor, subcontractors and City Officials. BIDDER STATUS Attention of bidders is called to compliance with the provisions of the Resident Bidder/Non-Resident Bidder requirements. Each bidder submitting a bid shall execute and include with the bid, a Bidder Status Form in the form herein provided. — Failure to submit a fully completed Bidder Status Form with the bid may result in the bid being deemed nonresponsive and rejected. SALES TAX EXEMPTION CERTIFICATES Contractors and approved subcontractors will be provided a Sales Tax Exemption Certification to purchase building materials or supplies in the performance of construction contracts let by the City of Waterloo. Published pursuant to the provisions of Chapter 26 of the City Code of Iowa and upon order to the City Council of said Waterloo, Iowa. CITY OF WATERLOO, IOWA NOTICE TO BIDDERS CSVI 91109AL0200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO. 20601 NTB-4 of 4 NOTICE OF PUBLIC HEARING On Proposed Plans, Specifications, Form of Contract, And Estimate of Cost and the For the Terminal Building Carpet- TERMINAL IMPROVEMENTS WATERLOO REGIONAL AIRPORT In the City of Waterloo, Iowa IDOT CSVI PROJECT NO. 91190AL0200 IDOT CONTRACT NO. 20601 -- RECEIVING OF BIDS Sealed proposals will be received by the City Clerk of the City of Waterloo, Iowa, at her office in the City Hall of the said City on the 27 of June, 2019, until 1:00 p.m. for the construction of the Terminal Building Carpet - TERMINAL IMPROVEMENTS, as described in detail in the plans and specifications now on file in the Office of the City Clerk. OPENING OF BIDS All proposals received will be opened in the First Floor Conference Room at City Hall, in the City of Waterloo, Iowa, on the 27th day of June, 2019, at 1:00 p.m., and the proposals will be acted upon at such later time and place as may then be fixed by the City Council. PUBLIC HEARING Notice is hereby given that the Council of said City will conduct a public hearing on the proposed plans, specifications, form of contract, and estimate of cost for the construction of the above-described improvement project at 5:30 p.m. on July 1, 2019, said hearing to be held in the Harold E. Getty Council Chambers in City Hall in said City. The proposed plans, specifications, form of contract. and estimate of cost for said improvements heretofore prepared by AECOM are now on file in the office of the City Clerk for public examination, and any person interested therein may file written objection thereto with the City Clerk before the date set for said hearing, or appear and make objection thereto with the City Clerk before the date set for said hearing, or appear and make objection thereto at the meeting above set forth. The NOTICE TO BIDDERS can be viewed at the following locations: 1) City of Waterloo web site at http://ci.waterloo.ia.us/ 2) Plan rooms: Master Builders of Iowa 221 Park Street, PO Box 695 Des Moines, IA 50303 — McGraw Hill Construction Dodge 3315 Central Ave. Hot Springs, AR 71913 Reed Construction Data 30 Technology Parkway South, Ste. 500 Norcross, GA 30092 3) Plan Room Web sites: Master Builders of Iowa web site at www.rnbionline.com Dodge Lead web site: http://dodgeprojects.construction.com! Reed Const. Data Lead web site: http://www.cmdgroup.com/project-leads/ NOTICE OF PUBLIC HEARING CSVI 91109ALO200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 NPH-1 of 2 SCOPE OF WORK The project is to replace carpet in the first floor area of the Terminal Building. Published pursuant to the provisions of Chapter 26 of the City Code of Iowa and upon order to the City Council of said Waterloo, Iowa, on the day of , 20_ CITY OF WATERLOO, IOWA By: Kelley Felchle City Clerk NOTICE OF PUBLIC HEARING CSVI 91109AL0200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 NPH-2 of 2 -- INSTRUCTIONS TO BIDDERS 1. EXPLANATIONS TO BIDDERS Any explanation desired by a bidder regarding the meaning or interpretation of the Notice to Bidders, Plans, Specifications, etc., must be requested in writing and with sufficient time allowed for a reply to reach bidders before submission of their bids. Any interpretation made will be in the form of an amendment of the Notice to Bidders, Plans, Specifications, etc., and will be furnished to all prospective bidders. Its receipt by the bidder must be acknowledged in the space provided on the Proposal Form or by letter or telegram received before the time set for opening of bids. Oral explanations or instructions given before the award of the contract will not be binding. 2. EXAMINATION OF PROPOSED WORK Bidders should visit the site and take such other steps as may be reasonably necessary to — ascertain the nature and location of the work, and the general and local conditions which can affect the work or the cost thereof. Failure to do so will not relieve bidders from responsibility for estimating properly the difficulty or cost of successfully performing the work. The owner will assume no responsibility for any understanding or representation concerning conditions made by any of its officers or agents prior to the execution of the contract, unless included in the Notice to Bidders, the Specifications or related documents. 3. PREPARATION OF BIDS a. Bids shall be submitted on the forms furnished, or copies thereof, and must be manually signed. If erasures or other changes appear on the forms, each erasure or change must be initialed by the person signing the bid. The bidder has the option to submit a computer-generated spreadsheet in lieu of the portion of the Form of Bid or Proposal, which includes the Bid Item Number, Description, Unit, Estimated Quantity, Unit Bid Price, Total Bid Price, and Total Bid. The computer- generated spreadsheet shall include all of the information listed in that portion of the Form of Bid or Proposal as well as bear the signature of the Prime Contractor submitting the bid. For the bidders who submit a computer-generated spread- sheet, the TOTAL BID (with alternates, if applicable) shall also be indicated in the space(s) provided on the Form of Bid or Proposal. b. The Bid Form may provide for submission of a price or prices for one or more items, which may be lump sum bids, alternate prices, schedule items resulting in a bid on a unit of construction or a combination thereof, etc. When the Bid Form explicitly requires that the bidder bid on all items, failure to do so will disqualify the bid. When submission of a price on all items is not required, bidders should insert the words "no bid" in the space provided for any item on which no price is submitted. c. Unless called for, alternate bids will not be considered. d. Modifications of bids already submitted will be considered if received at the office designated in the Notice to Bidders by the time set for closing of bids. Telegraphic modifications will be considered, but should not reveal the amount of the original or revised bid. e. In preparing his bid, the bidder shall specify the price, written legibly in ink or with the typewriter, at which he proposes to do each item of work. The unit price shall be stated in figures in the blank space provided (i.e., $7.14). In items where unit price is required, INSTRUCTIONS TO BIDDERS CSVI 91109AL0200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 IB-1 of 10 the total amount of each item shall be computed at the unit prices bid for the quantities _ given on the Bid Form and stated in figures in the blank space provided. If the bidder chooses to submit the unit prices, total bid price, and total bid on a computer-generated spreadsheet, all numbers shall be easily legible. -- f. Any changes or alterations made in the Bid Form, or any addition thereto, may cause the rejection of the bid. No bid will be considered which contains a clause in which the contractor reserves the right to accept or reject a contract awarded him by the city Council of Waterloo. Bids in which the unit prices are obviously unbalanced may be rejected. g. If the bidder does not qualify as a resident bidder, the nonresident bidder shall specify on the project proposal whether any preference to resident bidders, including but not limited to any preference to bidders, the imposition of any type of labor force preference, or any other form of preferential treatment to bidders or laborers from that state or foreign —' country is in effect in the nonresident bidder's state or country of domicile at the time of a bid submittal. 4. SUBMISSION OF BIDS a. A bid must be sealed in a separate envelope and marked to indicate its contents and be accompanied by the bid security in a separate envelope. If forwarded by mail, the two envelopes shall be placed in a third and mailed to the City Clerk/Auditor. All bids must be filed with the City Clerk/Auditor of the City of Waterloo at his office in the City Hall before the time specified for closing bids. — b. Bids received prior to the advertised hour of opening will be securely kept sealed. The officer whose duty it is to open them will decide when the specified time has arrived, and no bid received thereafter will be considered; except that when a bid arrives by mail after the time fixed for opening, but before the reading of all other bids is completed, and it is shown to the satisfaction of the City of Waterloo, Iowa, that the non-arrival on time was due solely to delay in the mails for which the bidder was not responsible, such bid will be — received and considered. c. Bidders are cautioned that, while telegraphic modifications of bids may be received as provided above, such modifications, if not explicit and if in any sense subject to misinterpretation, shall made the bid so modified or amended, subject to rejection. 5. LATE BIDS AND MODIFICATIONS OR WITHDRAWALS — Bids and modifications or withdrawals thereof received at the office designated in the Notice to Bidders after the exact time set for closing of bids will not be considered. However, a modification which is received from an otherwise successful bidder, and which makes the terms of the bid more favorable to the City of Waterloo, will be considered at any time it is received and may therefore be accepted. Bids may be withdrawn by written or telegraphic request received from bidders prior to the time set for closing of bids. 6. PUBLIC OPENING OF BIDS Bids will be publicly opened at that time and place set for opening in the Notice to Bidders. Their — content will be made public for the information of bidders and others interested who may be present either in person or by representative. INSTRUCTIONS TO BIDDERS CSVI 91109AL0200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 IB-2 of 10 7. BID SECURITY REQUIRED — All bids must be accompanied in a separate envelope by a certified or cashier's check drawn on an Iowa bank, or a bank chartered under the laws of the United States, a certified share draft drawn on a credit union in Iowa or chartered under the laws of the United States, or bid bond (on the form furnished by the City) payable to the City of Waterloo, Iowa, in the sum of not less than five percent (5%) of the bid submitted, which certified check, certified share draft or bid bond will be held as security that the Bidder will enter into a Contract for the construction of the work and will furnish the required bonds, and in case the successful Bidder shall fail or refuse to enter into the Contract and furnish the required bond, his bid security may be retained by said City as agreed upon liquidated damages. If bid bond is used, it must be signed by both the bidder and the surety or surety's agent. Signature of surety's agent must be supported by accompanying Power of Attorney. 8. COLLUSIVE AGREEMENTS a. Each bidder submitting a bid shall execute and include with the bid, a Non-Collusion Affidavit in the form herein provided, to the effect that he as not colluded with any other person, firm, or corporation in regard to any bid submitted. — b. Each bidder submitting a bid shall have each proposed subcontractor, if any, execute and submit to the City Contract Compliance Officer by 5:00 P.M. the business day following the day bids on this project are due, a Non-Collusion Affidavit in the form herein provided, — to the effect that he has not colluded with any other person, firm, or corporation in regard to any bid submitted. Before executing any subcontract, the successful bidder shall submit the name of any proposed subcontractor for approval by the City. — 9. MINORITY AND/OR WOMEN BUSINESS ENTERPRISE SUBCONTRACTORS a. CITY OF WATERLOO AND/OR WOMEN BUSINESS ENTERPRISE PRE-BID — CONTACT INFORMATION FORM The City of Waterloo Minority and/or Women Business Enterprise Pre-Bid Contact Information Form shall be submitted with the Form of Bid or Proposal. Failure to do so -- shall be grounds for the bid being rejected if subcontracting is proposed by the prime contractor. — 10. MBE/WBE CONTRACT COMPLIANCE PROGRAM PURPOSE The purpose of the Contract Compliance Program (hereinafter called Program) is to act as an impetus for increasing the participation of minority and women disadvantaged business enterprise (MBE/WBE) in City awarded construction contracts. The Program does not propose to eliminate any bonafide contractor or subcontractor from bidding on City contracts, but it will hopefully serve as a needed stimulus to help local MBE/WBE's grow and eventually become mainstream contractors and subcontractors. This Contract Compliance Program does not propose to include any set-aside or quotas, but only flexible goals where "good-faith efforts" are required by the contractor to use MBE/WBE subcontractors. INSTRUCTIONS TO BIDDERS CSVI 91109AL0200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 IB-3 of 10 This Program shall not eliminate the need for contractors to continue their "good-faith efforts" in using MBE/WBE subcontractors on City contracts estimated at less than $50,000. The City of Waterloo will make every effort to reduce in-house construction and — maintenance work that would be more cost effectively performed by the private sector and, thus, would allow additional bidding opportunities for MBE/WBE firms. The City Contract Compliance Officer shall be advised of all City of Waterloo awarded — construction contracts. DEFINITIONS Goals: A flexible numerically expressed objective which contractors are required to make "good- faith efforts." The key to the requirement is to make documented efforts. Goals are neither set-a-sides nor a device to achieve proportional representation or equal results. Numerical goals do not create set-a-sides for specific groups, nor are they designed to achieve proportional representation or equal results. Rather, the goal-setting process in _ affirmative action planning is used to target and measure the effectiveness of affirmative action efforts to eradicate and prevent discrimination. Quota: A flat numerical requirement that the contractor is required to meet in order to obtain the benefit or be in compliance. The numerical goal component of affirmative action programs is not designed to be, nor may it properly or lawfully be interpreted as, _ permitting unlawful preferential treatment and quotas with respect to persons of any race, color, religion, sex, or national origin. The regulations at 41 CFR 60-2.12(a), 60-2.15 and 60-2.30, specifically prohibit discrimination and the use of goals as quotas. (U.S. Department of Labor) Set-Aside: An arrangement in which a particular contract is reserved for competition solely among minority and women business enterprises. Contractor. As used in this document means contractor, subcontractor, supplier, vendor, and professional service provider. Minority Business Enterprise (MBE) — Any business, which is at least 51%, owned by one or more minorities and whose management and daily business operations are controlled by one or more such individuals and is on the current State Unified Certification List, or were listed on the City of Waterloo Certified MBE/WBE Contractors list as of July 1, 2002 — Women Business Enterprise (WBE): Any business which is at least 51% owned by one or more women and whose management and daily business operations are controlled by one or more such individuals and is on the current State Unified Certification List, or were listed on the City of Waterloo Certified MBE/WBE Contractors list as of July 1, 2002 Minority: Any person or persons who are considered as socially and economically disadvantaged because of their identity as a group member without regard to their individual qualities. _ The groups include: Black American, Hispanic American, Native Americans, Eskimos, Aleuts, and Asian-Pacific Americans. 13 C.F.R. 124-1.1(c)(3)(ii)(1983). INSTRUCTIONS TO BIDDERS CSVI 91109AL0200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 IB-4 of 10 Lowest Responsible Bidder: Bidder who has offered the lowest bid and who has exhibited skill relative to the type of work bid on, judgment, financial responsibility, and evidence of working with the Affirmative Action Employment Program and the Contract Compliance Program. Broker. One buying or selling for others on commission or other fee basis without maintaining a warehouse or other similar inventory storage facility. Mayor's Advisory Committee: Mayor's Advisory Committee for Minority, Female, and Disadvantaged Business Enterprise. Good Faith Efforts: The successful bidder shall be selected on the basis of having submitted the lowest responsible bid. The obligation of the bidder is to make good faith efforts. The bidder can demonstrate that it has done so by the following: 1. The Prime Contractor met the project goal - No Action necessary 2. If the Prime Contractor failed to meet the goal, they must submit documentation of good faith efforts. CONTRACT COMPLIANCE PROGRAM SUBCONTRACTING The program proposes numerical projections or goals regarding utilization of Minority Business Enterprise (MBE) and Women Business Enterprise (WBE) as subcontractors in the performance of contracts awarded by the City of Waterloo, Iowa. A goal of at least 10% for MBE participation on all City funded construction projects that are estimated at $50,000 or more and projects under $50,000 where applicable at the Contract Compliance Officer's discretion. There is at least 2% WBE goal on City funded projects. Any project which is funded solely or in part with Federal funds shall follow the respective agencies contract compliance program and goals. Any project which is funded solely or in part with State funds shall follow the respective agencies contract compliance program and goals. The City of Waterloo Contract Compliance Program is for City awarded construction contracts only. The prime contractor shall make "good-faith efforts" to meet the Contract Compliance MBE/WBE goals. The MBE/WBE subcontracts must provide the prime contractor a reasonably competitive price for the service being rendered or the contractor is not required to accept the bid. Administrative Reconsideration: As part of this reconsideration, the bidder will have the opportunity to provide written documentation or arguments concerning the issue of whether they made adequate good faith efforts to meet the goals. The bidder will have the opportunity to meet in person with the City of Waterloo's Administrative Reconsideration Committee to discuss the issue of -- whether they made adequate good faith efforts. The Administrative Reconsideration Committee will forward a written decision on reconsideration to the Mayor and City Council, explaining the basis for finding that the bidder did or did not meet the goal or make adequate good faith efforts to do so. Documentation required will include but is not limited to the following: * Making portions of the work available for MBE/WBE subcontracting INSTRUCTIONS TO BIDDERS CSVI 91109AL0200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 IB-5 of 10 * Evidence of negotiating with MBE/WBE firms — * MBE/WBE quotes obtained and non-MBE/WBE quotes used * Reasons agreements were not reached * Follow-up after initial solicitations * Efforts to assist in obtaining equipment, supplies and materials (at competitive — prices), bonding, lines of credit, insurance, etc. * Evidence of past compliance or non-compliance by same contractor The Contract Compliance Officer will determine the weight to be given to each item listed above (supported by appropriate documentation) based on overall program goals. RESPONSIBILITIES — 1. City of Waterloo A. The City Contract Compliance Officer has the responsibility to assure the City's — compliance with Federal, State and Municipal regulations. B. The City Contract Compliance Officer is responsible for maintaining a current directory of certified firms. Certification of MBE/WBE/DBE contractors is through — the Iowa Department of Transportation and its Unified Certification Program. Only firms certified based on guidelines prescribed in 49 CFR Part 26 and provisions of this agreement, shall be recognized as certified by the City of Waterloo. C. The City Contract Compliance Officer is responsible for making available a list of future project information notices to MBE/WBE firms. D. The City Contract Compliance Officer shall send notices to appropriate — MBE/WBE firms in the directory of each bid solicitation with opening date. E. The City Contract Compliance Officer will receive MBE/WBE Letter(s) of Intent to Bid and within two (2) business days forward the complete list of MBE/WBE bidders who submitted a Letter of Intent to Bid to prime contractors. — Prime Contractors In order to be in compliance with the guidelines of this program, the prime contractor must show good-faith efforts in following the MBE/WBE Contract Compliance Program. Good-faith efforts include, but are not limited to, the following: A. Prime contractors shall send solicitation letters (Form CCO-3) to appropriate MBE/WBE (those certified in directory prepared by City Contract Compliance Officer) at least seven (7) working days prior to bid date. Letters should identify specific items to be subcontracted. A minimum of three (3) disadvantaged business contacts must be made and documented, if there are at least three disadvantaged businesses offering services in the area to be subcontracted (See City of Waterloo MBE/WBE Certification List). If less than three (3) are offering the services to be subcontracted, then a contact is required for any that are listed as providing that service. If the Prime Contractor submits a MBE/WBE contact not on the City's MBE/WBE list, attach a copy of the MBE/WBE/DBE Certifications from another government agency. B. If a prime contract bidder is unable to identify MBE/WBE firms to perform portions of the work, the City Contract Compliance Officer should be contacted — for assistance immediately. C. Prime contract bidders may solicit MBE/WBE proposals by telephone or personal interviews, but all such contacts shall be confirmed by Certified Mail, or subcontract bid request forms (Form CCO-2). INSTRUCTIONS TO BIDDERS CSVI 91109AL0200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 IB-6 of 10 D. If any MBE/WBE business submitting bids is not selected for subcontract award, documentation must accompany the "MBE/WBE Business Enterprise Pre-Bid Contact Information Form" (Form CCO-4 and CCO-4A) on why the MBE/WBE was not selected. These reasons could include: '- a. Not low bid. Copies of the competing bids may be required for verification. b. MBE/WBE did not bid, withdrew bid or non-responsive. c. Documentation of other business-related reason for not selecting the MBE/WBE business for a subcontract. d. Prime contractor self performs work. e. Any other reason relied on by prime. The Contract Compliance Officer will determine the weight to be given to each item listed above (supported by appropriate documentation) based on overall program goals. ll. MBE/WBE Firms A. MBE/WBE firms shall be certified by the Iowa Department of Transportation as owners and controllers of their respective businesses, or were listed on the City of Waterloo Certified MBE/WBE Contractors list as of July 1, 2002. B. MBE/WBE firms must perform the work on the project; they cannot act as a broker by subcontracting the work out to others. C. Each MBE/WBE firm planning to submit quotes on construction projects with goals, shall submit a Letter of Intent to Bid (Form CCO-5) to the City Contract Compliance Officer seven (7) working days prior to bid opening, listing specific items which the MBE/WBE firm is interested in bidding. If sufficient Letters of Intent to Bid are not received by the City Contract Compliance Officer seven (7) working days prior to bid opening, goals on subject project will be reduced accordingly. Agreements between the bidder/proposer and a MBE/WBE in which the MBE/WBE promises not to provide subcontracting quotations to other bidders/proposers are prohibited. NON-COMPLIANCE OF CONTRACTORS A. Noncompliance exists when the contractor's actions are not consistent with the requirements of the Contract Compliance Program in the areas of employment and subcontracting. B. A bidder's failure to show good-faith efforts to meet project goals or a failure to use certified MBE/WBE firms may be grounds for finding its bid not responsible. C. The Contract Compliance Officer shall submit to City Council his/her recommendation on any non-compliant contract in writing. NOTICE TO PROCEED Notice to proceed on any project with goals will not be issued until City Contract Compliance Officer determines the lowest responsible bidder has used good-faith efforts to comply with this Compliance Program and the bid was responsive. CONCLUSION This program repeals or revises all sections of previous Waterloo Contract Compliance Programs. INSTRUCTIONS TO BIDDERS CSVI 91109AL0200 Terminal Bldg Carpet-Terminal Improvements -- AECOM 60600098 CONTRACT NO.20601 IB-7 of 10 11. EMPLOYMENT AND BUSINESS OPPORTUNITY To the greatest extent feasible, suppliers, subcontractors, and low income workers owning businesses or living in the Waterloo area must be given priority in supplying materials, bidding for subcontract work, or applying for employment by the contractor on this project. Opportunities for — training and for employment arising in connection with this project, shall to the greatest extent feasible be made available to lower income persons residing in the project area. The contract area is the City of Waterloo. — The City of Waterloo will require the contractor to document his efforts in securing lower income workers living in the project area and in purchasing supplies from, and awarding subcontracts to, businesses owned by persons residing in the project area. — 12. STATEMENT OF BIDDER'S QUALIFICATIONS Each bidder shall, upon request of the City of Waterloo, Iowa, submit on the form furnished for — that purpose (a copy of which is included in the contract documents), a statement of bidder's qualifications, his experience record in constructing the type of improvements embraced, and his organization and equipment available for the work contemplated; and, when specifically — requested, a detailed financial statement. The City of Waterloo, Iowa, shall have the right to take such steps as it deems necessary to determine the ability of the bidder to perform his obligations under the contract, and the bidder shall furnish the City of Waterloo, Iowa, all such information and data for this purpose as it may request. The right is reserved to reject any bid where an investigation of the available evidence or information does not satisfy the City of Waterloo, Iowa, that the bidder is qualified to carry out properly the terms of the contract. 13. AWARD OF CONTRACT a. Award of contract will be made to that responsive and responsible bidder whose bid, conforming to the Specifications, is most advantageous to the City of Waterloo; price and — other factors considered. The intention is to award the contract at the time of opening bids, but the right is reserved to postpone such action for a reasonable time, not exceeding thirty (30) days. — b. The City Council may, when in its interest, reject any or all bids or waive any informality in bids received. c. The bidder shall submit bids on all the items listed in the proposal and shall state the unit bid price in words in the blank spaces provided beneath the item description. Should there be any discrepancy between the unit bid price in words and listed numeral unit bid — price, the City of Waterloo shall consider the unit bid price in words as being the valid unit bid price. A computer-generated spreadsheet as herein provided shall also be acceptable. Proposals requiring mathematical computations to determine unit prices or totals will be rejected. A contract will be awarded to the qualified bidder submitting the — lowest total bid for the BASE BID plus ALTERNATE(S) chosen by the City as indicated in the NOTICE TO BIDDERS. d. When a contract for a public improvement is to be awarded to the lowest responsive and responsible bidder, a resident bidder shall be allowed a preference as against a nonresident bidder from a state or foreign country if that state or foreign country gives or requires any preference to bidders from that state or foreign country, including but not — limited to any preference to bidders, the imposition of any type of labor force preference, or any other form of preferential treatment to bidders or laborers from that state or foreign country. The preference allowed shall be equal to the preference given or required by — the state or foreign country in which the nonresident bidder is a resident. In the instance of a resident labor force preference, a nonresident bidder shall apply the same resident INSTRUCTIONS TO BIDDERS CSVI 91109AL0200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 IB-8 of 10 labor force preference to a public improvement in this state as would be required in the construction of a public improvement by the state or foreign country in which the nonresident bidder is a resident. 14. EXECUTION OF AGREEMENT, BONDS, AND CERTIFICATE OF INSURANCE a. Subsequent to the award and within ten (10) days after the prescribed forms are presented for signature, the successful bidder shall execute and deliver to the City of Waterloo, Iowa, an agreement in the form included in the contract documents in such number of copies as the City of Waterloo, Iowa, may require. b. Having satisfied all conditions of award as set forth elsewhere in these documents, the successful bidder shall, within the period specified in paragraph "a" above, furnish a surety bond and a payment bond in a penal sum not less than the amount of the contract as awarded, as security for the faithful performance of the contract and terms and conditions therein contained and shall guarantee the prompt payment of all persons, firms, or corporations to whom the contractor may become legally indebted for labor, materials, tools, equipment, or services of any nature including utility and transportation services, employed or used by him in performing the work. The bonds shall protect and save harmless the City from claims and damages of any kind caused by the operations of the contractor and shall also guarantee the maintenance of the contract improvements for the period stated in the Notice of Hearing from and after completion of said improvements and their acceptance by the City. Such bonds shall be in the same form as that included in the contract documents and shall bear the same date as, or a date subsequent to that of the agreement. The current Power of Attorney for the person who signs for any surety company shall be attached to such bonds. c. The successful bidder shall, within the period specified in paragraph "a" above, furnish a certificate of insurance for approval in amounts of not less than the amounts specified in the General Specifications for Construction, Section F. No. 4 "Liability Insurance," Pages 14 to 15 of 18 Pages. The certificate of insurance shall be furnished in such number of copies as the City of Waterloo may require. The City of Waterloo shall be named as an "Additional Insured." The contractor shall similarly submit his subcontractor's certificates of insurance in the amounts for approval before each commences work. The contractor shall carry or require that there be Workmen's Compensation Insurance for all his employees and those of his subcontractors engaged in work at the site, in accordance with State Workmen's Compensation Laws. d. The failure of the successful bidder to execute such agreement and to supply the required bond or bonds within ten (10) days after the prescribed forms are presented for — signature, or within such extended period as the City of Waterloo, Iowa, may grant, based upon reasons determined sufficient by the City of Waterloo, Iowa, may either award the contract to the next lowest bidder or re-advertise for bids, and may charge against the _ bidder the difference between the amount of the bid an the amount for which a contract for the work is subsequently executed, irrespective of whether the amount thus due exceeds the amount of the bid guaranty. If a more favorable bid is received by re- advertising, the defaulting bidder shall have no claim against the City of Waterloo, Iowa, fora refund. 15. RECIPROCAL RESIDENT BIDDER PREFERENCE Attention of bidders is called to the requirement of complying with the provisions of the Resident Bidder/Non-Resident Bidder requirement. INSTRUCTIONS TO BIDDERS CSVI 91109AL0200 Terminal Bldg Carpet-Terminal Improvements -_ AECOM 60600098 CONTRACT NO.20601 IB-9 of 10 Each bidder submitting a bid shall execute and include with the bid, a Bidder Status Form in the form herein provided. Failure to submit a fully completed Bidder Status Form with the bid may result in the bid being deemed nonresponsive and rejected. — INSTRUCTIONS TO BIDDERS CSVI 91109ALO200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 IB-10 of 10 FORM OF BID OR PROPOSAL _ Terminal Building Carpet- TERMINAL IMPROVEMENTS WATERLOO REGIONAL AIRPORT In the City of Waterloo, Iowa Honorable Mayor and City Council Waterloo, Iowa Gentlemen: 1. The undersigned, being a Corporation existing under the laws of the State of , a Partnership consisting of the following partners: having familiarized (himself) (themselves) (itself) with the existing conditions on the project area affecting the cost of the work, and with all the contract documents listed in the Table of Contents and Addenda (if any), as prepared by AECOM now on file in the office of the City Clerk, City Hall, `— Waterloo, Iowa, hereby proposes to furnish all supervision, technical personnel, labor, materials, machinery, tools, appurtenances, equipment, and services, including utility and transportation services required to construct and complete this Terminal Building Carpet - TERMINAL IMPROVEMENTS, all in accordance with the above-listed documents and for the unit prices for work in place for the following items and quantities: Terminal Building Carpet- TERMINAL IMPROVEMENTS CSVI PROJECT NO.91190AL0200 IDOT CONTRACT NO.20601 Ref. Estimated Unit Bid Item Item Unit Quantity Price Total Bid Price Terminal Building Carpet-Includes Floor Molding 1 Main Terminal Floor SFT 9,997 $ $ 2 Ticket Counter-Front SFT 1,068 $ $ 3 Ticket Counter-Behind SFT 513 $ $ 4 FAA Office SFT 425 $ $ 5 Office Area 1 SFT 1,190 $ $ TOTAL BASE BID $ BID ALTERNATE NO. 1 1 Business Center SFT 363 $ $ 2 Office Area 2 SFT 423 $ $ TOTAL BASE BID+ADD ALTERNATE NO. 1 $ 2. It is the City's intention to evaluate bids reviewing both the Base Bid and Add Alternate Bids. The City has limited funds available and will award only what funding allows. The City reserves the right to award the contract based on the Base Bid only or the Base Bid plus any and all Add Alternate Bid Options. 3. It is understood that the quantities set forth are approximate only and subject to variation and that the unit bid price for the work done shall govern in the actual payment to Contractor. 4. In submitting this bid, the bidder understands that the right is reserved by the City of Waterloo, Iowa, to reject any or all bids. If written notice of the acceptance of this bid is mailed, telegraphed, FORM OF BID CSVI 91109AL0200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 BF-1 of 2 or delivered to the undersigned within thirty (30) days after the opening thereof, or at any time thereafter before this bid is withdrawn, the undersigned agrees to execute and deliver an "— agreement in the prescribed form and furnish the required bond and certificate of the insurance within ten (10) days after the agreement is presented to him for signature, and start work within ten (10)days after"Notice to Proceed"is issued. — 5. Security in the sum of Dollars ($ ) in the form of , is submitted herewith in accordance with the INSTRUCTIONS TO BIDDERS. 6. Attached hereto is a Non-Collusion Affidavit of Prime Contractor. 7. Attached hereto is a Bidder Status Form indicating Resident Bidder Certification ( ), or Non-Resident Bidder Certification ( ). (Mark one.) — 8. The bidder is prepared to submit a financial and experience statement upon request. 9. The Prime Contractor and Subcontractor(s), which have performed an aggregate of$10,000.00 in work for the City in the current calendar year, are prepared to submit an AAP or Update and an EOC,within ten (10)days of notification that the bid submitted is lowest and acceptable. 10. The bidder has received the following Addendum or Addenda: — Addendum No. Date 11. The bidder shall list the MBE/WBE subcontractor(s), amount of subcontracts and bid items on the City of Waterloo Minority and/or Women Business Pre-bid Contact Information Form submitted with this Form of Bid or Proposal. The apparent low Bidder shall submit a list of all other Subcontractor(s) to be used on this Project to the City of Waterloo by 5:00 p.m. the business day following the day Bids on this Project are due along with the Non-Collusion Affidavits of All Subcontractor(s). The Contractor shall submit information on subcontractors on "SUBCONTRACTOR REQUEST — AND APPROVAL" Form to be provided by City prior to approval of contract. The subcontractors listed on this proposal and/or submitted to the Contract Compliance Officer cannot be changed except for the following reasons: 1) The City of Waterloo does not approve the subcontractors. 2) The subcontractors submit in writing that they cannot fulfill their subcontracts. — 12. The bidder has filled in all blanks on this proposal. Those blanks not applicable are marked"none" or"NA". 13. The bidder has attached all applicable forms. 14. The Owner reserves the right to select alternates, delete line items, and/or to reduce quantities prior to the award of a contract due to budgetary limitations. (Name of Bidder) (Date) BY: Title Official Address: (Including Zip Code): I.R.S. No. FORM OF BID CSVI 91109AL0200 Terminal Bldg Carpet-Terminal Improvements — AECOM 60600098 CONTRACT NO.20601 BF-2 of 2 INFORMATION NEEDED FOR IOWA CONSTRUCTION SALES TAX EXEMPTION CERTIFICATE CONTRACTOR NAME: ADDRESS: (Check One PRIME SUBCONTRACTOR FEDERAL ID#: PROJECT NAME: PROJECT CONTRACT NO.: DESCRIPTION OF WORK: ❑ Brickwork ❑ Landscaping ❑ Carpentry ❑ Painting ❑ Concrete ❑ Paving ❑ Drywall-Plaster-Insulation ❑ Plumbing ❑ Electrical ❑ Roofing-Siding-Sheet Metal ❑ Excavation/Grading ❑ Windows _ ❑ Flooring ❑ Wrecking-Demolition ❑ Heavy Construction ❑ Other (Please specify) ❑ Heating-Ventilating-Air Cond. SALES TAX EXEMPTION CSVI 91109AL0200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 STE-1 of 1 THIS PAGE LEFT BLANK INTENTIONALLY BID BOND KNOW ALL MEN BY THESE PRESENTS, that we, as Principal, and as Surety are held and firmly bound unto the Iowa, hereinafter called "OWNER." In the penal sum Dollars ($ ) lawful money of the United States, for the payment of which sum will and truly be made, we bind ourselves, our heirs, executors, administrators, and successors, jointly and severally, firmly by these presents. The condition of this obligation is such that whereas the Principal has submitted the accompanying bid dated the day of , 2016, for NOW, THEREFORE, (a) If said Bid shall be rejected, or in the alternate, (b) If said Bid shall be accepted and the Principal shall execute and deliver a contract in the form specified and shall furnish a bond for his faithful performance of said contract, and for the payment of all persons performing labor or furnishing materials in connection therewith, and shall in all other respects perform the agreement created by the acceptance of said Bid, Then this obligation shall be void, otherwise the same shall remain in force and effect; it being expressly understood and agreed that the liability of the Surety for any and all claims hereunder shall, in no event, exceed the penal amount of this obligation as herein stated. By virtue of statutory authority, the full amount of this bid bond shall be forfeited to the Owner in liquidation of damages sustained in the event that the Principal fails to execute the contract and provide the bond as provided in the specifications or by law. The Surety, for value received, hereby stipulates and agrees that the obligations of said Surety and its bond shall be in no way impaired or affected by any extension of the time within which the Owner may accept such Bid or execute such contract; and said Surety does hereby waive notice of any such extension. IN WITNESS WHEREOF, the Principal and the Surety, have hereunto set their hands and seals, and such of them as are corporations, have caused their corporate seals to be hereto affixed and these pres- - ents to be signed by their proper officers this day of , A.D. 2016. (Seal) Principal By (Title) (Seal) Witness Surety By Witness Attorney-in-fact BID BOND CSVI 91109AL0200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 BB-1 of 1 THIS PAGE LEFT BLANK INTENTIONALLY NON-COLLUSION AFFIDAVIT OF PRIME BIDDER State of )ss County of , being first duly sworn, deposes and says that: 1. He is (Owner, Partner, Officer, Representative, or Agent) , of , the Bidder that has submitted the attached Bid; 2. He is fully informed respecting the preparation and contents of the attached Bid and of all pertinent circumstances respecting such Bid; 3. Such Bid is genuine and is not a collusive or sham Bid; 4. Neither the said Bidder nor any of its officers, partners, owners, agents, representatives, employees, or parties in interest, including this affiant, has in any way colluded, conspired, connived or agreed, directly or indirectly, with any other Bidder, firm or person to submit a collusive or sham Bid in connection with the Contract for which the attached Bid has been submitted or to refrain from bidding in connection with such Contract, or has in any manner, directly or indirectly, sought by agreement or collusion or communication or conference with any other Bidder, firm or person to fix the price or prices in the attached Bid or of any other Bidder, or, to fix any overhead, profit or cost element of the bid price or the bid price of any other Bidder, or to secure through any collusion, conspiracy, connivance, or unlawful agreement any advantage against the City of Waterloo, Iowa, or any person interested in the Proposed Contract; and 5. The price or prices quoted in the attached Bid are fair and proper and are not tainted by any collusion, conspiracy, connivance or unlawful agreement on the part of the Bidder or any of its agents, representatives, owners, employees, or parties in interest, including this affiant. (Signed) Title Subscribed and sworn to before me this day of , 20_. Title My commission expires NON-COLLUSION AFFIDAVITS CSVI 91109AL0200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 NCA-1 of 2 NON-COLLUSION AFFIDAVIT OF SUBCONTRACTOR State of ) ss: County of , being first duly sworn, deposes and says that: 1. He is (Owner, Partner, Officer, Representative, or Agent) , of hereinafter referred to as the _ "Subcontractor;" 2. He is fully informed respecting the preparation and contents of the subcontractor's proposal submitted by the subcontractor to — contract pertaining to the project in • (City or County and State) _ 3. Such subcontractor's proposal is genuine and is not a collusive or sham proposal; 4. Neither the subcontractor nor any of its officers, partners, owners, agents, representatives, employees, or parties in interest, including this affiant, has in any way colluded, conspired, connived, or agreed, directly or indirectly, with any other bidder, firm or person to submit a collusive or sham proposal in connection with such contract or to refrain from submitting a _ proposal in connection with such contract, or has in any manner, directly or indirectly, sought by unlawful agreement or connivance with any other bidder, firm or person to fix the price or prices in said subcontractor's proposal, or to fix any overhead, profit or cost element of the price of prices in said subcontractor's proposal, or to secure through collusion, conspiracy, connivance or -- unlawful agreement any advantage against the City of Waterloo, Iowa, or any person interested in the proposed contract; and 5. The price or prices quoted in the subcontractor's proposal are fair and proper and are not tainted by any collusion, conspiracy, connivance or unlawful agreement on the part of the bidder or any of its agents, representatives, owners, employees, or parties in interest, including this affiant. (Signed) Title Subscribed and sworn to before me this day of , 20_. Title My commission expires NON-COLLUSION AFFIDAVITS CSVI 91109AL0200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 NCA-2 of 2 ...... ..... TARGETED SMALL BUSINESS (TSB) PRE-BID CONTACT INFORMATION 0 . a) .6 CC ' ,.._ 8 o >, ...-:-.-. -ca c a) _c .- fp ILI In E t1.3 ,cn 0 C..) 1 1 0 (11:;) 0 (13 0 re ,, cr ci_ z — tn ...1.) (I) 0 , o co ba I—: 0 *r . cc E a -,- < D o 3 0 o (a 0 a) 4 63' <w a_ .c a) w _ f'a 0 0 _c Ta LU 0 1 CD/-0 (2 ScC-4 CD 0), 1:3 D F '''' eT3 Z i E -' o 0, I (a . ..... IP_ a) a 0 •;;;-- ' 0 a) i-0 c-0 0 a) 22 0 a) M LU ›- ..c 0 I 0 I- a) I 1. !II i F P_ >- CI U.1 0- 0) CI) 1 - '6 ----;,; 0 0 r: 0 LU 0 E.' cj. a> ›!!, CL < > ,,17c'ifC_ .0" -0,, - t! (n I-- El Eci o u) ct Z ea i (i) U-1 0 °Li j i 1 0; , [ f I a I-- 0• -----z -E ti t5 SI' a., ,, CC c cn - ,.., 5 ca-'-='3 ul LE- u) -(75 — u),,...- .) 0 o o E -_-Cl) u,= L 0 6- , 00 0 c 5 a) - 0 Lu ei >-- z --0 _o__..1 .i z 0- -{;fi _C = .,-, - z Z a) i i ' _i_ a) - -0 w-cii <I__ ti o .a a) @ z a)- 8 a) 0 it) o -.° ._ 0 cr-' I- 1 --a E T- -_, 0 ; — 0 zi-- Cb a, E ° .0'0 __I LU1- < ,C < CO al - :0 -EC -4 0 1 :•E--0 ..,.- 5 1-Z WO 0 0 8 -s) .L Cn <0 !: (.13-.>!:. ,... 0 0 In c_ 2,_ 4, >" 0 0 o 0 , tx — o ct, >, u_ [ ; < co -0 0 0 o .., — 1-- IL a) ,..„.. 0:,-;;„,, cz : .-;„, (I) -0 CZ a) 01 Eo cc -0_- 2 E 0 E . 0 0 u) • . o. a. E -- -. co-0 0 0 to 1.,,_ I . (I)-0 a--- 0 cr5 ... w < .-a- 0 cr c a) o 0 S...) 00 fla) t3) CD g CO-j H ' 1 . _. 1 a c a) < o o a) -0 _ u) ,-, 0) L-- v) -0 -0_„, H! , 0 0 CO 0 ...... 0 C'' co E --° ° • I « co t- 0 a _ , '- CC0- If )- ,..o T, .0 ° • . ; o 6 fa E .0 o ° I: -o a) .a. q:_-° CD ;..3 0 1 I 0-0 ‹.1) 'L--- 1:3 ,-,., = to . : 0, = a> 0 > cr 0 as — 0 > -6 iz.., .....,_-, 0, 053-0 2,-3 _;;;;,.,-_-, JD i i CY 0 ,._ ci3 /.5 ..., _--L-4 .0 izi ° I- us `.° § i- ID Cl) 0 0 1 0 (1.) 1 ci) 1-5 0 2.C3- 0 0 -!-. 17 0 1 ! 42) .7) So a ar < a) 02 -:::-.- 0 1-,9' - Ta.' 0 co - 1- a ...' '-'• u'a'''''' E "E' E---E z - o o 0 0 o a>:5 2 a, .E-- 0 -...--).- a) .0-,-- 0 0 0 0 ,, - a) to o E "*L" (:)... Ta -c I i 1--- 0 !..t.,- ,..! CO -F.,,, ,,..,. 2 -° c3? sp•-._. 0 0 '!” CS) . ,- 0 .- ...C.`,-,' 0.0 r-- _ 0-;-;''' 4--' ; ,„,,,,, ....., C a) a. i 0 - -. -0 oE 6-....-..-.e- 0 o 0 i-- - >,E E ,,,,a >, ,,•- ,... ,.... a) ,-- a -E" ° .-> C:D I ! ',;- -0 CD ta" 4.2 .0 a) 45 w K.3 cr) 17.5 ,.. ir- > -c 0. di - .‘...12 o E 1--- 0 0 -5- ._ — a) iii E -0P- 1..... "r"-- c)_- o -.E. 5 I .- .. 6- a .._ _ -a o if> u... 0 a_ 0 0 a 0 c o - to - ..,-, 2125 .-... TSB PRE-BID CONTACT INFORMATION CSVI 91109AL0200 Terminal Bldg Carpet-Terminal Improvements — AECOM 60600098 CONTRACT NO.20601 TSB-1 of 1 EQUAL OPPORTUNITY CLAUSE (As provided in Executive Order No. 11246) — All contractors, subcontractors, vendors and suppliers of goods and services doing business with the City and value of said business equals or exceeds ten thousand dollars ($10,000.00) annually agree as follows: 1. The contractors, subcontractor, vendor and supplier of goods and services will not discriminate against any employee or applicant for employment because of race, color, creed, sex, national origin, economic status, age, mental or physical handicap, political opinions or affiliations. The -- contractor, subcontractor, vendor and supplier will develop an Affirmative Action program to ensure that applicants are employed and that employees are treated during employment without regard to their race, creed, color, sex, national origin, religion, economic status, age, mental or physical disability, political opinions or affiliations. Such actions shall include but not be limited to the following: a. Employment b. Upgrading c. Demotion or Transfer d. Recruitment and Advertising e. Layoff or Termination f. Rates of Pay or Other Forms of Compensation g. Selection for Training Including Apprenticeship 2. The contractor, subcontractor, vendor and supplier of goods and services will, in all solicitations or advertisements for employees, state that all qualified applicants will receive consideration for employment without regard to race, creed, color, sex, national origin, religion, economic status, age, mental or physical disabilities, political opinion or affiliations. 3. The contractor, subcontractor, vendor and supplier or his/her collective bargaining representative will send to each labor union or representative of workers which he/she has a collective bargaining agreement or other contract or understanding, a notice advising said labor union or workers' representative of the contractor's commitment under this section. 4. The contractor, subcontractor, vendor and supplier of goods and services will comply with all published rules, regulations, directives, and order of the City of Waterloo Affirmative Action Program Contract Compliance Provisions. -- 5. The contractor, subcontractor, vendor and supplier of goods and services will furnish and file compliance reports within such time and upon such forms as provided by the Affirmative Action Officer. Said forms will elicit information as to the policies, procedures, patterns, and practices of each subcontractor as well as the contractor himself/herself and said contractor, subcontractor, vendor and supplier will permit access to his/her employment books, records and accounts to the City's Affirmative Action Officer, for the purpose of investigation to ascertain compliance with this contract and with rules and regulations of the City's Affirmative Action Program—Contract Compliance Provisions relative to Resolution No. 24664. 6. In the event of the contractor's non-compliance with the non-discrimination clauses of this contract or with any of such rules, regulations and orders, this contract may be canceled, terminated or suspended in whole or in part and the contractor may be declared ineligible for further contracts in accordance with procedures authorized by the City Council. EQUAL OPPORTUNITY CLAUSE CSVI 91109ALO200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 EOC-1 of 2 7. The contractor, subcontractor, vendor and supplier of goods and services will include, or — incorporate by reference, the provisions of the non-discrimination clause in every contract, subcontract or purchase order unless exempted by the rules, regulations or orders of the City's Affirmative Action Program, and will provide in every subcontract, or purchase order that said provisions will be binding upon each contractor, subcontractor, or supplier. — 8. We, the undersigned, recognize that we are morally and legally committed to non-discrimination in employment. Any person who applies for employment with our company will not be discriminated against because of race, creed, color, sex, national origin, economic status, age, mental or physical disabilities. (Signed) (Appropriate Official) (Title) (Date) EQUAL OPPORTUNITY CLAUSE CSVI 91109ALO200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 EOC-2 of 2 TITLE VI CIVIL RIGHTS During the performance of this contract, the contractor (for itself), its assignees, and successors in interest(hereinafter referred to as the"contractor") agrees as follows: -- 1. Compliance with Regulations: The contractor shall comply with the Regulations relative to non- discrimination in Federally assisted programs of the DOT Title 49, Code of Federal Regulations, Part 21, as they may be amended from time to time, (hereinafter referred to as the Regulations), which are herein incorporated by reference and made a part of this contract. 2. Nondiscrimination: The contractor, with regard to the work performed by it during the contract, shall not discriminate on the grounds of race, color, national origin, sex, age, or disability in the selection and retention of subcontractors, including procurement of materials and leases of equipment. The contractor shall not participate either directly or indirectly in the discrimination prohibited by section 21.5 of the Regulations, including employment practices when the contract covers a program set forth in Appendix B of the Regulations. 3. Solicitations for Subcontracts, Including Procurement of Materials and Equipment: In all solicitations either by competitive bidding or negotiation made by the contractor for work to be performed under a subcontract, including procurement of materials or leases of equipment, each potential subcontractor or supplier shall be notified by the contractor of the contractor's obligations under this contract and the Regulations relative to non-discrimination on the grounds of race, color, national origin, sex, age, or disability. 4. Information and Reports: The contractor shall provide all information and reports required by the Regulations or directives issued pursuant there to, and shall allow access to its books, records, -- accounts, other sources of information, and its facilities as may be determined by the Contracting Authority, the Iowa DOT, or FHWA to be pertinent to ascertain compliance with such Regulations, orders and instructions. Where any information required of a contractor is in the exclusive possession of another who fails or refuses to furnish this information the contractor shall so certify to the Contracting Authority, the Iowa DOT, or the FHWA as appropriate, and shall set forth what efforts it has made to obtain the information. 5. Sanctions for Noncompliance: In the event of the contractor's noncompliance with the nondiscrimination provisions of this contract, the Contracting Authority, the Iowa DOT, or the FHWA shall impose such contract sanctions as they may determine to be appropriate, including, but not limited to: a. Withholding of payments to the contractor under the contract until the contractor complies, and/or b. Cancellation, termination, or suspension of the contract, in whole or in part. 6. Incorporation of Provisions: The contractor shall include the provisions of paragraphs (1) through (6) in every subcontract, including procurement of materials and leases of equipment, unless exempt by the Regulations, or directives issued pursuant thereto. The contractor shall take such action with respect to any subcontract or procurement as the Contracting Authority, the Iowa DOT, or the FHWA may direct as a means of enforcing such provisions including sanctions for non-compliance: Provided, however, that, in the event of a contractor becomes involved in, or it threatened with, litigation with a subcontractor or supplier as a result of such direction, the contractor may request the Contracting Authority or the Iowa DOT to enter into such litigation to _ protect the interests of the Contracting Authority or the Iowa DOT; and, in addition, the contractor may request the United States to enter into such litigation to protect the interest of the United States. TITLE VI CIVIL RIGHTS CSVI 91109AL0200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 TVI-1' _ Bidder Status Form _ To be completed by all bidders Part A P|eooaanower~Yaa or~No^for each of the following: -- F] Yoe E] No My company is authorized to transact business in Iowa. (To help you determine if your company is authorized, please review the worksheet on the next page). E] Yes F� No My company has an office to transact business in Iowa. -- El Yea Fl No My company's office in Iowa is suitable for more than receiving mai|, telephone calls, and e-mail. Fl yam No My company has been conducting business in Iowa for at least 3 years prior tothe first request for bids onthis project. -- �lyea �� No yNy company iu not o subsidiary of another business entity ormy company iyo subsidiary ofanother ��� business entity that would qualify as s resident bidder in Iowa. If you answered 'Yes"for each question above, your company qualifies as a resident bidder. Please -- complete Parts B and O of this form. If you answered ^No~toone or more questions above, your company is a nonresident bidder. Please complete Parts C and O of this form. ~~ n�� � To be completed by resident bidders Part ~~ My company has maintained offices in Iowa during the past 3 years at the following addresses: _ Dohao: / / to / / Address: City, State, Zip: Dates: / / to / / Address: City, 8tobs. Zip: _ Dates: / / to / / Address: You may attach additional ohoet(s) if needed. City, State, Zip: .._. Part To be completed by non-resident bidders . �8.. .~�� ~~ 1. Name of home state or foreign country reported to the Iowa Secretary of State: 2. Does your company's home state or foreign country offer preferences to resident bidders, resident labor �l ymu �l No _~ force preferences nr any other b/pacf preference bo bidders orlaborers? �� �� 1 If you answered "Yes"to question 2, identify each preference offered by your company's home state or foreign country and the appropriate legal citation. —~ You may attach additional oheeh)difneeded. ^~ ` To be completed by all bidders Part | certify that the odobamento mode on this document are true and complete to the best of my knowledge and | know that my failure to provide accurate and truthful information may be a reason to reject my bid. ~~ Firm Name: Signature: � Oebn: You must submit the completed form ta the governmental body requesting bids per 875 Iowa Administrative Code Chapter i5G.This form has been approved bythe Iowa Labor Commissioner. 309-6001 (0e'15) l ~- orksheet: Authorization to Transact Business This worksheet may be used to help complete Part A of the Resident Bidder Status form. If at least one of the following describes your business, you are authorized tu transact business inIowa. ~- �lYes [] No My business is currently registered as a contractor with the Iowa Division of Labor. �l Yea E] No My business is a sole proprietorship and | am an |mmo resident for Iowa income tax purposes. ElYem No My business is a general partnership or joint venture. More than 50 percent of the general partners or joint venture parties are residents of Iowa for Iowa income tax purposes. F7 Yea No My business is an active corporation with the |nxva Secretary of State and has paid all fees required by the Secretary of State, has filed its most recent biennial repod, and has not filed articles of dissolution. El Yes nNo My business is a corporation whose articles of incorporation are filed in a state other than Iowa, ~- the corporation has received a certificate of authority from the |mma oaonatory of state, has filed its most recent biennial report with the secretary ofstate, and has neither received m certificate of withdrawal from the secretary of state nor had its authority revoked.Yes No No My business is a limited liability partnership which has filed a statement of qualification in this state and the statement has not been canceled. _ �l Yes No My business is a limited liability partnership which has filed a statement of qualification in e state other than Iowa, has filed a statement of foreign qualification in Iowa and a statement of cancellation has not been filed. -- �l Yea No My business is a|imited partnership or limited liability limited partnership which has filed a certificate of limited partnership in this state, and has not filed a statement of termination, -- �7 Yes No My business is o limited partnership or limited liability limited partnership whose certificate of limited partnership is filed in a state other than Iowa, the limited partnership or limited liability ^_ limited partnership has received notification from the Iowa secretary of state that the application for certificate of authority has been approved and no notice of cancellation has been filed by the limited partnership or the limited liability limited partnership. �lYes ElNo My business is a limited liability company whose certificate of organization is filed in Iowa and has not filed a statement cf termination, _ F1 Yes nNo My business is a limited liability company whose certificate of organization is filed in a state other than Iowa, has received a certificate of authority to transact business in Iowa and the certificate has not been revoked orcanceled. _ _ _ _ 309a001m9-19 2 _ Revised February 2003 — CONTRACTOR'S OR SUBCONTRACTOR'S AFFIRMATIVE ACTION PROGRAM Check box that applies to party completing program: -- ( ) General Contractor ( ) Subcontractor — I. Section A to be completed by GENERAL CONTRACTORS only: A. — Name of Company Address of Company Zip Telephone Number( Federal ID Number(if no Federal ID Number, Owner/President's Social Security Number) Name of Equal Employment Officer Name of Project Project Contract Number Estimated Construction Work Dates / — Section B to be completed by SUBCONTRACTORS only: B. Name of General or Prime Contractor Name of Subcontractor Subcontractor's Address Zip Subcontractor's Telephone Number( Subcontractor's Federal ID Number(if no Federal ID Number Owner/President's Social Security Number) Name of Equal Employment Officer - 1 - C. Remainder of program to be completed by party completing program, either Prime or Subcontractor. —' 1. The Owners and/or Principals of your company: Ethnic Name Address Position Sex Origin 2. Other Areas of Interest: If your company has branches or subsidiaries, or if your company is a branch or subsidiary of a parent organization, give the following information: Type of Name Address Affiliation Degree II. EMPLOYER'S POLICY (Please read carefully.) A. We, the undersigned, recognize that we are morally and legally committed to nondiscrimination in employment. Any person who applies for employment with our — company will not be discriminated against because of race, color, creed, sex, national origin, economic status, age, mental or physical handicap. B. The employment policies and practices of the undersigned are to recruit and hire employees without discrimination, and to treat them equally with respect to compensation and opportunities for advancement, including training, upgrading, promotion, and transfer. However, we realize the inequities associated with employment training, upgrading, — contracting and subcontracting for minorities and women and we will direct our efforts to correcting any deficiencies to the maximum extent possible. The same will be required of our SUBCONTRACTORS and suppliers. C. We submit this program to assure compliance with Executive Order 11246, as amended, and other subsequent orders that may pertain to equal employment opportunity and merit employment policies, fully realizing that our qualification and/or merit system should be — evaluated and revised, if necessary. D. We agree to put forth the maximum effort to achieve full employment and utilization of capabilities and productivity of all our citizens without regard to race, creed, color, sex, — national origin, economic status, age, and mental or physical handicap. E. will give training (Name of Company) and employment opportunities to local residents of Waterloo, Iowa, to the greatest extent feasible. - -2- III. AFFIRMATIVE ACTION A. recognizes that the (Name of Company) effective application of a policy of merit employment involves more than just a policy statement, and (Name of Company) will, therefore, re-evaluate our Affirmative Action Program to ensure that equal employment opportunities are available on the basis of individual merit, and to actively encourage minorities, women and local residents to seek employment with our company _ on this basis. B. will undertake the (Name of Company) following six(6) steps to improve our Affirmative Action Program: 1. Minority Recruitment and Employment; 2. Local Recruitment and Employment; 3. Disabled Veteran and Vietnam Era Veteran Recruitment and Employment; 4. Handicapped Recruitment and Employment; 5. Female Recruitment and Employment; and 6. Training, Upgrading and Promotional Opportunities. C. will take (Name of Company) whatever steps are necessary to ensure that our total work force has adequate minority, female, and local representation. We will utilize the following methods in our recruitment attempts: 1. Local advertising media (newspapers, radio, TV); 2. Community organizations (churches, clubs, schools); 3. Public and private institutions in the area (UNI, Hawkeye Community College); 4. Job Service of Iowa; and 5. Other. D. will seek qualified minority, (Name of Company) female, and local group applicants for all job categories and will make asserted efforts to increase minority, female and group representation in occupations at the higher levels or skill and responsibility. E. All sources of employment used shall be aware that we are an Equal Employment Opportunity Employer. Labor organizations representing our employees will be notified of our Equal Employment Opportunity Policy and Affirmative Action Program. F. Training, upgrading, promotion and transfer activities at all levels will be monitored to ensure that full consideration has been given to qualified minority, female, and local group employees. -3- G. will encourage other (Name of Company) companies with whom we are associated and/or do business, to do the same and we will assist them in their efforts. H. has taken the following (Name of Company) Affirmative Action to ensure that minority, female, local contractors and/or suppliers were provided opportunities to negotiate and/or bid on this project: (if none, write "NONE") 1. 2. As a result of the above efforts, we have involved minority, female, and local contractors and/or suppliers in the following areas of subcontracting: (if none, write "NONE") 1. 2. J. will require approved — (Name of Company) Affirmative Action Programs from all nonexempt contractors who propose to work on this -- project and will take whatever steps are necessary to ensure that non-minority contractors have adequate representation of minority, female and local persons in their total work force. K. In further accordance with rules and guidelines issued pursuant to Executive Order 11246 as amended, we establish the goals for our company, based on parity percentages supplied by the City, and we realize these goals will be reviewed on an annual basis. — L. will keep records of (Name of Company) specific actions relative to recruitment, employment, training, upgrading and promotion and will provide the City of Waterloo with any information relative to same, including activities of our SUBCONTRACTORS and suppliers as necessary or when requested. M. Parity figures for companies located in Waterloo are as follows: Minority Parity= .08 (8%) N. Affirmative Action (Name of Company) Employment Goals: The definition of Affirmative Action Goals is as follows: "Goals may not be rigid and — inflexible quotas which must be met, but must be targets, reasonably attainable by means of applying every good faith effort to make all aspects of the entire Affirmative Action Program work." -4- For the year 20_, please submit percentage targets for employing minorities and women. If you already have reached your target for hiring minorities and women, please submit that percentage. *Goals for Minorities: Goals for Women: *Your affirmative action goals should be between 1% and 10% or more for minorities and 1% and 5% or more for women. Please be advised that the goals or targets are purely your estimation of how many women and minorities your company can reasonably expect to hire in 20_. Note, that none of the goals are rigid or inflexible. They are targets that your company calculates as reasonably attainable. This will help the City in its monitoring procedures as required by City of Waterloo Resolution No. 1984-142(4). -5- CONTRACTOR'S TOTAL WORK FORCE (WATERLOO) HOURLY NAME AND ADDRESS JOB CATEGORY RACE SEX WAGE INDICATE: DISABLED VETERAN: DV VIETNAM ERA VETERAN: W HANDICAPPED: H -6- We hereby certify that we are in compliance with all City and Federal Affirmative Action Regulations and agree to accept all liability for failure to comply. Respectfully submitted, By: Company Executive Date By: Equal Employment Opportunity Officer Date City of Waterloo Affirmative Action Officer Approved Disapproved Reason: By: Date: -7- DESCRIPTION OF JOB CATEGORIES 1. Officials/Manager: Occupations in which employees set broad policies, exercise overall — responsibility for execution of all policies, or direct individual departments or special phases of the agency's operations or provide specialized consultation on a regional, district or area basis. Includes: department heads, bureau chiefs, division chiefs, directors, deputy directors, controllers, examiners, wardens, superintendents, unit supervisors, sheriffs, police and fire chiefs and inspectors and kindred workers. 2. Professionals: Occupations which require specialized and theoretical knowledge which is — usually required through college training or thorough work experience and other training which provides comparable knowledge. Includes: personnel and labor relations workers, social workers, doctors, psychologists, registered nurses, economists, dietitians, lawyers, system analysts, accountants, engineers, employment and vocational rehabilitation counselors, teachers — or instructors, police and fire captains and lieutenants and kindred workers. 3. Technicians: Occupations which require a combination of basic scientific or technical knowledge — and manual skill which can be obtained through specialized post-secondary school education and through equivalent on-the-job training. Includes: computer programmers and operations, draftsmen, surveyors, licensed practical nurses, photographs, radio operators, technical illustrators, police and fire sergeants and kindred workers. — 4. Office/Clerical: Workers are responsible for internal and external communication, recording and retrieval of data and/or information and other paper work required in an office. Includes: bookkeepers, messengers, office machine operators, clerk-typists, stenographers, court transcribers, hearing reporters, statistical clerks, dispatchers, license distributors, payroll clerks and kindred workers. 5. Skilled Craft Workers: Workers perform jobs which require special manual skill and a thorough and comprehensive knowledge of the processes involved in the work which is acquired through on-the-job training programs. Includes: Mechanics and repairman, electricians, heavy equipment operators, stationary engineers, skilled machine occupations, carpenters, compositors and typesetters and kindred workers. 6. Sales Workers: Occupations engaging wholly and primarily in direct selling. Includes: — advertising agents and salesman, insurance agents and brokers, real estate agents and brokers, stock and bond salesmen, demonstrators, salesmen and sales clerks, grocery clerks and cashier checkers, and kindred workers. — 7. Operatives (semi-skilled): Workers who operate machine or processing equipment or perform other factory-type duties of intermediate skill level which can be mastered in a few weeks and require only limited training. Includes: apprentices (auto mechanics), plumbers, building trades, — metal working trades, bricklayers, carpenters, electricians, machinists, mechanics, printing trades, etc., operatives, attendants (auto service and parking), plasterers, chauffeurs, deliverymen and furnacemen, heaters (metal), laundry and dry cleaning operatives, milliners, mine operatives and — laborers, motormen, oilers and greasers, (except auto painters), (except construction and maintenance), photographic process workers, stationary fireman, truck and tractor drivers, weavers, (textile), welders and flame cutters and kindred workers. -8- 8. Laborers (unskilled): Workers in manual occupations which generally require no special training. Perform elementary duties that may be learned in few days and require the application of little or no independent judgment. Includes: garage laborers, car washers and greasers, gardeners (except farm) and groundskeepers, longshoremen, and stevedores, lumbermen, raftsmen and woodchoppers, laborers performing lifting, digging, mixing, loading and pulling operations and kindred workers. 9. Apprentices: Persons employed in a program including work training and related instruction to learn a trade or craft which is traditionally an apprenticeship, regardless of whether the program is registered with a Federal or State agency. 10. Trainees (on-the-job): Production, persons in formal training for craftsmen when not trained under apprentice programs--operative laborer, and service occupations. White Collar. . . persons engaged in formal training for clerical, managerial, professional, technical, sales, office and clerical occupations. -9- ITEMS OF POTENTIAL MBE/WBE PARTICIPATION NOTICE TO PROSPECTIVE BIDDERS: The following are items from the Terminal Building Carpet - TERMINAL IMPROVEMENTS, project that have a potential for MBE/WBE Participation. This listing, however, is not intended to be all encompassing; to preclude MBE/WBE Contractors from bidding on any items of the Proposal as a Subcontractor or the entire Proposal as a Prime Contractor. All items are eligible for participation. MBE/WBE GOALS FOR THIS PROJECT IMPORTANT: Prime Contract Bidders should be aware that ten percent (10%) MBE goal and two percent (2%) WBE goal is attached to this project. "Certified Return Receipt" letters are no longer needed with the bid showing proof of contacting MBE or WBE Subcontractors, but the Pre-Bid Contact Information Form must be filled out completely. City of Waterloo Contract Compliance Officer: Contract Compliance Officer Community Development Board Carnegie Annex, Suite 202 620 Mulberry Street Waterloo, Iowa 50703 Phone: (319)291-4429 MBE/WBE PARTICIPATION CSVI 91109ALO200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 M-1 of 6 SUBCONTRACTOR'S BID REQUEST FORM PRIME BIDDER'S LETTERHEAD Contract No.: Letting Date: — I, (subcontractor's name), hereby attest that I have been solicited for a bid on (project name) in the area of (description of work and bid item no.). (Prime contractor) has informed me that if I am interested in bidding, a subcontracting bid proposal must be submitted to the company office by(date) and (time). Subcontractor's Company Name — Date Subcontractor's Signature Date Prime Bidder's Signature MBE/WBE PARTICIPATION CSVI 91109AL0200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 M-2 of 6 LETTER TO BE USED WHEN SOLICITING FOR SUBCONTRACTOR QUOTES Subcontractor Company Name Address RE: Contract No.: Dear • (Prime Contractor's Company Name) is presently soliciting for the following work in connection with the above referenced project. (Insert bid Item Nos. and Description of Work) (Prime Contractor's Company Name) is an Equal Opportunity Employer, and all qualified bidders will not be discriminated against due to race, religion, color, sex, or origin. If interested in bidding your proposal must be turned in to this office by (Date) and (Time) Sincerely, (Prime Contractor's Representative) Form CCO-3 (11/28/2001) MBE/WBE PARTICIPATION CSVI 91109AL0200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 M-3 of 6 LETTER OF INTENT TO BID (MBE/WBE LETTER) According to the Current MBE/WBE Contract Compliance Program -2002, all MBE/WBE Contractors interested in submitting subcontractor quotes on construction projects with goals, MUST submit a LETTER OF INTENT TO BID to the City of Waterloo Contract Compliance Officer at least seven (7) days prior to bid opening. The LETTER OF INTENT TO BID must list the specific items which the MBE/WBE Contractor is interested in bidding. — Letter should include the following: Name of Project: Your Company Name: Address: Phone: Date: List of Specific items to be bid: Item No. Description: Item No. Description: Item No. Description: Item No. Description: Item No. Description: (Subcontractor's Company Name and authorized signature) Return this LETTER OF INTENT TO BID to: Contract Compliance Officer — Community Development Board 620 Mulberry St. Carnegie Annex, Suite 202 Waterloo, IA 50703 Phone: (319) 291-4429 Form CCO-5 (06-20-2002) — MBE/WBE PARTICIPATION CSVI 91109AL0200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 M-4 of 6 a) 0 0 C O C CO N a) W W U U >, co O @a ° aU) O m cn m ca c`a rn ° c o .EE2 aa) pm � o > � cEo E� c is ° w a o o o � a a) �a) a) 0 a m fY c 00 o O o� 0- E 2 to o 2 W ° 0 a a a) @ U a) �- y c .- m o C a) m L W a) UU � o E o_ .c a) cc a) � _aL... - U .0 C • 15 E L O W 04- a >, as O Q•� o is 7 '� Z 0 . C a) U to L 7 a) O C •tn O C_ L 0 Q O C13t O ` ' C 0 w 0 0 m a) U a •= m ao a) a0 .10 0m c Z m E U c a o E ° m w co oo 0 o E .E aa)) '� m - a) fa_ mew a) H w a woo m a) pm Q m O a) Q ° - a o p • 2 c 2 2 m -° U o- E — °° moo w CO c m 2 m a) a) > 0)o ° 1° m a) a) 0 a) o p CD H o c c - LL w E c 0E c2 a) tea) a) z > Q � .N U co mom � > UU�) ° @ O -o c CO a) - c � n3LN c°) o a) -c a)a 0 caicLi E ° as > E0O a) a) � Oa c _ � w N � u) > a) H C q 02 0al w cL5 E C y .0 O z nia O c ° oW rnN o - o CO o O v) is • ° a m a) Cl) ca) � c o 0 � �' � � 0 a) _ U - O u, Cii U m ° m a � 'a o Jm o ~ coi L a3 a) cn in 15 E E to ° �° , Q a Dm .� = O a 0 CO w C ° 0 0 cn > 0 0 0 w � � ° U � cw n °o f° c° E � � o ._ fn W W L0 0 O N co C W L ` N c a3 N L 0 � Z cm mO � L E c0n as LE h G L rY O a2 ta w a) u°) c a Cm 3 w '- c°) o W co 3 .O m W0 CO 0 - 0 � � m m W 7H ui E o- Q 0 csi zLL a) .E CC = a) ° al H wm -aa E wE o > w �p wZ ° .,. c 0 a s N z m < as t .° m - m' 0 �Z cnO c NX) u_ = > w w 3 p m L L v off wQ ° al ZOO ^�,ra co CO c2 Uap as a0 3 0 >U zg ix -0 -a H 0 � U)) o Z Ew o > a) ° 0 0 02 �z W Q c a a) = p c a) C a) U p = O a) U as c MI O c m L c m a) c c 3 a) > .2 ain L mH m ° o Z E E) ) E w .> U Nm '5 c o o 0; ; 1E _ Q 0 --• H W CO w as a) m E o ° c .E 0 c 00z o `��° > U E c _0 U O a.) -2 ° mom ° � fl- "0w � 0 E 0 o z o � w .� -a . ui CD 'o cr.) a) m o � •a) oa O 0 c -o a Oa � m ° m � w N E a o 3 cla w - m c• 0 u) U 1E c o to a Lu o-= ° z n3 a U a)C ° O 0 m uJ o a) -2 o Zia o >. m 0 '.- c � ,_ 0 N w 0 � O E al m (a U a) L N 2 ` 0 C O) o N .E a) O .2 U c a o � 3 IL _c U) -' a ° o Q CU 0 C � � � LL .E ° nZ a) od co p Cr ° a) � � as E o v) - Z-0 v) o a) E au) 0 � — a`) c 0 a o E a c cn o O 0 :° � 0- cn 30 Zr) > ns ru U m o w c a c ° .> 0.) v`ni CO 2 n@ a)O Ct m U) > E � a) c _0 >, a5 N 4- pa cu.. oa 'cn ELa = a) U 0) E U a) W O 0-'" C in a U 0 - L 7 0 c = N c O • ° oo LLaoi ma) toaa)) C ° > .(7) E0 -c3 ° ° oY > o w� ° cn � OcaE ° E U oQa � o ° o U O 0 c W d �a c c U a) D ° H o ._L .� N N 3 U L to a - H • o W O W p a) > 0 Q U O 0 U + _ `) 0 Cam to ZNO ma to > CO ` •N N tn � a) . to - C � a c ° coo wo c a) _ O a a U 3 u) c °-c 0 CO • m oa o ,� O U 0) C .Q a) O c ° ° to O c .a C cn0 c” 0 a) N N M ,_ s W a) N c 073 O U c�a U c °" 0 rn 0 Z Ufl m CO)i wo a m o f° � cc) E _ o cz aw m 0E a>) 0 - 0 et c 0 O Z C O C L o ° -_° 0 W H L m ' O a) Q a L 'a a) Q ° O N O D a) c c � 0 a 0 >-° a) m Q o G E a) 0 0 Ce m U (0) 0 d co U ° .° p m L p 0 C E a) O 0 0 0 I- - w U E >,U H a)) al 0 0 0 °) W a co o p o c c z om O •- c Cl) o � 00 � < o — m e 0 m � o) = o c rn a`) o o < � mWOZ � Od < o o 0 m a) a) 0 `t Qo 0 o c _ % 0 as E U o O as o ° ai0 O 2U co .0 Li -6 ai 0) 2 C C cL5 O ao m . Uc cc 0 U min ilium c COa V. - N > o f c _c .2 0L U mc° O 0 o a CO m N ` = C 0 L C cca m U ° U d Q a) O` 0 0 E E `t o f . as < o = .0 U H •cn 4- uU a) o) .o w E E 2 a E LU0 d 0. a a)-00 � ci CO cNi :,.. 2 0 c= 0 - o cri d H n U)) - 0 0 < raa ci 2 Q § E\ 2 ®° t ƒ \ 6 0 / [2 - 5 f E m = ± IC x / L 0 — 0 / / O0 ( 0 0 gnC E a n5 - e t $ / / 2 % _ 0. / co y _ - \ 2 2 _ o m § 2 0- £ ) - 0 o c L D / / f / \ C \ o 0 _ o 2 & § / \ / § Eo E 0 0 2 = e « ■ - c / k / 4 = E t 0 7 7e a ae % 0 @ k 2 \ .m £ 7 m g a 0 \ 0 2 76 c 2 /ab = e / \ § 2 \ E U 7 ° [ k 0 ce / � .\f \ / / 9 0 � � o_ \ o ƒ / � kk � � / ■ 2 Ee / � ® � B ° ao & - § / � '® � � w2 � ® R -0c = tea � z � « 2 $ 2 2 § \ % $ � o I � \ k 7E E \ f / / 0w 2 §§ @ o 0 5 k o . ° cn > � 2 R m � em oc J ° ° $ = 02 ' ae 0 LuZ - 2 ° - .E 2 $ E 7 z_ a ° 0 _ <k wZ O kk _a :E / k ° V � w v }_\ mI- / 2 0 / -o- P $ xz �r 2 m @ w \z alZ / b � '7 § § b mf 2@ 00 2S \ / / o .E Hof of - w °- c ° 2 & > 2 \ = c - ■ mm 2 2gk LD' / w \ ° .2 ° Cl)2 � k 2w > » la a2C &5 � m O 0 a % % 0 .� .2 R U 2� 0m apt £ 0 zm — co L _ ° m2 u _ / � 7 � 0 � � ow $ S LU co k O & 'ef oo / no ea Z � 2E \ � E mU) < � § e / E c@ R 0 as = ew S � 0 b \ / eta e ® ® k / f of \ k / / - $ » 77 2 '( Im 2 .@ E I a) LL § -I / % sE � a) £ o ® co as � 2 £ � — I / 0 � G 0Enb \ 'C.) -'E' ®2 £ � moo / Z & �Ce / t / / % /y / / � \ 0 _ 2 ° 2 § S / @b § 032 15 � � E { 2 \ f = b22 ' b2 $ o coo & G � h \ vb 7 �ka « \ 2k Cr.)co \ ° 7 « - / 5 a) E 'q - o ƒ f\ / @ � 0- = f 2 .g 0 <0 . ® / w � \ / �\ \ / \ \ t \ 0 §\ ( \ § \ \ m \ CO co / E \0- b om oMa � oo »� $ L =u o Z 0@ « 3 ¥ o4 � - - �< CERTIFIED MBE / WBE CONTRACTORS CITY OF WATERLOO, IOWA CONTRACT COMPLIANCE OFFICE Community Development Board Carnegie Annex, Suite 202 620 Mulberry Street Waterloo,Iowa 50703 City WEB Site: www.ci.waterloo.ia.us Contract Compliance WEB Site for listing updates: http:l/www.wplwloo.lib.ia.uslcontractcompliancel Contact: Rudy Jones, Community Development Director Email: rudv.iones(tiwaterloo-ia.org Phone: (319) 291-4429 Fax: (319) 291-4431 MBE/WBE Certified Contractors List Page 1 of 4 CERTIFIED MBE CONTRACTORS CARTER ELECTRIC 725 Adams Street Waterloo, IA 50703 Phone: (319)232-9808 Pager: (319)235-4021 Contact: Derrick Carter Specializing in: ELECTRICAL CONTRACTOR CULPEPPER ELECTRIC 1731 Cottage Grove Avenue Waterloo, IA 50707 Phone: (319)235-0885 Fax: (319)236-8177 Contact: Martin Culpepper Certified: City of Waterloo Certified MBE,Licensed Electrician Specializing in: ELECTRICAL CONTRACTOR DANIELS HOME IMPROVEMENT 339 Albany Street Waterloo, IA 50703 Phone: (319) 961-1659 Contact: Sammy Daniels Specializing in: ALL TYPES OF CONCRETE FLATWORK, POURED WALLS ALL TYPES, FOOTINGS, LIGHT L' DEMOLITION D.C. CORPORATION 426 Beech Street Waterloo, IA 50703 L Phone: (319)493-2542 FAX: (319)236-0515 Contact: Terry Phillips Certified: City of Waterloo Certified MBE, Iowa DOT, TSB Certified Specializing in: COMMERCIAL AND RESIDENTIAL DEMOLITION, CONCRETE PAVING, DRIVEWAYS, TRUCKING (ALL TYPES), GENERAL CONSTRUCTION MBE/WBE Certified Contractors List Page 2 of 4 GREER'S WORKS 2003 Plainview Street Waterloo, IA 50703 Phone: (319) 233-4701 Contact: Willie Greer Specializing in: DRIVEWAYS, SIDEWALKS, CARPENTRY, ROOFING, GENERAL CONSTRUCTION OLD GREER'S WORKS 2309 Springview Street Waterloo, IA 50707 Phone: (319) 233-2150 Contact: David L. Greer, Sr. Specializing in: ROOFING& GENERAL CONSTRUCTION QUICK CONSTRUCTION 217 Bates Street Waterloo,IA 50703 Phone: (319)215-4166 Contact: Leroy Harrington Specializing in: ALL TYPES OF CONCRETE FLATWORK AND GENERAL CONSTRUCTION D & D CONSTRUCTION 1124 West Donald Street Waterloo, IA 50703 Phone: (319) 961-4208 Contact: Darrell E. Caldwell, Sr. Specializing in: ROOFING AND GENERAL CONSTRUCTION off E. CASTRO ROOFING 702 Riehl Street Waterloo, IA 50701 Phone: (319) 215-5683 Contact: Emillio Castro Specializing in: ROOFING, SIDING, GENERAL CONSTRUCTION MBE/WBE Certified Contractors List Page 3 of 4 CERTIFIED WBE CONTRACTORS ATLAS PAINTING, INC.* 911 Sycamore Street P.O. BOX 65 Waterloo, IA 50704 Phone: (319)232-9164 Specializing in: COMMERCIAL AND INDUSTRIAL PAINTING WATCO CONSTRUCTION, INC.* 2920 Texas Street Waterloo,IA 50702 Phone: (319)233-7481 Certified: City of Waterloo WBE Contact: Patricia J. Kimball Specializing in: _ STORM SEWER, INLETS, DRAIN TILE, WATER MAIN, SANITARY SEWER, INTAKE STRUCTURES PETERMAN & HAES CARPET ONE* 4003 University Waterloo, IA 50701 _ Phone: (319)233-6131 Fax: (319)233-6133 Certified: City of Waterloo WBE Email: JR11486(cr�cfu.net Contact: Carol Reese Specializing in: FLOOR COVERING *DENOTES WOMEN BUSINESS ENTERPRISE MBE/WBE Certified Contractors List Page 4 of 4 STATEMENT OF BIDDER'S QUALIFICATIONS (To be submitted by the Bidder only upon the specific request of the City of Waterloo, Iowa.) All questions must be answered and the date given must be clear and comprehensive. This statement must be notarized. If necessary, questions may be answered on separate attached sheets. The Bidder may submit any additional information he desires. 1. Name of bidder. 2. Permanent main office address. 3. When organized. 4. If a corporation, when incorporated. 5. How many years have you been engaged in the contracting business under your present firm or trade name? 6. Contracts on hand: (Schedule these, showing amount of each contract and the appropriate anticipated dates of completion.) 7. General character of work performed by your company. 8. Have you ever failed to complete any work awarded to you? If so, where and why? 9. Have you ever defaulted on a contract? If so, where and why? 10. List the more important projects recently completed by your company, stating the approximate cost for each, and the month and year completed. 11. List your major equipment available for this contract. 12. Experience in construction work similar in importance to this project. 13. Background and experience of the principal members of your organization, including the officers. 14. Credit available: $ 15. Give bank reference: 16. Will you, upon request, fill out a detailed financial statement and furnish any other information that may be required by the City of Waterloo, Iowa? STATEMENT OF BIDDER'S QUALIFICATIONS CSVI 91109AL0200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 SBQ-1 of 2 17. The undersigned hereby authorizes and requests any person, firm, or corporation to furnish any _ information requested by the City of Waterloo, Iowa, in verification of the recitals comprising this Statement of Bidder's Qualifications. Dated at this day of 20 — (Name of Bidder) — By: — Title: State of ) ss: — County of , being duly sworn deposes and says that he is _ of (Name of Organization) and that the answers to the foregoing questions and all statements therein contained are true and correct. Subscribed and sworn to before me this day of , 20_ Notary Public My commission expires STATEMENT OF BIDDER'S QUALIFICATIONS CSVI 91109AL0200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 SBQ-2 of 2 Exhibit A CONTRACT PROVISION Targeted Small Business (TSB) Affirmative Action Responsibilities on Non-Federal Aid Projects(Third-Party State-Assisted Projects) 1 a-1 May 2017 1 CONTRACT PROVISION -- Targeted Small Business(TSB)Affirmative Action Responsibilities on Non-Federal-aid Projects(Third-party State-Assisted Projects) 1. TSB DEFINITION A TSB is a small business, as defined by Iowa Code Section 15.102(10), which is 51% or more owned, operated and actively managed by one or more women, minority persons, service-disabled veterans or persons with a disability provided the business meets all of the following requirements: is located in this state, is operated for profit and has an annual gross income of less than 4 million dollars computed as an average of the three preceding fiscal years. — 2. TSB REQUIREMENTS In all State-assisted projects made available through the Iowa Department of Transportation, local governments have certain affirmative action requirements to encourage and increase participation of disadvantaged individuals in business enterprises. These requirements are based on Iowa Code Section 19B.7. These requirements supersede all existing TSB regulations, orders, circulars and administrative requirements. 3. TSB DIRECTORY INFORMATION Available from: Iowa Economic Development Authority Targeted Small Business Certification Program 200 East Grand Avenue Des Moines, IA 50309 Phone: 515-725-3132 Website: https://www.iowa.govitsb/index.php/home 4. THE CONTRACTORS TSB POLICY The contractor is expected to promote participation of disadvantaged business enterprises as suppliers, manufactures and subcontractors through a continuous, positive, result-oriented program. Therefore,the contractor's TSB policy shall be: It is the policy of this firm that Targeted Small Business (TSB) concerns shall have the maximum practical opportunity to participate in contracts funded with State-assisted funds which are administered by this firm (e.g. suppliers, manufactures and subcontractors). The purpose of our policy is to encourage and increase the TSB participation in contracting opportunities made available by State-assisted programs. — 5. CONTRACTOR SHALL APPOINT AN EQUAL EMPLOYMENT OPPORTUNITY(EEO)OFFICER The contractor shall designate a responsible person to serve as TSB officer to fulfill the contractors affirmative action responsibilities. This person shall have the necessary statistics, funding, authority and responsibility to carry out and enforce the firm's EEO policy. The EEO officer shall be responsible for developing, managing and implementing the program on a day-to-day basis. The officer shall also: A. For current TSB information, contact the Iowa Economic Development Authority (515-725-3132)to identify potential material suppliers, manufactures and contractors. B. Make every reasonable effort to involve TSBs by soliciting quotations from them and incorporating them into the firm's bid. C. Make every reasonable effort to establish systematic written and verbal contact with those TSBs having the materials or expertise to perform the work to be subcontracted, at least two weeks prior to the time quotations are to be submitted. Maintain complete records of negotiation efforts. D. Provide or arrange for assistance to TSBs in seeking bonding, analyzing plans/specifications or other actions that can be viewed as technical assistance. Page I TSB Affirmative Action Responsibilities A. Ensure the scheduled progress payments are made to TSBs as agreed in subcontract agreements. B. Require all subcontractors and material suppliers to comply with all contract equal opportunity and affirmative action provisions. — 6. COUNTING TSBs PARTICIPATION ON A PROJECT TSBs are to assume actual and contractual responsibilities for provision of materials/supplies, subcontracted work or ... other commercially useful function. A. The bidder may count: (1) Planned expenditures for materials/supplies to be obtained from TSB suppliers and manufacturers; or (2) Work to be subcontracted to a TSB; or (3) Any other commercially useful function. B. The contractor may count: (1) 100%of an expenditure to a TSB manufacturer that produces/supplies goods manufactured from raw materials. — (2) 60%of an expenditure to TSB suppliers that are not manufacturers; provided the suppliers perform a commercially useful function in the supply process. (3) Only those expenditures to TSBs that perform a commercially useful function in the work of a contract, including those as a subcontractor. (4) Work the Contracting Authority has determined that it involves a commercially usefulfunction. The TSB must have a necessary and useful role in the transaction of a kind for which there is a market outside the context of the TSB program. For example, leasing equipment or purchasing materials from the prime contractor would not count. 7. REQUIRED DATA, DOCUMENTS AND CONTRACTAWARD PROCEDURES FROM BIDDERS/CONTRACTORS FOR PROJECTS WITH ASSIGNED GOALS A. Bidders Bidders who fail to demonstrate reasonable positive efforts may be declared ineligible to be awarded the contract. Bidders shall complete the bidding documents plus a separate form called "TSB Pre-Bid Contact _ Information". This form includes: (1) Name(s)of the TSB(s)contacted regarding subcontractable items. (2) Date ofthe contract. (3) Whether or not a TSB bid/quotation was received. (4) Whether or not the TSB's bid/quotation was used. (5) The dollar amount proposed to be subcontracted. B. Contractors Using Quotes From TSBs Use those TSBs whose quotes are listed in the"Quotation Used in Bid" column along with a"yes" indicated on the Pre-bid Contact Information form. Page 2 A. Contractors NOT Using Quotes From TSBs If there are no TSBs listed on the Pre-bid Contract Information form, then the contractor shall document all efforts made to include TSB participation in this project by documenting the following: (1) What pre-solicitation or pre-bid meetings scheduled by the contracting authority were attended? (2) Which general news circulation,trade associations and/or minority-focused media were advertised concerning the subcontracting opportunities? • (3) Were written notices sent to TSBs that TSBs were being solicited and was sufficient time — allowectively? • (4) Were initial ed solicitations of par c pateinterestedeff TSBs followed up? (5) Were TSBs provided with adequate information about the plans, specifications and requirements of the contract? (6) Were interested TSBs negotiated with in good faith? [f a TSB was rejected as unqualified, was the decision based on an investigation of their capabilities? (7) Were interested TSBs assisted in obtaining bonding, lines of credit or insurance required by the contractor? (8) Were services used of minority community organization, minority contractors'groups; local, State and Federal minority business assistance offices or any other organization providing such assistance. The above documentation shall remain in the contractor's files fora period of three(3)years after the completion of the project and be available for examination by the lowaEconomic Development Authority. 8. POSITIVE EFFORT DOCUMENTATION WHEN NO GOALS ARE ASSIGNED Contractors are also required to make positive efforts in utilizing TSBs on all State-assisted projects which are not assigned goals. Form"TSB Pre-bid Contact Information"is required to be submitted with bids on all projects. If there is no TSB participation, then the contractor shall comply with section 7C. of this document prior to the contract award. Page 3 a / 5 § ) m 0 , , \ \ / 2 E = m / a } E / CIS f \ 0 � — E ° s 2 Z o k / R / al E / 7 / k 0• — 0 - ± e < L o ' \_ Z � � CL f k w O / / \ 0 � = 2 E \ 0 — cn k 3 G . \ k k 0 @0 m 0 E 2 LU2 e o £ 0 * o I— a g \ ) / 0 L a f \ 3 ® m / 0 2 ± / \ ± g — / -c / 0./ m / E 0Z 0 o { Q 2 / 2 f m ® W0 -2 y 0 \ o \ g ƒ 0 — % ® 2 \ CO ƒ q - \ ▪ C \ \ «ca i_ 2 . % ® / » \ ƒ / % / / c / % g / o - 0 / # a = a % _ £ % I _ . . ( / / ) / ' co / \ ci 2 < \ c a E @ 0 a 0 C / 6 m E2 \ < < m < o / / \ / \ \ « \ < 0 m — 00 m 0_ • ± \ ® / 2 00 0 <EK ca \ ° 0 / f / . . - o ® \ £ \ � 52 coE0 � ƒ E O. E 0 • [ %2 m ° 0 CO e — E e o n @ ± @ / o E c o -4 « 0 @ § / / § o < C . . . 0 ƒ % 7 ° 2 / \ ® E _ o , / E / H \.0 % G u) m 0 &9 E p 0 ° § m3 5 \ o a . / \ R 0 \ \ / \ƒ/ p .o ± Cl) ° I- cn o \ / / / _ kco \ 0 0o k / / .r U 0) co . . / 2 0 E / / 2 / / / \ ƒ e % c \ — a) m $ Cl) w \ \ 'E 0 \ / 9 o ® 22 o .c $ a -C a . _ 40 \ off . > E Ec / K / \ C \ CD w ) / — F / - 0 � 0) f 6 / d { o c 3 'E e = [ 2 / _ o e a ) R � _ _ / / $ 0 O. 0 0 £ 7 5 £ Za / / _ UTILIZATION OF TARGETED SMALL BUSINESS (TSB) ENTERPRISES ON NON-FEDERAL AID PROJECTS (THIRD-PARTY STATE-ASSISTED PROJECTS) In accordance with Iowa Code Section 19B.7, it is the policy of the Iowa Department of Transportation (Iowa DOT) that Targeted Small Business(TSB) enterprises shall have the maximum practicable opportunity to participate in the performance of contracts financed in whole or part with State funds. Under this policy the Recipient shall be responsible to make a positive effort to solicit bids or proposals from TSB firms and to utilize TSB firms as contractors or consultants. The Recipient shall also ensure that the contractors or consultants make positive efforts to utilize TSB firms as subcontractors, subconsultants, suppliers, or participants in the work covered by this agreement. The Recipient's"positive efforts"shall include, but not be limited to: — 1. Obtaining the names of qualified TSB firms from the Iowa Economic Development Authority(515-725-3132)or from its website at: https://www.iowa.govitsb/index.php/home. 2. Notifying qualified TSB firms of proposed projects involving State funding. Notification should be made in sufficient time to allow the TSB firms to participate effectively in the bidding or request for proposal(RFP)process. 3. Soliciting bids or proposals from qualified TSB firms on each project, and identifying for TSB firms the availability of subcontract work. 4. Considering establishment of a percentage goal for TSB participation in each contract that is a part of this project and for which State funds will be used. Contract goals may vary depending on the type of project,the subcontracting opportunities available, the type of service or supplies needed for the project, and the availability of qualified TSB firms in the area. 5. For construction contracts: a) Including in the bid proposals a contract provision titled"TSB Affirmative Action Responsibilities on Non-Federal Aid Projects (Third-Party State-Assisted Projects)"or a similar document developed by the Recipient. This contract provision is available on-line at: http://www.dot.state.ia.us/local_systems/publications/tsb_contract_provision.pdf b) Ensuring that the awarded contractor has and shall follow the contract provisions. -- 6. For consultant contracts: a) Identifying the TSB goal in the Request for Proposal (RFP), if one has been set. b) Ensuring that the selected consultant made a positive effort to meet the established TSB goal, if any. This should include obtaining documentation from the consultant that includes a list of TSB firms contacted; a list of TSB firms that responded with a subcontract proposal; and, if the consultant does not propose to use a TSB firm that submitted a subcontract proposal, an explanation why such a TSB firm will not be used. The Recipient shall provide the Iowa DOT the following documentation: 1. Copies of correspondence and replies, and written notes of personal and/or telephone contacts with any TSB firms. Such '— documentation can be used to demonstrate the Recipient's positive efforts and it should be placed in the general project file. 2. Bidding proposals or RFPs noting established TSB goals, if any. 3. The attached"Checklist and Certification." This form shall be filled out upon completion of each project and forwarded to: Iowa Department of Transportation, Civil Rights Coordinator, Office of Employee Services, 800 Lincoln Way,Ames, IA 50010. Page 5 CHECKLIST AND CERTIFICATION — 3 For the Utilization of Targeted Small Businesses (TSB) On Non-Federal-aid Projects (Third-Party State-Assisted Projects) Recipient: Project Number: County: Agreement Number: Z. Were the names of qualified TSB firms obtained from the Iowa Department of Inspections and Appeals? ❑ YES ❑ I` If no, explain 2. Were qualified TSB firms notified of project? ❑ YES ❑ NO If yes, by ❑ letter, ❑telephone, ❑ personal contact, or ❑ other(specify) If no, explain — 3. Were bids or proposals solicited from qualified TSB firms? ❑ YES ❑ NO If no, explain — 4. Was a goal or percentage established for TSB participation? ❑ YES ❑ NO If yes, what was the goal or percentage? If no, explain why not: 5. Did the prime contractor or consultant use positive efforts to utilize TSB firms on subcontracts? Li YES Li NO If no, what action was taken by Recipient? Is documentation in files? ❑ YES ❑ NO 6. What was the dollar amount reimbursed to the Recipient — from the Iowa Department of Transportation? $ What was the final project cost? $ What was the dollar amount performed by TSB firms? $ , Name(s) and address(es) of the TSB firm(s) (Use additional sheets if necessary) Was the goal or percentage achieved? ❑ YES ❑ NO If no, explain As the duly authorized representative of the Recipient, I hereby certify that the Recipient used positive efforts to utilize TSB firms as participants in the State-assisted contracts associated with this project. Title Signature Page 6 GENERAL SPECIAL PROVISIONS 1. SCOPE OF WORK The work covered by this contract consists of furnishing all labor, equipment, and materials and performing all operations, in connection with the Terminal Building Carpet - TERMINAL IMPROVEMENTS, in accordance with these specifications. — The specifications are dated May 28, 2019. They have the general title of Terminal Building Carpet-TERMINAL IMPROVEMENTS. The Iowa Department of Transportation Standard Specifications for Highway and Bridge Construction, Series of 2015, are to be used, along with the special provisions described herein, and shall be considered as part of the contract documents. 2. CONFLICTING SPECIFICATIONS All requirements of other specifications contained in the contract documents which conflict with the provisions of the special provisions will be considered void. 3. DUMPING AREAS _ Excess material resulting from construction operations shall be hauled to the County Landfill or other area secured by the contractor and approved by the City Engineer. Rubble, rubbish, trees, brush, and other unsuitable backfill material, as designated by the City Engineer, shall be hauled to the County Landfill. All Landfill charges are to be considered incidental to the contract and are — the responsibility of the contractor. 4. CONSTRUCTION DAMAGE The Contractor shall exercise care during construction operations to ensure the safety and protection to existing features located near or within the limits of construction. Damage caused by negligence or poor workmanship, as determined by the Engineer, shall be considered the Contractor's responsibility. 5. REMOVED MATERIALS All materials removed as part of this Contract shall remain the property of the City unless the City determines that the materials are not salvageable and the City does not want to retain ownership of the materials. Materials designated in the field by the Engineer as nonsalvageable shall be hauled and disposed of by the Contractor at no cost to the City. All other materials shall be transported to locations as directed by the Engineer. No separate measurement or payment will be made for hauling or disposing of removed materials and it shall be considered incidental to applicable items. 6. OVERHAUL — Overhaul will not be paid for "surplus material" obtained from any of the items of construction under this contract. The cost of overhaul will be considered as incidental to the items to which it applies. GENERAL SPECIAL PROVISIONS CSVI 91109AL0200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 GSP-1 of 5 7. PAY ITEMS All pay items are listed in the proposal and shall include the purchase of all materials, delivery of these materials, and furnishing all labor, plant, and miscellaneous work needed to make the item complete. All such cost shall be incidental to the proposed item to which it applies and shall not _ be considered for separate payment. 8. BREAKDOWN OF LUMP SUM CONTRACT PRICE ITEMS The Contractor shall, immediately upon execution and delivery of the contract, before the first estimate for payment is made, deliver to the City Engineer a detailed estimate giving a complete breakdown of the lump sum contract prices. The submitted breakdown shall be approved by the City Engineer prior to any payment of any lump sum price item. 9. PERMISSION TO HAUL OVER STREETS, RAILROADS, AND HIGHWAYS The Contractor will be required to secure, from the proper authorities, permission or permit which may be required to haul over streets, highways, railroads or private property, and any hauling operations of the Contractor shall be subject to the requirements of such permits, permission, and _ to all applicable regulations, laws, and ordinances governing hauling and movement of equipment over streets, railroads, highways, and private property. Any costs or inconvenience caused by obtaining any necessary permits or permission shall be considered completely covered by the price bid for the items in the proposal. -- 10. CONSTRUCTION SCHEDULING The Engineer shall approve Contractor's work schedule prior to starting. All revisions shall also be approved. The Engineer may change the schedule to accommodate changing construction conditions. The Contractor shall coordinate the work under this contract with contractors performing work under other contracts, which may be performed concurrently. The Contractor shall be responsible to notify the Police, Fire, Street, and Engineering Departments of the closing and opening of streets. The Contractor shall commence work within ten (10) days after receipt of the "Notice to Proceed" and diligently execute the work of the contract to completion. 11. PRE-CONSTRUCTION CONFERENCE Before any work is started, the Contractor shall arrange with the Engineer to hold a pre- construction conference for the purpose of discussing the contract. 12. UNDERGROUND UTILITIES It is the responsibility of the Contractor to obtain the location of gas lines, water lines, electric, telephone, and cable television cables or wires from the various utility companies and the City electrician before starting any excavation. The Contractor shall be responsible for any damage to any underground utilities. The Contractor shall expose those utilities indicated on the plans so that elevations may be determined before beginning construction. This work shall be considered — incidental to other items of work. If the Contractor believes that additional costs have been incurred due to a utility being improperly located, the resolution of the additional costs incurred shall be made between the contractor and the respective utility company. GENERAL SPECIAL PROVISIONS CSVI 91109AL0200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 GSP-2 of 5 13. SAFETY OF WORKERS AND PUBLIC The Contractor shall, at all times, take necessary precautions to protect the life and health of all persons employed on this project and the public. He shall provide necessary safety devices and safeguards in accordance with latest and best accident prevention practices. All such protection shall be furnished to employees without cost. No direct measurement of payment shall be made for this protection but shall be considered incidental to other items of work. The public shall be kept outside of any work area. 14. WORKING ON SATURDAYS, SUNDAYS AND LEGAL HOLIDAYS The Contractor shall notify the Engineer in writing forty-eight (48) hours in advance if work on Saturday is planned. By noon the Friday before the planned Saturday work, the Contractor shall confirm the Saturday work schedule with the project inspector. Work on Sunday requires prior approval of the Engineer in accordance with the Waterloo Standard Specifications. The Contractor shall not work the following days in 2019 due to City Holidays: Thursday, July 4, 2019 - Independence Day Monday, September 2, 2019- Labor Day 15. ACCESS TO SITE. Access to the work shall be limited to those gates and routes indicated on the plans. All areas used by the Contractor either for access or for construction operations shall be repaired by the Contractor after completion of the Contract work to restore such areas to essentially their original condition. All unsurfaced roads used by the Contractor shall be watered regularly by the Contractor to reduce dust. All surfaced roads, streets, or airport pavement used by the Contractor for access or hauling shall be swept at least daily or as directed by the Engineer. All damage to surfaced roads used by the Contractor shall be repaired to original condition or better at no cost to the Owner. The Contractor shall be solely responsible for security at those airport property entrance gates assigned to his use. At all times gates are unlocked the Contractor shall provide a full-time guard who shall: 1. Allow entry onto airport property of only those persons authorized, carrying proper _ identification, and previously registered with the Airport Security Office as Contractor's personnel, supplier, subcontractor or other party in connection with the work. 2. Keep a log of all vehicles and persons entering and leaving through the gate under his control. 3. Report immediately to the Airport Office any unauthorized entry into the airport. 16. INSPECTION OF THE SITE. Contractor shall inspect the construction site and the area of work in general and familiarize himself with existing conditions. Bidders shall arrange an individual site visit prior to Bidding by contacting the Airport Director at (319)291-4483. GENERAL SPECIAL PROVISIONS CSVI 91109AL0200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 GSP-3 of 5 17. SECURITY REQUIREMENTS. Contractor's supervisory employees shall obtain Security Clearance prior to having access to any area on the Airport within the limits of the perimeter fence (the 8' and 10' chain link fence). Other contractor employees who have a need for access to a work area on the Airport must be escorted by an employee with current Security Clearance. The _ Security-Cleared employee shall have no more than 10 employees under his/her direct supervision. This employee shall be in direct contact and control of and be responsible for all employees under his/her supervision at all times. The procedure for a Contractor's employee to obtain Security Clearance is as follows. — a. Obtain fingerprint form from the Airport Administration. Provide data on the fingerprint form and take it to the Waterloo Police Department office in City Hall. Fingerprinting will be conducted by the Waterloo Police Department. Return the completed fingerprint form to the Airport Administration. The cost of fingerprinting at the Waterloo Police Department is $10.00 per person to be paid at time of fingerprinting. b. The completed fingerprint form that has been returned to the Airport Administration will be forwarded for a criminal background check. c. After the background check is completed, which takes approximately 7-10 days, Airport Administration will issue approval notice of unescorted access to the airfield. d. Prior to access to the airfield, the person(s) are required to attend a Driver Training Program at the airport. This program takes approximately two (2) hours to complete. e. In addition to the cost of fingerprinting, a non-refundable payment in the amount of$100 is required for each Airport Security Clearance Request. This payment is due to the Waterloo — Regional Airport when the completed fingerprint form is returned to Airport Administration. Each company or agency must provide the Airport Administration with a list of individuals who have or are requesting Airport Security Clearance. '- 18. WORK AREA. The Contractor's operations, including storage of materials upon the site, shall be confined to authorized or approved areas. No unauthorized or unwarranted entry upon, or — passage through, or storage of materials shall be made upon other airport premises. Temporary buildings, storage sheds, shops and office, etc., may be erected by the Contractor only with the prior approval of the Engineer and shall be built with labor and materials furnished by the Contractor without expense to the airport. Such temporary buildings and utilities shall remain the property of the Contractor and shall be removed by him, at his expense, after the completion of the work. 19. CLEANUP OF PROJECT SITE. The Contractor shall at all times keep the site of the work and — adjacent premises as free from materials, debris, rubbish and trash as practicable, and shall remove same from any portion of the site if, in the opinion of the Owner, such materials, debris, rubbish or trash constitute a nuisance or are objectionable in any way to the public. The — Contractor shall be responsible for the removal of dirt accumulation or any other debris on pavements resulting from the Contractor's operations on the work. At the completion of the work the Contractor shall remove all materials, implements, barricades, equipment, staging, piling, falsework, debris and rubbish connected with or caused by operations for such work immediately upon the completion of that work and shall leave the premises in perfect condition insofar as affected by the work under this Contract. Fires for disposal of rubbish on the site are prohibited. — At the end of each day, the project site shall be inspected and cleaned of construction debris and trash. The project site shall be inspected by air operations prior to opening area to aircraft. GENERAL SPECIAL PROVISIONS CSVI 91109AL0200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 GSP-4 of 5 All cleaning shall be accomplished by a street sweeper or power broom to remove debris. Prior to sweeping, the area shall be cleaned of large debris, concrete, mud, etc., with an end loader. If the Contractor should fail to clean up the premises as required above, the Owner after giving the Contractor one (1) hour notice, may do so and charge the cost thereof to the Contractor. The Airport and the Contractor hereby agree that the cleanup charge will be $200.00 per hour. 20. TEMPORARY TOILETS. The Contractor shall provide and maintain temporary sanitary facilities as necessary for use of workmen. All facilities must be in compliance with statutory sanitation requirements. 21. CONTRACTOR COMMUNICATION. The Contractor shall provide a telephone, pager, etc., on the project site to enable communication between the Contractor and the Engineer or Airport personnel. The Contractor shall have a 24-hour contact person for after-construction-hours communication. This person shall be contacted in case of an emergency on the project site. 22. CONVICT LABOR. No convict labor may be employed under this contract. 23. CONSTRUCTION ACCESS ROUTE. See Appendix. 24. SITE PLAN. See Appendix. GENERAL SPECIAL PROVISIONS CSVI 91109AL0200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 GSP-5 of 5 SPECIAL PROVISIONS 1. LIQUIDATED DAMAGES Time is an essential element of this contract. It is important that the work be diligently pursued to completion. If the work is not completed within the specified contract period, plus authorized extensions, the Contractor shall pay to the City Liquidated Damages in the amount of$500.00 per day, for each day, as further described herein, in excess of the authorized time. Days beyond the specified completion date for which Liquidated Damages will be charged will be working days that the Contractor does, or could have worked from Monday through Saturday. Sundays will be counted only if work is performed. Partial working days will be considered as a full working day. Days not chargeable for Liquidated Damages will include rain days, Sundays, if no work is done, and legal holidays. Working days will cease to be charged when only punch list items remain to be completed. Punch list items do not include contract bid items or approved change/extra work orders. When the Contractor believes the project to be substantially completed, a written notice stating the same shall be submitted to the Engineer and a request made for a Punch List. If the work under the Contract extends beyond the normal construction season for such work, the Contractor shall submit to the Engineer in writing a request that working days counted toward the project be suspended until work is resumed the following construction season. This amount is not construed as a penalty. These damages are for the cost to the City of providing the required additional inspection, engineering and contract administration. 2. PERCENT OF CONTRACT TO BE PERFORMED BY PRIME CONTRACTOR The prime contractor shall be required to perform at least 35 percent of the total contract amount of the project. 3. SHOP DRAWINGS, CERTIFICATES, AND EQUIPMENT LISTS A. Submission of Drawings: 1. The Contractor shall submit to the Engineer all shop drawings and equipment drawings or lists as called for in the contract documents or as requested by the Engineer. Drawings and listings shall be complete and shall contain all required detail information conveyed according to the latest recommended standards for detailing. 2. The Contractor shall make any corrections required by the Engineer and submit the revised shop or equipment drawings or listings for review. After review by the Engineer, the shop or equipment drawings or listings will be so marked, dated, signed by the Engineer, and forwarded to the Contractor for reproduction and distribution. B. Submission of Equipment Lists: 1. If requested in the contract documents, as soon as practicable after award of contract and before any items of material or equipment are purchased, the Contractor shall submit to the Engineer for review a complete list of the principal fixtures and equipment to be incorporated into the work. SPECIAL PROVISIONS CSVI 91109AL0200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 SP-1 of 4 2. The Contractor shall also submit applicable brochures, technical data, catalogs, cuts, diagrams, manufacturer's drawings and installation instructions, samples if required, and other descriptive data including the complete description, trade name, model number, type, size, and rating. C. Engineer's Review: 1. Review by the Engineer shall not be construed as a complete check but will indicate only that the general method of construction and detail is satisfactory. The Engineer assumes no responsibility for errors in dimensions in the shop drawings and assumes the Contractor will use material complying with requirements of the contract documents or, where not specified, those of sound and reasonable quality, and will erect the subjects of such shop drawings according to recognized standards of first quality work or, when specified, according to standards of the contract documents. 2. Any work done or material ordered by the Contractor prior to review by the Engineer shall be at the Contractor's risk. D. ENGINEER'S ACTION ON SUBMITTALS 1. General: a. Except for submittals for record and similar purposes, where action and return on submittals required or requested, ENGINEER will review each submittal, mark with appropriate action, and return. Where submittal must be held for coordination, ENGINEER will so advise CONTRACTOR without delay. b. ENGINEER will stamp each submittal with action stamp, appropriately marked with submittal action. 2. Notification of Insufficient Information: a. If information submitted is not sufficient to complete review of submittal, — ENGINEER will send transmittal to CONTRACTOR notifying CONTRACTOR that additional information is required. b. Submittal will not be returned. Submittal will be placed in an "on hold" status until CONTRACTOR provides additional information. 3. Action Stamp: a. Marking: No Exceptions Taken. 1) Final Unrestricted Release: Where submittals are marked as "No Exceptions Taken," Work covered by submittal may proceed provided it complies with — Contract Documents. Acceptance of Work depends on that compliance. b. Marking: Make Corrections Noted. — 1) Final-But-Restricted Release: When submittals are marked as "Make Corrections Noted," Work covered by submittal may proceed provided it complies with ENGINEER'S notations or corrections on submittal and with Contract Documents. Acceptance of Work depends on that compliance. Resubmittal is not required. SPECIAL PROVISIONS CSVI 91109AL0200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 SP-2 of 4 c. Marking: Rejected. 1) Submittal Not Accepted: When submittals are marked as "Rejected," do not proceed with Work covered by submittal. Work covered by submittal does not comply with Contract Documents. 2) Prepare new submittal for different material or equipment supplier or different product line or material of same supplier complying with Contract Documents. d. Marking: Revise and Resubmit. 1) Returned for Resubmittal: When submittals are marked as "Revise and Resubmit," do not proceed with Work covered by submittal. Do not permit Work covered by submittals to be used at Project site or elsewhere where Work is in progress. 2) Revise submittal or prepare new submittal in accordance with ENGINEER'S notations. Resubmit without delay. Repeat if required to obtain different -- action marking. 4. PROJECT RECORD DOCUMENTS A. Maintain at the project site one record copy of the drawings, project manual, addenda, change orders and other modifications to contract, field orders or clarifications, shop drawings, field test records, and associated permits. B. Provide one marked up set of drawings to Engineer at substantial completion for use in preparation of record drawings. C. Maintain record documents in clean dry, legible condition and in good order. Do not use record documents for construction purposes. Make record documents available for inspection by Engineer. 5. BUILDING PERMITS Contractor shall be required to obtain all necessary building permits from the City of Waterloo Building Department. All costs for permits shall be the responsibility of the Contractor. 6. STANDARD SPECIFICATIONS The Standard Specifications, which are referenced in the contract documents, are designated as follows: WATERLOO STANDARD SPECIFICATIONS - Standard Specifications for Municipal Public Works Construction, City of Waterloo, Iowa." 7. SPECIAL PROVISIONS Standard Specifications are amended by the following additions. These are Special Provisions and shall prevail over those published in the Standard Specifications. Section 09 68 00-Carpeting 8. AIRPORT SECURITY REQUIREMENTS Contractor's supervisory employees shall obtain Security Clearance prior to having access to any area on the Airport within the limits of the perimeter fence (the 8' and 10' chain link fence). Other contractor employees who have a need for access to a work area on the Airport must be escorted SPECIAL PROVISIONS CSVI 91109AL0200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 SP-3 of 4 by an employee with current Security Clearance. The Security-Cleared employee shall have no more than 10 employees under his/her direct supervision. This employee shall be in direct contact and control of and be responsible for all employees under his/her supervision at all times. The procedure for a Contractor's employee to obtain Security Clearance is as follows. — a. Obtain fingerprint form from the Airport Administration. Provide data on the fingerprint form and take it to the Waterloo Police Department office in City Hall. Fingerprinting will be conducted by the Waterloo Police Department. Return the completed fingerprint form to the Airport Administration. The cost of fingerprinting at the Waterloo Police Department is$10.00 per person to be paid at time of fingerprinting. b. The completed fingerprint form that has been returned to the Airport Administration will be forwarded for a criminal background check. c. After the background check is completed, which takes approximately 7-10 days, Airport — Administration will issue approval notice of unescorted access to the airfield. d. Prior to access to the airfield, the person(s) are required to attend a Driver Training Program at the airport. This program takes approximately two (2) hours to complete. e. In addition to the cost of fingerprinting, a non-refundable payment in the amount of $100 is required for each Airport Security Clearance Request. This payment is due to the Waterloo Regional Airport when the completed fingerprint form is returned to Airport Administration. Each company or agency must provide the Airport Administration with a list of individuals who have or are requesting Airport Security Clearance. — SPECIAL PROVISIONS CSVI 91109AL0200 Terminal Bldg Carpet-Terminal Improvements — AECOM 60600098 CONTRACT NO.20601 SP-4 of 4 SECTION 09 68 00 CARPETING PART 1 GENERAL 1.1 REFERENCES The publications listed below form a part of this specification to the extent referenced. The publications are referred to within the text by the basic designation only. AMERICAN ASSOCIATION OF TEXTILE CHEMISTS AND COLORISTS (AATCC) AATCC 107 (2013) Colorfastness to Water AATCC 134 (2016) Electrostatic Propensity of Carpets AATCC 16 (2004; E 2008; E 2010) Colorfastness to Light AATCC 165 (2013) Colorfastness to Crocking: Textile Floor Coverings - Crockmeter Method AATCC 174 (2016) Antimicrobial Activity Assessment of New Carpets ASTM INTERNATIONAL (ASTM) -• ASTM D1335 (2017; E 2018) Standard Test Method for Tuft Bind of Pile Yarn Floor Coverings ASTM D2859 (2016) Standard Test Method for Ignition Characteristics of Finished Textile Floor Covering Materials ASTM D3278 (1996; R 2011) Flash Point of Liquids by Small Scale Closed-Cup Apparatus ASTM D5793 (2018) Standard Test Method for Binding Sites Per Unit Length or Width of Pile Yarn Floor Coverings ASTM D5848 (2010; E 2010) Mass Per Unit Area of Pile Yarn Floor Coverings ASTM D6859 (2011) Standard Test Method for Pile Thickness of Finished Level Pile Yarn Floor Coverings ASTM D7330 (2015) Standard Test Method for Assessment of Surface Appearance Change in Pile Floor Coverings Using Standard Reference Scales ASTM E648 (2017a) Standard Test Method for Critical Radiant Flux of Floor-Covering Systems Waterloo Regional Airport CSVI 9I190ALO200 CONTRACT NO. 20601 .. AECOM 60600098 SECTION 09 68 00 Page 1 1 Using a Radiant Heat Energy Source CALIFORNIA DEPARTMENT OF PUBLIC HEALTH (CDPH) CDPH SECTION 01350 (2010; Version 1.1) Standard Method for the Testing and Evaluation of Volatile Organic Chemical Emissions from Indoor Sources using Environmental Chambers CARPET AND RUG INSTITUTE (CRI) CRI 104 (2015) Carpet Installation Standard for Comnmercial Carpet CRI 105 (2015) Carpet Installation Standard for Residential Carpet CRI GLP QM (2017) Green Label Plus Quality Manual CRI Test Method 103 (2015) Standard Test Method for the L.. Evaluation of Texture Appearance Retention of Carpet Standards Program GREEN SEAL (GS) GS-36 (2013) Adhesives for Commercial Use INTERNATIONAL ORGANIZATION FOR STANDARDIZATION (ISO) ISO 2551 (1981) Machine-made Textile Floor Coverings - Determination of Dimensional Imam Changes Due to the Effects of Varied Water and Heat Conditions SCIENTIFIC CERTIFICATION SYSTEMS (SCS) SCS SCS Global Services (SCS) Indoor Advantage SOUTH COAST AIR QUALITY MANAGEMENT DISTRICT (SCAQMD) SCAQMD Rule 1113 (2016) Architectural Coatings SCAQMD Rule 1168 (2017) Adhesive and Sealant Applications U.S. NATIONAL ARCHIVES AND RECORDS ADMINISTRATION (NARA) 16 CFR 1630 Standard for the Surface Flammability of Carpets and Rugs (FF 1-70) UNDERWRITERS LABORATORIES (UL) UL 2818 (2013) GREENGUARD Certification Program For Chemical Emissions For Building Materials, Finishes And Furnishings 1.2 SUBMITTALS Owner approval is required for submittals Waterloo Regional Airport CSVI 9I190ALO200 CONTRACT NO. 20601 AECOM 60600098 SECTION 09 68 00 Page 2 SD-02 Shop Drawings Installation Drawings SD-03 Product Data Carpet Recycled Content for Carpeting; S IromN Moldings Indoor Air Quality for Aerosol Adhesives Indoor Air Quality for Non-Aerosol Adhesives Indoor Air Quality for Concrete Primer SD-04 Samples "1 Carpet Moldings SD-06 Test Reports Moisture and Alkalinity Tests SD-07 Certificates Indoor Air Quality for Carpet Indoor Air Quality for Fiber Cushion Indoor Air Quality for Rubber Cushion mal Indoor Air Quality for Polyurethane-Foam Cushion SD-08 Manufacturer's Instructions Surface Preparation SD-10 Operation and Maintenance Data Cleaning and Protection Maintenance Service SD-11 Closeout Submittals Warranty Waterloo Regional Airport CSVI 9I190ALO200 CONTRACT NO. 20601 AECOM 60600098 SECTION 09 68 00 Page 3 1.3 CERTIFICATIONS 1.3.1 Indoor Air Quality Certifications 1.3.1.1 Floor Covering Materials Provide carpet and cushion products certified to meet indoor air quality requirements by UL 2818 (GreenGuard) Gold, SCS Global Services Indoor Advantage Gold, CRI GLP QM or provide certification or validation by other ... third-party program that products meet the requirements of this Section. Provide current product certification documentation from certification body. When product does not have certification, provide validation that product meets the indoor air quality product requirements cited herein. L ' 1.4 DELIVERY, STORAGE, AND HANDLING i.. Deliver materials to the site in the manufacturer's original wrappings and packages clearly labeled with the manufacturer's name, brand name, size, dye lot number, and related information. Remove materials from packaging and store them in a clean, dry, well ventilated area protected from damage, soiling, and moisture, and maintain at a temperature above 60 degrees F for 2 days prior to installation. Do not store carpet near materials that may off gas or emit harmful fumes, such as kerosene heaters, fresh paint, or adhesives. 1.5 AMBIENT CONDITIONS Maintain areas in which carpeting is to be installed at a temperature above 60 degrees F and below 90 degrees F for 2 days before installation, during installation, and for 2 days after installation. Provide temporary ventilation during work of this section. Maintain a minimum temperature of 55 degrees F thereafter for the duration of the contract. 1.6 WARRANTY Provide manufacturer's standard performance guarantees or warranties including minimum ten year wear warranty, two year material and workmanship and ten year tuft bind and delamination. PART 2 PRODUCTS 2 .1 CARPET Furnish first quality carpet that is free of visual blemishes, streaks, poorly dyed areas, fuzzing of pile yarn, spots or stains, and other physical and manufacturing defects. Provide carpet materials and treatments as reasonably nonallergenic and free of other recognized health hazards. Provide a static control construction on all grade carpets which gives adequate durability and performance. Submit manufacturer's catalog amp data and printed documentation stating physical characteristics, durability, resistance to fading, and flame resistance characteristics for each type of carpet material and installation accessory. Submit manufacturer's Product Data for 1) Carpet, 2) Moldings, and 3) Carpet — Cushion. Also, submit Samples of the following: a. Carpet: Two "Production Quality" samples 18 by 18 inches of each carpet proposed for use, showing quality, pattern, and color specified — b. Moldings: Two samples of each type minimum 12 inches long Waterloo Regional Airport CSVI 9I190ALO200 CONTRACT NO. 20601 AECOM 60600098 SECTION 09 68 00 Page 4 2.1.1 Recycled Content Carpeting must contain a minimum of 20 percent recycled content. Provide data identifying percentage of recycled content for carpeting. Provide certification of indoor air quality for carpet. 2.1.2 Indoor Air Quality Requirements Products must meet emissions requirements of CDPH SECTION 01350. Provide certification or validation of indoor air quality for carpet. 2 .1.3 Physical Characteristics for Modular Tile Carpet 2 . 1 .3 .1 Carpet Construction Tufted 2 .1 .3 .2 Type Modular tile 24 by 24inch square with 0.15 percent growth/shrink rate in accordance with ISO 2551. 2 .1 .3 .3 Pile Type Level-loopor Multilevel loop 2.1.3 .4 Pile Fiber Commercial 100 percent branded (federally registered trademark) nylon continuous filament. 2 .1 .3 .5 Gauge or Pitch Minimum 5/64 inch in accordance with ASTM D5793 2 . 1 .3 .6 Stitches or Rows/Wires Minimum 10. 00 per square inch 2 .1.3 .7 Surface Pile Weight Minimum 20 ounces per square yard. This does not include weight of backings. Determine weight in accordance with ASTM D5848. 2.1.3.8 Pile Thickness .1 Minimum 0.113 inch in accordance with ASTM D6859 2.1.3.9 Dye Method Solution dyed 2.1.3 .10 Backing Materials Provide primary backing materials like those customarily used and accepted by the trade for each type of carpet. Provide secondary backing to suit project requirements of those customarily used and accepted by the trade Waterloo Regional Airport CSVI 9I190ALO200 CONTRACT NO. 20601 AECOM 60600098 SECTION 09 68 00 Page 5 1 for each type of carpet. 2.2 PERFORMANCE REQUIREMENTS 2.2.1 Texture Appearance Retention Rating (TARR) V Provide carpet with a greater than or equal to 3.5 (Severe) TARR traffic level classification in accordance with ASTM D7330 or CRI Test Method 103 . 2 .2 .2 Static Control Provide static control to permanently regulate static buildup to less than 3 .5 kV when tested at 20 percent relative humidity and 70 degrees F in accordance with AATCC 134. 2 .2 .3 Flammability and Critical Radiant Flux Requirements Comply with 16 CFR 1630 or ASTM D2859. Provide carpet in corridors and exits with a minimum average critical radiant flux of 0.45 watts per square centimeter when tested in accordance with ASTM E648. — 2.2 .4 Tuft Bind Comply with ASTM D1335 for tuft bind force required to pull a tuft or loop free from carpet backing with a minimum 8 pound average force for modular carpet tile. 2 .2 .5 Colorfastness to Crocking Comply dry and wet crocking with AATCC 165 and with a Class 4 minimum rating on the AATCC Color Transference Chart for all colors. ._ 2 .2 .6 Colorfastness to Light Comply colorfastness to light with AATCC 16, Test Option E "Water-Cooled L.. Xenon-Arc Lamp, Continuous Light" and with a minimum 4 grey scale rating after 40 hours. L 2.2.7 Colorfastness to Water Comply colorfastness to water with AATCC 107 and with a minimum 4.0 gray scale rating and a minimum 4.0 transfer scale rating. 2.2.8 Delamination Strength Provide delamination strength for tufted carpet with a secondary back of minimum 2.5 lbs/inch. 2.2.9 Antimicrobial Nontoxic antimicrobial treatment in accordance with AATCC 174 Part I (qualitative) , guaranteed by the carpet manufacturer to last the life of the carpet. 2.3 ADHESIVES AND CONCRETE PRIMER Comply with applicable regulations regarding toxic and hazardous ■- materials. Provide water resistant, mildew resistant, nonflammable, and nonstaining adhesives and concrete primers for carpet installation as Waterloo Regional Airport CSVI 9I190ALO200 CONTRACT NO. 20601 AECOM 60600098 SECTION 09 68 00 Page 6 required by the carpet manufacturer. Provide release adhesive for modular tile carpet as recommended by the carpet manufacturer. Provide adhesives flashpoint of minimum 140 degrees F in accordance with ASTM D3278. Non-aerosol adhesive products used on the interior of the building (defined as inside of the weatherproofing system) must meet either emissions requirements of CDPH SECTION 01350 (limit requirements for either office or classroom spaces regardless of space type) or VOC content requirements of SCAQMD Rule 1168. Aerosol adhesive products used on the interior of the building (defined as inside of the weatherproofing system) must meet either emissions requirements of CDPH SECTION 01350 (limit requirements for either office or classroom spaces regardless of space type) or VOC content requirements of GS-36. Provide validation of indoor air quality for aerosol adhesives. Provide validation of indoor air quality for non-aerosol adhesives. Concrete primer products used on the interior of the building (defined as inside of the weatherproofing system) must meet either emissions requirements of CDPH SECTION 01350 (limit requirements for either office or classroom spaces regardless of space type) or VOC content requirements of SCAQMD Rule 1113. Provide validation of indoor air quality for concrete primer. 2 .4 MOLDINGS Provide carpet moldings where floor covering material changes or carpet edge does not abut a vertical surface. Provide a heavy-duty vinyl molding designed for the type of carpet being installed. Provide color to match resilient base. 2.5 COLOR, TEXTURE, AND PATTERN Provide color, texture, and pattern in accordance with the drawings. PART 3 EXECUTION 3 .1 SURFACE PREPARATION Do not install carpet on surfaces that are unsuitable and will prevent a proper installation. Prepare subfloor in accordance with flooring manufacturer's recommended instructions. Repair holes, cracks, depressions, or rough areas using material recommended by the carpet or adhesive manufacturer. Free floor of any foreign materials and sweep clean. Before beginning work, test subfloor with glue and carpet to determine "open time" and bond. Submit three copies of the manufacturer's printed Installation instructions for the carpet, including Surface Preparation, seaming techniques, and recommended adhesives and tapes. 3.2 MOISTURE AND ALKALINITY TESTS Test concrete slab for moisture content and excessive alkalinity in accordance with CRI 104/CRI 105. Submit three copies of reports of Moisture and Alkalinity Tests including content of concrete slab stating date of test, person conducting the test, and the area tested. 3 .3 PREPARATION OF CONCRETE SUBFLOOR Do not commence installation of the carpeting until concrete substrate is at least 90 days old. Prepare the concrete surfaces in accordance with the carpet manufacturer's instructions. Match carpet, when required, and adhesives to prevent off-gassing to a type of curing compounds, leveling agents, and concrete sealer. Waterloo Regional Airport CSVI 9I190ALO200 CONTRACT NO. 20601 1 AECOM 60600098 SECTION 09 68 00 Page 7 lom 3 .4 INSTALLATION Perform all work by manufacturer's approved installers. Conduct installation in accordance with the manufacturer's printed instructions and CRI 104/CRI 105. Protect edges of carpet meeting hard surface flooring with molding and install in accordance with the molding manufacturer's printed instructions. Follow ventilation, personal protection, and other safety precautions recommended by the adhesive manufacturer. Continue ventilation during installation and for at least 72 hours following installation. Do not permit traffic or movement of furniture or equipment in carpeted area for 24 hours after installation. Complete other work which would damage the carpet prior to installation of carpet. Submit three copies of Installation Drawings for 1) Carpet, 2) Carpet Cushion, and 3) Moldings indicating areas receiving carpet, carpet types, patterns, direction of pile, location of seams, and locations of edge molding. Do not install building construction materials that show visual evidence of biological growth. 3.4.1 Modular Tile Installation Install modular tiles with releasable 1/4 turn installation method. Comply L. with manufacturer installation instructions for required drying time of releasable adhesive so it sets up properly. Provide accessibility to the subfloor where required. Carpet tile on stairs and sloped surfaces must be installed with a more permanent installation method in accordance with the manufacturer's instructions and with manufacturer recommended adhesives for ... this application. 3.4.2 Entrance Carpet Installation Install tiles withreleasable adhesive and snug joints. Use 1/4 turn installation method. 3.5 CLEANING AND PROTECTION Submit three copies of carpet manufacturer's maintenance instructions describing recommended type of cleaning equipment and material, spotting and cleaning methods, and cleaning cycles. 3 .5.1 Cleaning After installation of the carpet, remove debris, scraps, and other foreign matter. Remove soiled spots and adhesive from the face of the carpet with appropriate spot remover. Cut off and remove protruding face yarn. Vacuum carpet clean. 3 .5.2 Protection L. Protect the installed carpet from soiling and damage with heavy, reinforced, nonstaining kraft paper, plywood, or hardboard sheets. Lap and secure edges of kraft paper protection to provide a continuous cover. L. Restrict traffic for at least 48 hours. Remove protective covering when directed by the Contracting Officer. Waterloo Regional Airport CSVI 9I190ALO200 CONTRACT NO. 20601 AECOM 60600098 SECTION 09 68 00 Page 8 3 .6 MAINTENANCE 3.6.1 Extra Materials Provide extra material from same dye lot consisting of uncut carpet tiles for future maintenance. Provide a minimum of three percent of total square yards of each carpet type, pattern, and color. -- End of Section -- Waterloo Regional Airport CSVI 9I190AL0200 CONTRACT NO. 20601 AECOM 60600098 SECTION 09 68 00 Page 9 .11.mr 11•=. Wm. Ulm linmr I•m• mom. • ••••• GENERAL SPECIFICATIONS FOR CONSTRUCTION CITY OF WATERLOO, IOWA Department of Engineering SECTION A - Definitions of Terms SECTION B -Scope of work SECTION C -Control of Materials and Work SECTION D - Procedure and Progress SECTION E - Measurements and Payments SECTION F - Legal Relations and Responsibility SECTION A- DEFINITIONS OF TERMS 1. CITY. The City of Waterloo, Iowa, which is the Party of the First Part of the accompanying contract, acting through its authorized representative. 2. COUNCIL. The duly elected Council of the City of Waterloo, Iowa. 3. ENGINEER. The City Engineer of Waterloo, Iowa, or his authorized representative. 4. INSPECTOR. The authorized representative of the Engineer, assigned to the detailed inspection of the work or materials therefor and to such other duties as may be delegated to him in these specifications. 5. CONTRACTOR. The Party of the Second Part in the accompanying contract for the improvement covered by these specifications, or his authorized representative. 6. SUBCONTRACTOR. Any person, firm, or corporation who has, with the approval of the Council, contracted with the Contractor to execute and perform in his stead all or any part of the contract. 7. BIDDER. Any individual, firm, or corporation submitting a proposal for all or a part of the work provided for in these specifications. 8. PROPOSAL GUARANTEE. The security designed in the Notice of Bidders or Proposal to be furnished by the bidder as a guarantee of good faith to enter into a contract and furnish an acceptable bond for the work contemplated if it be awarded him. 9. SURETY. The corporate body bound with and for the Contractor for the acceptable performance of the contract. 10. PROPOSAL. The written Proposal, submitted by the bidder in the prescribed manner and on the standard form, for the improvements covered by these specifications. 11. SPECIFICATIONS. The documents that set forth the manner in which the proposed work is to be accomplished which have been prepared by the Engineer and approved by the City Council, -- official copies of which are now on file with the City Clerk. 12. SPECIAL PROVISIONS. Clauses or memoranda not contained herein, applying to the contract of which these specifications are a part, which change or supplement these specifications. 13. CONTRACT. The agreement entered into between the City and the Contractor, setting forth the terms under which the work covered by the plans and specifications is to be performed. The contract includes all conditions, definitions, and instructions set forth in the official publications relating to GENERAL SPECS CSVI 91109AL0200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 GS-1 of 13 the work, the official contract and specifications, the Proposal, official plans, and all supplemental agreements entered into by the parties to the contract. 14. NOTICE TO BIDDERS. The notice called attention of bidders to the time and place for receiving bids, containing a brief description of the work, and briefly setting forth the requirements and — conditions for submission of Proposals. 15. INSTRUCTIONS TO BIDDERS. The clauses setting forth in detail the information relative to the proposed work and requirements for the submission of Proposals. 16. PLANS. The plans for the improvement covered by the specifications and approved by the Council, official copies of which are on file with the City Clerk. 17. CONTRACT BOND. The bond executed by the Contractor and his surety in favor of the City of Waterloo, Iowa, guaranteeing the complete execution of the contract in accordance with the plans and specifications, the payment of all debts pertaining to the work, and maintenance of the work as provided by law or by the specifications. 18. CONTRACT PERIOD. The period from the specified date for beginning the work to the _ specified date of completion, both dates inclusive. The contract period may be extended by the Council, as provided in these specifications, in which event the contract period includes the new date of completion. 19. OFFICIAL PUBLICATIONS. The official publications are the formal resolutions and notices relative to the proposed improvement that are required by law to be published in a prescribed manner and that have actually been published in accordance with the statutes relating thereto. Attention is directed to the fact that these official publications are by statute vested with all of the force and effect of contract obligations. 20. A.S.T.M. Abbreviation for American Society for Testing Materials. '— 21. WORK. The term "Work" of the Contractor and Subcontractor includes labor or materials or both, equipment, transportation, or other facilities necessary to complete the contract. _ 22. TIME. All time limits stated in the contract documents are of the essence in the contract. SECTION B -SCOPE OF WORK 1. CORRELATION AND INTENT OF DOCUMENTS. The Contract documents are complementary, and what is called for by any one shall be as binding as if called for by all. The intention _ of the documents is to include all labor, materials, equipment, and transportation necessary for the proper execution of the work. Materials or work described in words which, so applied, have a well-known technical or trade meaning shall be held to refer to such recognized standard. 2. DRAWINGS AND SPECIFICATIONS. Unless otherwise provided in the contract documents, the engineer shall furnish to the Contractor, free of charge, all copies of drawings and specifications reasonably necessary for the execution of the work. _ The Contractor shall keep one (1) copy of all drawings and specifications on the work available to the Engineer and to his representatives. 3. CONTRACTOR'S UNDERSTANDING. It is understood and agreed that the Contractor has, by careful examination, satisfied himself as to the nature, character and location of the work, the conformance to the ground, the character, quality, and quantity of the materials to be encountered, the character of the equipment and facilities needed preliminary to and during the prosecution of the work, the general and local conditions, and all other matters which can, in any way, affect the work under this GENERAL SPECS CSVI 91109AL0200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 GS-2 of 13 contract. No verbal agreement or conversation with any officer, agent, or employee of the City, either before or after the execution of the Contract, shall affect or modify any of the terms or obligations herein — contained. 4. REPORTING ERRORS AND DISCREPANCIES. If the Contractor, in the course of the work, finds any discrepancies between the plans and the physical conditions of the locality, or any errors of omission in plans or in the layout as given by said stakes and instructions, it shall be his duty to inform the Engineer immediately, in writing, and the Engineer shall promptly correct the same. 5. ALTERATION OR CORRECTION OF PLANS. The plans are made up from surveys that are presumably correct and represent the foreseen construction requirements. Any modification of the plans which may be required by the exigencies of the construction or any corrections made necessary because of errors in the original surveys, will be made by the Engineer. Should corrections or modifications of the plans or specifications require a different quality or class of work than that upon which the unit prices in the Proposal are based, or if the modifications or corrections are required in parts of the work partially completed and such modifications result in an increased cost to the Contractor, the amount to be paid for work resulting from such changes shall be agreed upon in writing at the time the changes are ordered and before the work is begun by the Contractor. No allowance will be made for anticipated profits on work not performed. 6. CHANGES IN THE WORK. The City, without invalidating the contract, may order extra work or make changes by altering, adding to, or deducting from the work, the contract sum being adjusted by agreement or arbitration before such changed work is undertaken. All such work shall be executed under the conditions of the original contract, except that any claim for extension of time caused thereby shall be adjusted at the time of ordering such change. 7. INCREASED OR DECREASED QUANTITIES. The right is reserved without impairing the contract, to order the performance of such work of a class not contemplated in the Proposal or to increase or decrease the quantities as may be considered necessary to complete fully and satisfactorily the work included in the contract. However, when the work is completed without change in the plans, and the measured quantity of any item of work varies by more than twenty percent (20%) from the estimated quantity specified in the contract, an adjustment in price may be made for such item of work by agreement between the Engineer and the Contractor, subject to the approval of the City Council. Either party to the contract may request such an adjustment. 8. LANDS AND RIGHT OF WAY. The City shall provide the lands upon which the work under this contract is to be done, except that the Contractor shall provide land required for the erection of temporary construction facilities and storage of his material, together with the right of access to same. 9. CITY WATER. The Contractor shall be allowed to use City Water but before any water is used, he shall make application to the Waterloo Water Works for a temporary water connection from a fire hydrant or by some other connection method. Water usage will be charged at the rate for temporary water service. The rules, regulations, and water rates are available at the Waterloo Water Works offices at 325 Sycamore Street or their telephone number is 319-232-6280. 10. RIGHTS OF VARIOUS INTERESTS. Whenever work being done by the City's forces or by other Contractors is contiguous to work covered by this contract, the respective rights of the various interests involved shall be established by the Engineer to secure the completion of the various portions of -- the work in general harmony. 11. CLOSING STREETS TO TRAFFIC. The Engineer shall be the judge of how many streets or parts of streets it is necessary for the Contractor to close at any time and may refuse to permit the closing of additional streets until such of the work is finished and opened to traffic as he may direct. 12. OBSTRUCTION OF STREETS. The work is to be carried on in such manner as to obstruct the streets, highways, and alleys as little as possible. The Contractor shall carry on the different -- GENERAL SPECS CSVI 91109AL0200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 GS-3 of 13 parts of the work so as to complete the whole, as nearly as practicable, at the same time. In doing the work, the Contractor shall follow the directions of the Engineer as to the place or places where work shall —" be started or be carried on and the direction in which it shall be done. 13. SHANTIES AND BUILDINGS. Shanties or other buildings shall not be erected in or upon any street, highway, or alley without permission of the Engineer. If such permission be granted, it may be upon any reasonable terms prescribed by the person or body granting such permission. 14. SANITARY CONVENIENCES. The Contractor shall furnish the necessary sanitary conveniences, properly secluded, for the laborers on the work, and these shall be maintained in a manner that will be inoffensive to the public. 15. CLEANING UP. The Contractor shall, as directed by the Engineer, remove from the City's property and from all public and private property, at his own expense, all temporary structures, rubbish, and waste materials resulting from his operations before work can be considered completed. The Contractor shall also renew or replace any and all fences, sidewalks, or other property damaged or — disturbed by his work. 16. OMISSION OF PARTS OF GENERAL SPECIFICATIONS. Parts of the General _ Specifications deemed not to apply to some particular work may be omitted by special reference in other parts of the contract documents. SECTION C -CONTROL OF MATERIALS AND WORK -- 1. SUPERVISION AND INSPECTION. The Engineer shall have supervision of the construction provided for in this Contract and shall decide any and all questions which may arise as to the _ quality and acceptability of materials furnished, work performed, manner of performance, rate of progress on the work, and all questions regarding the acceptable fulfillment of the terms of the Contract. Materials and construction work shall, at all times, be subject to the inspection of the Engineer or his representatives. The Contractor shall be held strictly to the true intent of these specifications as regards the quality of materials, workmanship, and the diligent prosecution of the work. The Engineer and his representatives shall, at all times, have access to the work wherever it is in _ preparation of progress, and the Contractor shall provide proper facilities for such access and for inspection. If the specifications, the Engineer's instructions, law ordinances, or any public authority require any work and/or materials to be especially tested or approved, the Contractor shall give the Engineer timely notice of readiness for inspection. If the inspection is to be made by authority other than the Engineer, the Contractor shall notify the engineer of the date fixed for inspection. Inspections by the Engineer will be promptly made and, where practicable, at the source of supply. If any work should be covered up without the approval or consent of the Engineer, it must, if required by the Engineer, be uncovered for examination at the Contractor's expense. Re-examination of questioned work may be ordered by the Engineer, and, if so ordered, the work must be uncovered by the Contractor. If such work be found in accordance with the Contract, the City shall pay the cost of re-examination and replacement. If such work be found not in accordance with the Contract, the Contractor shall pay such cost unless he shall show that the defect in the work was caused by another Contractor, and, in that event, the City shall pay the cost. 2. AUTHORITIES AND DUTIES OF INSPECTORS. Inspectors may be stationed on the — work to report to the Engineer as to the progress of the work and the manner in which it is being performed; also, to report whenever it appears that materials furnished and work performed by the Contractor fail to fulfill the requirements of the specifications and Contract, and to direct the attention of the Contractor to such failure or infringement; but such inspection shall not relieve the Contractor from GENERAL SPECS CSVI 91109AL0200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 GS-4 of 13 any obligations to furnish acceptable materials or to provide completed construction that is satisfactory in every particular. In case of any dispute arising between the Inspector and the Contractor as to materials furnished or the manner of performing the work, the Inspector shall have the authority to reject materials or suspend the work until the question at issue can be referred to and decided by the Engineer. Inspectors are not authorized to revoke, alter, enlarge, relax, or release any requirements of these specifications. The Inspector shall, in no case, act as foreman or perform other duties for the Contractor, or interfere with the management of the work by the latter. 3. STATUS OF THE ENGINEER. The Engineer shall have general supervision and direction of the work. He has authority to stop the work whenever such stoppage may be necessary to insure the proper execution of the Contract. He shall also have authority to reject any work and/or materials which do not conform to the specifications, to direct the application of forces to any portion of the work as, in his judgment, is required, and to order the force increased or diminished, and to decide questions which arise in the execution of the work. 4. ENGINEER'S DECISIONS. The Engineer shall, within a reasonable time, make decisions on all claims of the Contractor and on all other matters relating to the execution and progress of the work or the interpretation of the contract documents. All such decisions of the Engineer shall be final except as to the element of time and financial consideration involved, which, if no agreement in regard thereto is reached, shall be subject to arbitration. 5. STAKES AND INSTRUCTIONS. The Contractor shall provide reasonable and necessary opportunities and facilities for setting stakes and making measurements. The Contractor shall not furnish stakes or men to set them. He shall not proceed until he has received from the Engineer such stakes and instructions as may be necessary to the progress of the work. The Contractor shall carefully preserve bench marks, reference points, and stakes, and in case of willful or careless destruction, he shall be charged with the resulting extra expense and shall be responsible for any mistakes that may be caused, by their loss or disturbance. 6. SUPERINTENDENCE. The Contractor shall keep on his work during its progress a competent superintendent and any necessary assistants, all satisfactory to the Engineer. The Superintendent shall not be changed except with the consent of the Engineer, unless the Superintendent proves to be unsatisfactory to the Contractor and ceases to be in his employ. The Superintendent shall represent the Contractor in his absence, and all directions given to him shall be as binding as if given to the Contractor. Important decisions shall be confirmed in writing to the Contractor. Other directions shall be so confirmed on written request in each case. The Contractor shall give efficient supervision to the work using his best skill and attention. He shall carefully study and compare all drawings, specifications, and other instructions, and shall report at once to the Engineer any error, inconsistency, or omission which he may discover. 7. REMOVAL OF UNAUTHORIZED WORK. Work done without lines and grade being give, work done beyond lines shown on the plans or as given, except as herein provided, or any extra or additional work done without authority, will be considered as unauthorized and at the expense of the -- Contractor and will not be paid for under the provisions of the Contract. Work so done may be ordered removed and replaced at the Contractor's expense. 8. REMOVAL OF DEFECTIVE MATERIALS OR WORK. The Contractor shall promptly remove from the premises all materials condemned by the engineer as failing to conform to the Contract; whether incorporated in the work or not, and the Contractor shall promptly replace and re-execute his own work in accordance with the contract and without expense to the City, and shall bear the expense of making good all work of other Contractors destroyed or damaged by such removal or replacement. �— GENERAL SPECS CSVI 91109AL0200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 GS-5 of 13 If the Contractor does not remove such condemned work and materials within a reasonable time, — fixed by written notice, the City may remove them and may store the material at the expense of the Contractor. If the Contractor does not pay the expense of such removal within a reasonable time thereafter, the City may, upon ten (10) days' written notice, sell such materials at auction or at private sale ... and shall account for the net proceeds thereof, after deducting all the costs and expense that should have been borne by the Contractor; or, if the net proceeds of such sale are insufficient to pay the expenses of removal, the City may deduct the balance from any amounts due the Contractor. 9. MATERIALS, EQUIPMENT, APPLIANCES, AND FACILITIES. Unless otherwise stipulated, the Contractor shall provide and pay for all materials, labor, water, tools, equipment, light, power, transportation, and other facilities necessary for the execution and completion of the work. Materials shall be of the quality specified for each particular part of the work. Whenever, in construction of the work or in the manufacture of any article of appliance necessary for the construction or operation of the work, it is necessary to use any material that is not fully specified in these specifications, it shall be of good quality and shall meet with the approval of the Engineer. Any appliance that is necessary for the construction or operation of the work and is commonly _ recognized as a part of the work, shall be furnished by the Contractor as part of the work, whether or not it is specifically called for in the plans and specifications, and such appliance shall be of good quality and standard make and shall meet with the approval of the Engineer. 10. MATERIAL SAMPLES. Before the contract is awarded, the bidder may be required to furnish a statement of the origin, composition, and manufacture of any and all materials proposed for use in the performance of the Contract, together with samples of the material. These samples will be _ considered as representative and typical of the material to be obtained from any particular source. 11. CHARACTER OF WORKMEN AND EQUIPMENT. The Contractor shall employ competent and efficient workmen for every kind of work. Any person employed on the work who shall — refuse or neglect to obey the directions of the engineer or Inspector, or who shall be deemed incompetent or disorderly, or who shall commit trespass upon public or private property in the vicinity of the work, shall be dismissed when the Engineer so orders, and shall not be re-employed unless express permission be — given by the Engineer. The Contractor shall, at all times, enforce discipline and good order among his employees. The methods, equipment, and appliances used on the work, and the labor employed, shall be such as will produce a satisfactory quality of work and shall be adequate to complete the contract within the specified time limit. 12. HIRING CITY EMPLOYEES. The Contractor shall not employ and hire any of the City's employees without the permission of the Engineer. 13. LABOR. Local labor shall be given preferences so far as practicable. — 14. THE CITY'S RIGHT TO DO WORK. If the Contractor should neglect to prosecute the work properly or fail to perform any provision of this Contract, the City of Waterloo, after three (3) days' written notice to the Contractor may, without prejudice to any other remedy he may have, make good such deficiencies and may deduct the cost thereof from the payment then or thereafter due the Contractor, provided, however, that the Engineer shall approve both such action and the amount charged to the Contractor. — GENERAL SPECS CSVI 91109AL0200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 GS-6 of 13 SECTION D - PROCEDURE AND PROGRESS _ 1. ORDER OF COMPLETION - USE OF COMPLETED PORTIONS. The Contractor shall complete any portion or portions of the work in such order or time as the Engineer may require. The City shall have the right to take possession of an use completed or partially completed portion of the work at any time, but such taking possession and use shall not be deemed an acceptance of work so taken or used, or any part thereof. If such prior use increases the cost of or delays the work, the Contractor shall be entitled to such extra compensation or extension of time, or both, as the Engineer may determine. 2. WEATHER. During stormy or inclement weather, all work shall be suspended, except such as can be done in an acceptable manner. Permission to work during freezing, stormy, or inclement weather shall in no way be construed as a release of the Contractor's responsibility regarding the quality of the finished work at such time. 3. SUNDAYS AND LEGAL HOLIDAYS. Except for such work as may be required to properly maintain or protect completed or partially completed construction or to maintain lights and barricades, no work will be permitted on Sundays or legal holidays without specific permission of the Engineer. 4. DELAYS AND EXTENSION OF TIME. If the Contractor be delayed in the completion of the work by an act of neglect of the City, or its employees; or by any other Contractor employed by the City; or by changes ordered in the work; or by strikes, lockouts, fire, unusual delays in transportation, unavoidable casualties, or any cause beyond the Contractor's control; or by delay authorized by the Engineer pending arbitration; or by any cause which the Engineer shall decide justifies the delay, then the time of completion shall be extended for such reasonable time as the Engineer may decide will compensate for such delay. No such extension shall be made for delay occurring more than thirty (30) days before claim therefor is made in writing to the Engineer. In the case of a continuing cause of delay, only one claim is necessary. This article does not exclude the recovery of damages for delay by either party under provisions in the contract documents. 5. TEMPORARY SUSPENSION OF WORK. The Engineer shall have authority to suspend the work, wholly or in part, for such period or periods of time as he may deem necessary, due to unsuitable weather or such other conditions as are considered unfavorable for the suitable prosecution of the work, or for such time as is necessary due to the failure to the Contractor to carry out orders given or to perform any or all provisions of the Contract. 6. NOTICES - HOW SERVED. Any notice to be given by the City to the Contractor under this contract shall be deemed to be served if the same be delivered to the man in charge of any office used by the Contractor or his foreman or agent at or near the work, or deposited in the post office, postpaid, addressed to the Contractor at his last known place of business. 7. PROGRESS OF WORK. The progress of the work shall be such that, at the expiration of one-fourth (1/4) of the contract period, one-eighth (1/8) of the work shall be completed; at the expiration of one-half (1/2) of the contract period, three-eighths (3/8) of the work shall be completed; at the expiration -. of three-fourths (3/4) of the contract period, the work shall be three-fourths (3/4) completed, and the whole work shall be completed at the expiration of the contract period. If, at any time the above schedule is not being maintained, the Council may give written notice to the Contractor and his sureties that the specifications are not being complied with. Such notice shall state what action on the part of the Contractor is required to bring the work within the requirements of the specifications. If the Contractor fails, within ten (10) days, to proceed as directed in the said notice, then the Council shall have authority to annul this contract without process or action at law and take over the GENERAL SPECS CSVI 91109AL0200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 GS-7 of 13 prosecution and completion of the work, as provided under the article covering City's right to terminate contract. 8. CITY'S RIGHT TO TERMINATE CONTRACT. If the Contractor should be adjudged a bankrupt; or if he should make a general assignment for the benefit of this creditor; or if a Receiver should _. be appointed on account of his insolvency; or if he should persistently or repeatedly refuse or should fail, except in cases for which extension of time is provided, to supply enough skilled workmen or proper materials; or if he should fail to make prompt payment to Subcontractors or for materials or labor; or if he should persistently disregard laws, ordinances, or the instructions of the Engineer; or if he should —' otherwise be guilty of a substantial violation of any provision of the contract, then the City, upon the certificate of the Engineer that sufficient cause exists to justify such action, may, without prejudice to any other rights or remedy, and after giving the Contractor seven (7) days' written notice, terminate the employment of the Contractor and take possession of the premises and of all materials, tools and appliances thereon and finish the work by whatever method he may deem expedient. In such cases, the Contractor shall not be entitled to receive any further payment until the work is finished. If the unpaid balance of the contract price shall exceed the expenses of finishing the work, including compensation for additional managerial and administration services, such excess shall be paid to the Contractor. If such expense shall exceed such unpaid balance, the Contractor shall pay the _ difference to the City. The expense incurred by the City as herein provided and the damage incurred through the Contractor's default shall be certified by the Engineer. 9. REMOVAL OF EQUIPMENT. In the case of annulment of this contract before completion, from any cause whatsoever, the Contractor, if notified to do so by the City; shall promptly remove any part or all of his equipment and supplies from the property of the City, failing which, the City shall have the right to remove such equipment and supplies at the expense of the Contractor. SECTION E - MEASUREMENTS AND PAYMENT 1. STANDARD OF MEASUREMENT. All work completed under the contract shall be measured by the Engineer according to the United States standard measures. 2. SCOPE OF PAYMENTS. The Engineer's measurements of quantities shall be the basis for final payment for the work performed under this Contract. After the work is completed, the Engineer will make measurements and computations of the number of units of each of the various items of work completed, and the Contractor will be paid for the actual amount of work performed at the rates specified in his Proposal. Before final settlement is made, the Council may require the Contractor to submit a list of all persons furnishing labor or materials, with evidence that such persons have been paid in full. Payment shall be made in the manner set forth in official publications and Council Proceedings relative thereto. 3. PAYMENT FOR EXTRA WORK. Such extra work as may have been ordered by the Engineer and performed by the Contractor shall be compensated for as provided herein. If work is to be done or materials are to be furnished by the Contractor which cannot properly be classified under unit prices included in the Proposal, the Contractor shall be paid therefor the actual reasonable cost of the — labor and materials entering permanently in such work, plus fifteen percent (15%) of the cost thereof. In computing the labor cost on such extra work, the following items shall be included: (a) Actual payroll expenditures for labor at the current rate therefor, and cost of materials. (b) Pay of foreman and timekeepers for actual time required on the extra work. (c) Liability insurance, prorated, for the extra work. Labor cost items on extra work shall be furnished in duplicate by the Contractor to the Inspector daily. The Inspector shall check the items, and if he finds them to be correct, he shall so certify on the statement of cost, returning one copy to the Contractor and filing one copy with the Engineer. GENERAL SPECS CSVI 91109AL0200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 GS-8 of 13 The Engineer shall determine the cost of materials entering into extra work from the materials and receipted freight bills for the same. For any special machine, power tools, or equipment, including fuel and lubricants, but not including small hand tools, which may be deemed necessary or desirable to use, the Contractor shall be -- allowed a reasonable rental thereon, to be agreed upon in writing by the Engineer before such work is begun, and to which sum no percentage is to be added. The item of cost shall not include repairs or replacement of equipment or overhead expenses of any character. The fifteen percent (15%) allowed is considered to cover the use of hand tools and all overhead expenses except liability insurance. In no case will a claim for extra compensation be allowed unless the work upon which the claim is based has been ordered in writing, except as provided hereinafter. 4. CLAIMS FOR EXTRA COST. If the Contractor claims that any instructions, by drawings or otherwise, involved extra cost under this contract, he shall give the Engineer written notice thereof within ten (10) days after completion of the work. No such claim shall be valid unless so made. 5. CLAIMS FOR EXTRA COMPENSATION. If the Contractor deems that extra compensation is due him for work and/or materials that he considered is not clearly covered in the items for which he submitted unit prices in his bid and that were not ordered in writing by the Engineer as an extra s heretofore provided, the Contractor shall notify the Engineer, in writing, of his intention to make claim for extra compensation for work and/or material before starting construction. If such written notification is not given or the Engineer is not afforded proper facilities by the Contractor for keeping strict account of actual cost as defined herein, then the Contractor hereby agrees to waive the claim for extra compensation. Such notice to the engineer and the fact that the Engineer has kept account of cost as aforesaid, shall not in any way be construed as proving the validity of the claim, which must be passed upon by the Council. In the event that the Council finds the claim to be just, it shall be allowed and paid for as extra work as provided herein. 6. COMPLETION REPORT AND OBJECTIONS THERETO. Within ten (10) days after the full completion of the work to be done under this contract, the Engineer shall make a written statement of all the work done by the Contractor hereunder, stating the quantity of each item as found by him and including a statement of all credits for extra work and all credits or debits for changes, alterations, omissions, and defects, and shall forthwith deliver a copy of such statement to the Contractor. The Contractor shall compare such statement with his own records and shall then, in writing, either approve such statement or point out any claimed errors or omissions. If any of such claims are found correct, the -- Engineer shall, within ten (10) days, prepare a new statement, a copy of which shall in like manner be delivered unto the Contractor. The Engineer will not file a formal completion report with the City until the Contractor has approved the same. If the figures of the Engineer and the Contractor cannot be reconciled, or there is a difference of opinion regarding some item or items, then such difference of opinion shall be submitted to arbitration as hereinafter provided, and the decision of the arbitrator or arbitrators shall be final, and the Engineer shall, within a period of five (5) days, file his completion report. Before action by the City Council upon such completion report, the Contractor shall also file a written statement of any claims he may have against the City, other than those shown by such completion report, growing out of this contract or the work done hereunder. The City shall retain ten percent(10%) of the amount due the Contractor on the completion report for a period of thirty (30) days. If no claims are filed against the Contractor within thirty (30) days, the final ten percent (10%) shall then be paid to the Contractor. -- GENERAL SPECS CSVI 91109AL0200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 GS-9 of 13 7. WAIVER. By the execution of this contract ,the Contractor agrees that any objections he may have to the statement of the amount of work done hereunder included by the Engineer in this completion report, and any claims of the Contractor against the City growing out of this contract and the work done hereunder which are not stated in writing in the manner and within the time provided in Article _. 6, Section E hereof, shall be waived, and no such claim shall thereafter be asserted against the City. SECTION F - LEGAL RELATIONS AND RESPONSIBILITIES 1. LAWS RELATING TO WORK. The Contractor is presumed to be familiar with all laws, ordinances, and regulations which may, in any manner, affect those engaged or employed upon the work or the materials or equipment used in or upon the work, and shall conduct the work so as not to conflict with such laws, ordinances, and regulations. 2. PROTECTION OF WORK AND PROPERTY. The Contractor for any part of the improvement shall be held responsible for the care of materials and of partially completed and completed — work until final acceptance of the same by the Council. He will be required to make good at his own expense any damage which the work may sustain from any cause prior to the filing of the engineer's certificate of completion. He shall take all risk from floods and casualties of every description and make no charge for delay due to such cause. He may, however, be allowed a reasonable extension of time on account of such delays. He shall correct or make good at his own expense all damages to adjacent property due to the acts or negligence of his employees of the prosecution of his work, and save the City harmless therefor. The Contractor shall be held liable and responsible for all damages done to water, sewer, drain, or other underground pipes and structures, and to sidewalks and private property. — 3. RESPONSIBILITY FOR ACCIDENTS. The Contractor shall assume full responsibility for all damages sustained by persons or property due to the carrying on of his work until final acceptance thereof, or until released by the Engineer in writing. — 4. LIABILITY INSURANCE. The Contractor shall carry liability insurance which shall save the City harmless and protect the public and any person from injury sustained by the reason of the — prosecution of the work or the handling or storing of materials therefor, and said Contractor shall also carry liability insurance which shall meet the requirements of the Iowa Worker's Compensation Law. Before work shall be started on this contract, the Contractor shall furnish the City Clerk with proper affidavit or Affidavits executed by representatives of duly qualified insurance companies, evidencing that said insurance company or companies have issued liability insurance policies, effective during the life of the contract, or for a period of a least ten (10) days following the filing of written notice of _ cancellation, protecting the public and any person from injuries or damages sustained by reason of carrying on the work involved in the Contract. The affidavit shall specifically evidence the following forms of insurance protection: (a) Public liability insurance covering all operations performed by persons directly employed by the Contractor. (b) Public liability insurance covering all operations performed by any Subcontractor to whom a portion of the work may have been assigned. (c) Public liability insurance covering all work upon the project performed by any — independent Contractor working under the direction of either the principal Contractor or a Subcontractor. GENERAL SPECS CSVI 91109AL0200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 GS-10 of 13 (d) Motor vehicle bodily injury liability insurance and property damage liability insurance on all motor vehicles employed on the work, whether owned by the Contractor or by other persons, firms, or corporations. (e) The minimum protection shall be as follows: -- Comprehensive General Liability Insurance General Aggregate Limit $ 5,000,000.00 Products—Completed Operations Aggregate Limit $ 5,000,000.00 Each Occurrence Limit $ 5,000,000.00 Comprehensive Automobile Liability Insurance $ 1,000,000.00 The Contractor shall have the City of Waterloo, Iowa, and the Engineer, AECOM, named as "Additional Named Insureds." A certificate, or a policy if requested, shall be filed with the Owner. All certificates and/or policies of insurance furnished by the Contractor to be filed with the City Clerk shall include the name and address of the agency issuing the same. It shall also be required that the City Clerk be notified by registered mail of the cancellation or expiration of the above insurance. 5. BARRICADES AND SIGNS. The Contractor shall, at his own expense and without further or other order, provide, erect, and maintain, at all times during the progress and suspension of the work and until completion and final acceptance thereof, suitable and requisite barricades, signs, or other adequate protection, as required by the latest edition of the "Iowa Manual on Uniform Traffic Control Devices for Streets and Highways" and shall provide, keep, and maintain such barricades, signs, etc., as may be required or as may be ordered by the City Engineer, to insure the safety of the public as well as those engaged on the work. All barricading plans shall be approved by the City Engineer. 6. ROYALTIES AND PATENTS. The Contractor shall pay all royalties and license fees. He shall defend all suits or claims for infringement of any patent rights and shall save the City harmless -- from loss on account thereof, except that the City shall be responsible for all such loss when a particular process or the product of a particular manufacturer is specified. 7. PERMITS AND REGULATIONS. Permits and licenses of a temporary nature for the prosecution of the work shall be secured and paid for by the Contractor. Permits, license, and easements for permanent changes in existing facilities shall be secured and paid for by the City. 8. CLAIMS FOR DAMAGES. Any claim for damages arising under this Contract shall be made in writing to the party liable within a reasonable time of the first observance of such damage and no later than the time of final payment, except as expressly stipulated otherwise in the case of faulty work or materials, and shall be adjusted by agreement or arbitration. The Contractor shall be held for the payment of all just claims against him arising out of the prosecution of this contract, and his bond will not be released until such claims are paid for dismissed. 9. ASSIGNMENT OF CONTRACT. The Contractor shall not sell or assign the contract or sublet any portion of the work provided for therein without the written consent of the City Council. 10. SUBCONTRACTORS. The Contractor shall, as soon as practicable after the signature of the contract, notify the Engineer in writing of the names of the Subcontractors proposed for the work and shall not employ any that the Engineer may, within a reasonable time, object to as incompetent or unfit. GENERAL SPECS CSVI 91109AL0200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 GS-11 of 13 The Contractor agrees that he is as fully responsible to the City for the acts and omission of his Subcontractors and of persons either directly or indirectly employed by them as he is for the acts and omissions of persons directly employed by him. Nothing contained in the contract documents shall create any contractual relation between any Subcontractor and the City. 11. ARBITRATION. All questions subject to arbitration under this Contract shall be submitted to arbitration at the choice of either party to the dispute. The Contractor shall not cause a delay of the work during any arbitration proceedings, except by agreement with the Engineer. The demand for arbitration shall be filed in writing with the Engineer, in the case of an appeal from his decision, within ten (10) days of its receipt, and in any other case, within a reasonable time after — cause thereof, and in no case later than the time of final payment, except as otherwise expressly stipulated in the contract. If the Engineer fails to make a decision within a reasonable time, an appeal to arbitration may be taken as if his decision had been rendered against the part appealing. _ No one shall be nominated or act as an arbitrator who is in any way financially interested in the contract or in the business affairs of either the City or the Contractor. The general procedure shall conform to the laws of the State of Iowa. Unless otherwise provided by such laws, the parties may agree upon one arbitrator; otherwise, there shall be three--one named in writing by each party to this contract to the other party, and the third chosen by these two arbitrators, or, if _ they fail to select a third within ten (10) days, then he shall be chosen by the Comptroller of the State of Iowa. Should either party refuse or neglect to supply the arbitrators with any papers or information demanded in writing, the arbitrators are empowered by both parties to proceed ex parte. If there be one arbitrator, his decision shall be binding; if three, the decision of any two shall be binding. Such decision shall be a condition precedent to any right of legal action, and, wherever permitted by law, it may be filed in Court to carry it into effect. The arbitrators, if they deem that the case demands it, are authorized to award to the party whose contention is sustained such sums as they shall deem proper for the time, expense, and trouble incident to the appeal, and, if the appeal was taken without reasonable cause, damages for delay, the arbitrators — shall fix their own compensation unless otherwise provided by agreement, and shall assess the costs and charges of the arbitration upon either or both parties. The award of the arbitrators must be in writing, and it shall not be open to objections on account of the form of proceeding or the award, unless otherwise provided by the laws of Iowa. In the event of such laws providing on any matter covered by this article otherwise than as — hereinbefore specified, the method of procedure throughout and the legal effect of the award shall be wholly in accordance with the laws of the State of Iowa, it being intended hereby to lay down a principle of action to be followed, leaving its local application to be adopted to the legal requirements of the place in which the work is to be done. 12. PERFORMANCE AND PAYMENT BONDS. The Contractor shall, at the time of execution and delivery of this contract and before the taking effect of same, furnish and deliver to the City — written bonds of indemnity to the amount required by law in form and substance, and with surety thereon satisfactory and acceptable to the City, to insure the faithful performance and payment by the Contractor of all the covenants and agreements on the part of the Contractor contained in this contract. These bonds shall remain in force and effect for the full amount of the Contract. GENERAL SPECS CSVI 91109AL0200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 GS-12 of 13 13. PERSONAL LIABILITY OF PUBLIC OFFICIALS. In carrying out any of the provisions of the Contract or in exercising any power or authority granted him thereby, there shall be no liability upon the Engineer or his authorized assistants, either personally or as an official of the City, it being understood that in such matters he acts as the agent and representative of the City. 14. JURISDICTION. Any action in Court against the Contractor or sureties on his bond because of damages to property or individuals by said Contractor or his workmen, or because of the violation of any provisions of the specifications, or on account of the failure of said Contractor to comply fully with these provisions, shall be brought in the District Court of the State of Iowa in and for Black Hawk County. 15. TERMINATION OF RESPONSIBILITY. The Contract shall be considered as completed and the Contractor released from further obligations except as to the requirements of his bond, after the work has been completed and finally accepted and final estimates have been allowed and the completion report of the engineer has been filed and approved by the Council. _ 16. CITY'S LEGAL RIGHTS. The City shall not be precluded by any measurements, estimate, or certificate made, either before or after the completion and acceptance of the work and payment therefor, from showing the true amount and character of the work performed and materials furnished by the Contractor, or from showing that any such measurement, estimate, or certificate is untrue or incorrectly made, or the work or materials do not, in fact, conform to the Contract. The City shall not be precluded, notwithstanding any such measurements, estimate, or certificate and payment in accordance therewith, from recovering from the Contractor and his surety such damages as it may sustain by reason of his failure to comply with the terms of the Contract. Neither the acceptance by the City or any of its representatives, nor any payment for or acceptance of the whole or any part of the work, nor any extension of time, nor any possession taken by the City, shall operate as a waiver on — any portion of the contract or of any power herein reserved, or any right to damages herein provided. A waiver of any breach of the contract shall not be held to be a waiver of any other or subsequent breach. almol GENERAL SPECS CSVI 91109AL0200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 GS-13 of 13 THIS PAGE LEFT BLANK INTENTIONALLY SUPPLEMENTAL GENERAL SPECIFICATIONS FOR CONSTRUCTION 1. SUBCONTRACTS The contractor shall cause appropriate provisions to be inserted in all subcontracts relative to the work to require compliance by each subcontractor with the applicable provisions of the contract for the improvements embraced in this contract. 2. REVIEW BY THE CITY OF WATERLOO The City of Waterloo, its authorized representatives and agents, shall at all times have access to and be permitted to observe and review all work, materials, equipment, payrolls, personnel records, employment conditions, material invoices, and other relevant data and records pertaining to this contract, provided, however, that all instructions and approval with respect to the work will be given to the contractor only by the City of Waterloo through its authorized representative or agents. 3. INSPECTION a. The contractor shall furnish promptly all materials reasonably necessary for any tests, which may be required. All tests by the City of Waterloo will be performed in such manner as not to delay the work unnecessarily and will be made in accordance with the provisions of the Technical Specifications. b. Inspection of materials and appurtenances to be incorporated in the improvements embraced in this contract may be made at the place of production, manufacture or shipment, whenever the quantity justifies it, and such inspection and acceptance, unless otherwise stated in the Technical Specifications, shall be final, except as regards (1) latent defects, (2) departures from specific requirements of the contract, (3) damage or loss in transit, or (4) fraud or such gross mistakes as amount to fraud. Subject to the —` requirements contained in the preceding sentence, the inspection of materials as a whole or in part will be made at the project site. 4. WARRANTY OF TITLE No material, supplies, or equipment to be installed or furnished under this contract shall be purchased subject to any chattel mortgage or under a conditional sale, lease-purchase or other agreement by which an interest therein or in any part thereof is retained by the seller or supplier. The contractor shall warrant good title to all materials, supplies, and equipment installed or incorporated in the work and upon completion of all work, shall deliver the same together with all improvements and appurtenances constructed or placed thereon by him to the City of Waterloo free from any claims, liens, or charges. Neither the contractor nor any person, firm, or corporation furnishing any material or labor for any work covered by this contract shall have any right to a lien upon any improvement or appurtenance thereon. Nothing contained in this paragraph, however, shall defeat or impair the right of persons furnishing materials or labor to recover under any bond given by the contractor for their protection or any rights under any law permitting such persons to look to funds due the contractor in the hands of the City of Waterloo. The provisions of this paragraph shall be inserted in all subcontracts and material contracts and notice of its provisions shall be given to all persons furnishing materials for the work when no formal contract is entered into for such materials. SUPPLEMENTAL GENERAL SPECIFICATIONS CSVI 91109AL0200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 SGS-1 of 1 THIS PAGE LEFT BLANK INTENTIONALLY FORM OF CONTRACT FOR THE CONSTRUCTION OF Terminal Building Carpet- - TERMINAL IMPROVEMENTS WATERLOO REGIONAL AIRPORT In the City of Waterloo, Iowa IDOT CSVI PROJECT NO.91190AL0200 IDOT CONTRACT NO.20601 This contract made and entered into this day of , 20_, by and between the City of Waterloo, Iowa, a Municipal Corporation, (hereinafter referred to as City), and of , (hereinafter referred to as Contractor), WITNESSETH: PAR. 1 Contractor agrees to build and construct the Terminal Building Carpet - TERMINAL IMPROVEMENTS and furnish all necessary tools, equipment, materials, and labor necessary to do all the work called for in the plans and specifications in a workmanshiplike manner and for the prices set forth in Contractor's proposal, which was accepted by the City, and which is understood and agreed to be a part of this contract. PAR. 2 It is understood and agreed that the resolution adopted by the City Council ordering the construction of the improvement, the Notice to Contractors as published, the Instruction to Bidders, the Form of Proposal, the Construction and Maintenance Bonds, the Council Proceedings relating to this matter, and the Plans and Specifications shall all be considered as forming a part of the contract the same as though they were each set out in said contract. PAR. 3 The Contractor agrees to furnish at its own cost and expense, all necessary materials and labor for said work and to construct said improvements in a thorough, substantial, and workmanlike manner, and in strict accordance with the requirements of this contract, and of ._ the plans and specifications made a part hereof by reference, and to the satisfaction and approval of the City and its engineer. PAR. 4 The Contractor agrees to perform said work and install said improvements on the terms set _ out in bid or proposal to the City which has been accepted by the City and which is by reference made a part of this contract. PAR. 5 The Contractor agrees to commence said work within ten (10) working days after receipt of "Notice to Proceed"and complete it on or before November 1, 2019, unless an extension of time is granted in writing by the Council of the City. PAR. 6 Should the Contractor fail to complete said improvements in strict accordance with the terms and conditions of this contract, or the plans and specifications therefor promptly by the date herein specified, the City may pay such additional sums as it may be required to pay by reason of the failure of said contractor and deduct any and all such sums from any amount then due the Contractor. PAR. 7 The Contractor agrees to comply with and obey all ordinances of the City of Waterloo, Iowa, relating to the obstruction of streets and alleys, keeping open passage ways for water, traffic, and protecting any excavations in any street or alley, and maintaining proper and sufficient barricades with lights and signals during all hours of darkness, to see that the backfilling is properly done, and agrees to keep the City whole and defend any and all suits that may be brought against the City by reason of any injuries that may be sustained by any person or property allegedly caused by the Contractor, or his agents, while work is done pursuant to this agreement. FORM OF CONTRACT CSVI 91109AL0200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 C-1 OF 3 PAR. 8 The Contractor agrees that in the event a law suit is brought against the City for damages allegedly sustained by reason of any act, omission or negligence of the Contractor or its agents, or on account of any injuries allegedly sustained by reason of any obstruction, hole, depression or barrier placed or dug by the defendant or its agents, in the doing of the work herein contracted for, that it will defend said suit and save the City harmless therein, and in — case judgment is rendered against the City, the Contractor agrees to pay the same promptly. The Contractor agrees to carry public liability insurance in a solvent company in a sufficient amount to protect the City and those who use the streets of the City. PAR. 9 The City shall have the right to appoint one or more construction reviewers who shall review the progress of the work in detail; also, to make any test or any material to be used in such work. No material shall be used in any work until the same has first been approved by the construction reviewer. Such construction reviewer shall have full authority to pass judgment upon all materials and upon the manner of doing the work, and their judgment on rejecting any materials, substance, or manner of work shall be final unless it is revoked or modified by the City Engineer. — PAR. 10 Any material, which has been rejected by the construction reviewer, shall be at once removed from the line of work and shall not be again taken thereon or placed with the material proposed to be used without the written consent of the City Engineer. PAR. 11 The Contractor shall maintain no cause of action against the City on account of delays and prosecution of work, but if said work is delayed by the City, the Contractor shall have such extra time for completion of the job as was lost by reason of the delay caused by the City. PAR. 12 The Contractor agrees to pay punctually all just claims of labor, material, men, or subcontractors who shall perform labor or furnish materials entering into this improvement.It is agreed that the City need not pay the Contractor until all such claims are paid by the Contractor. It is agreed that the City shall not be liable for said labor, material, or men under this contract. PAR. 13 The Contractor agrees to furnish the City, simultaneously with this contract, a bond on a form to be provided by the City in the amount provided by law as stated in the Notice to Bidders, which shall be for the benefit of the City, and any and all persons injured by the breach of any of the terms of this contract. Said bond shall be filed with the City Clerk and shall be subject to the approval of the City Council, and is by reference made a part of this contract. PAR. 14 The Contractor agrees that should it abandon work under this contract or cease the prosecution thereof for a period of thirty (30) consecutive days without reasonable cause, and should it fail to proceed with said work within ten (10) days after a notice to continue or carry it on has been mailed to it at the address given herein by the City, or after such notice has been served on it, then the City may proceed to complete said work, using any material, tools, or machinery found along said line of work, doing the work either by contract or as it may elect, and the Contractor and the sureties on its bond shall be liable to the City for the — costs and expenses so paid out. Said costs shall be retained by the City from any compensation due, or to become due the Contractor, and may be recovered by the City in an action upon Contractor's bond. PAR. 15 In consideration of the full compliance on the part of the Contractor with all the provisions, stipulations, and conditions hereof, or contained in the various instruments made a part of this contract by reference, and upon completion and acceptance of said work, the City — agrees to pay to the Contractor, in the manner set out in the Notice to Contractors, the amount of money due the Contractor for work performed and accepted, at the unit prices set out in the Contractor's proposal, which has been accepted by the City. FORM OF CONTRACT CSVI 91109ALO200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 C-2 OF 3 PAR. 16 The total amount of the contract, based on the Engineer's estimates of quantities and the Contractor's unit bid prices, and for which 100% surety bond is required, is $ PAR. 17 After the completion of said work, the Contractor agrees to remove all debris and clean up said streets, and to save the City harmless from any damage allegedly resulting from a _. failure to clean up and remove the debris or put the street back in a proper condition for travel. PAR. 18 This contract is not divisible, but in the event of a conflict between this contract and the various instruments incorporated by reference, this contract shall govern. PAR. 19 Before the Contractor shall be entitled to receive final payment for work done under this contract, it shall execute and file a bond in the penal sum of not less than 100% of the total amount of the contract, same to be known as"Maintenance Bond," and which bond must be approved by the City Council, and which bond is in addition to the bond given by the Contractor to guarantee the completion of the work. PAR. 20 The Contractor shall maintain all work done hereunder in good order for the period of two (2) years from and after the date it is accepted by the Council of the City of Waterloo, Iowa. Said maintenance shall be made without expense to the City or the abutting property. In the event of the failure or default of the Contractor to remedy any or all defects appearing in said work within a period of two (2) years from the date of its acceptance by said Council, and after having been given ten (10) days' notice so to do by registered letter deposited in the United States Post Office in said town, addressed to said contractor at the address herein given, then the City may proceed to remedy such defects. The costs and expenses thereof to be recovered from the Contractor and the sureties on its maintenance bond by an action brought in any court of competent jurisdiction. PAR. 21 The Contractor shall give notice to said City by registered letter directed to the Mayor or City Clerk/Auditor thereof not more than four (4) and not less than three (3) months prior to the expiration of the term during which the Contractor is required to maintain said improvements, in good repair by the terms of its Contract. The liability of the Contractor and of the sureties on its bond for maintenance of the said improvements shall continue until three (3) months after such notice has been given to the City, and, in any event, until two (2) years after the acceptance of the work. CITY OF WATERLOO, IOWA Mayor City Clerk Contractor BY: Title: Approved by the City Council of the City of Waterloo, Iowa, this day of 20_. ATTEST: , City Clerk Waterloo, Iowa FORM OF CONTRACT CSVI 91109ALO200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 C-3 OF 3 THIS PAGE LEFT BLANK INTENTIONALLY PERFORMANCE BOND KNOW ALL MEN BY THESE PRESENTS: That we, of (the"Principal"), and of (the"Surety"), are held and firmly bound unto the City of Waterloo, Iowa (the"Obligee"), in the penal sum of_ Dollars ($ ), lawful money of the United States, for the payment of said sum in connection with a contract (the"Contract") dated on or about for the purpose of . The Contract is incorporated herein by reference as though fully set forth herein. Whenever the Principal shall be and is declared by the Obligee to be in default under the Contract, with the Obligee having performed its obligations in the Contract, then the Surety, acknowledging that time is of the essence, may promptly remedy the default, or shall promptly undertake to: 1. Complete the Contract in accordance with its terms and conditions; or 2. Obtain one or more bids for completing the Contract in accordance with its terms and conditions, and upon determination by the Surety of the lowest responsible bidder, or negotiated proposal, or, if the Obligee elects, upon determination by the Obligee and the Surety jointly of the lowest responsible bidder, or negotiated proposal, arrange for a contract between such party and the Obligee. The Surety will make available as work progresses sufficient funds to pay the cost of completion less the balance of the Contract price. The cost of completion includes responsibilities of the Principal for correction of defective work and completion of the Contract, the Obligee's legal and design professional costs resulting directly from the Principal's default, and liquidated damages or actual damages if no liquidated damages are specified in the Contract. The term "balance of the Contract price" _ means the total amount payable by the Obligee to the Principal under the Contract and any amendments thereto, less the amount properly paid by the Obligee to the Principal; or 3. Determine the amount for which it is liable to the Obligee and pay the Obligee that amount as soon as practicable. In the event this bond is enforced, Principal and Surety agree to indemnify Obligee and hold Obligee harmless from and against any and all costs of enforcement, including but not limited to reasonable attorneys' fees and expenses. Every Surety on this bond shall be deemed and held, any contract to the contrary notwithstanding, to consent to each and all of the following matters, without notice: 1. To any extension of time to the Contract in which to perform the Contract. 2. To any change in the plans, specifications, or Contract when such change does not involve an increase of more than twenty percent (20%) of the total Contract price, and shall then be released only as to such excess increase. 3. That no provision of this bond or of any other contract shall be valid which limits to less than one (1) year from the time of the acceptance of the work the right to sue on this bond for defect in workmanship or material not discovered or known to the Obligee at the time such work was accepted. If the Principal performs the Contract, then this bond shall be null and void; otherwise it shall remain in full force and effect. In no event shall the Surety's total obligation exceed the penal amount of this bond. PERFORMANCE BOND CSVI 91109AL0200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 PFB-1 of 2 Terms used herein shall include, as appropriate, the singular or plural number, or the masculine, feminine or neuter gender. — IN WITNESS WHEREOF, the undersigned Principal and Surety have executed this Performance Bond as of PRINCIPAL SURETY Name Name _. By: By: Title: Title: [attach Power of Attorney] NOTE: Date of BOND must not be prior to date of Contract. If CONTRACTOR is Partnership, all partners should execute BOND. PERFORMANCE BOND CSVI 91109AL0200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 PFB-2 of 2 PAYMENT BOND KNOW ALL MEN BY THESE PRESENTS: that (Name of Contractor) (Address of Contractor) a , hereinafter called Principal, (Corporation, Partnership or Individual) and, (Name of Surety) (Address of Surety) hereinafter called Surety, are held and firmly bound unto (Name of Owner) (Address of Owner) hereinafter called OWNER, in the penal sum of Dollars,($ ) in lawful money of the United States, for the payment of which sum well and truly to be made, we bind ourselves, successors, and assigns, jointly and severally, firmly by these presents. -- THE CONDITION OF THIS OBLIGATION is such that whereas, the Principal entered into a certain contract with the OWNER, dated the day of , 20_, a copy of which is hereto attached and made a part hereof for the construction of: TERMINAL BUILDING CARPET-TERMINAL IMPROVEMENTS WATERLOO REGIONAL AIRPORT NOW, THEREFORE, if the Principal shall promptly make payment to all persons, firms, SUBCONTRACTORS, and corporations furnishing materials for or performing labor in the prosecution of the WORK provided for in such contract, and any authorized extension or modification thereof, including all amounts due for materials, lubricants, oil, gasoline, coal and coke, repairs on machinery, equipment and tools, consumed or used in connection with the construction of such WORK, and all insurance premiums on said WORK, and for all labor, performed in such WORK whether by SUBCONTRACTOR or otherwise, then this obligation shall be void; otherwise to remain in full force and effect. PROVIDED, FURTHER, that the said Surety for value received hereby stipulates and agrees that no change, extension of time, alteration or addition to the terms of the contract or to the WORK to be performed thereunder or the SPECIFICATIONS accompanying the same shall in any wise affect its obligation on this BOND, and it does hereby waive notice of any such change, extension of time, alteration or addition to the terms of the contract or to the WORK or to the SPECIFICATIONS. PAYMENT BOND CSVI 91109AOL200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 PB-1 of 2 PROVIDED, FURTHER, that no final settlement between the OWNER and the CONTRACTOR shall abridge the right of any beneficiary hereunder, whose claim may be unsatisfied. IN WITNESS HEREOF, this instrument is executed in counterparts, each one (number) of which shall be deemed an original, this the day of , 20_ ATTEST: Principal (Principal) Secretary (SEAL) By (s) — (Address) Witness as to Principal (Address) Surety ATTEST: By — Attorney-in-Fact Witness as to Surety (Address) (Address) (Address) — NOTE: Date of BOND must not be prior to date of Contract. _ If CONTRACTOR is Partnership, all partners should execute BOND. PAYMENT BOND CSVI 91109A0L200 Terminal Bldg Carpet-Terminal Improvements AECOM 60600098 CONTRACT NO.20601 PB-2 of 2 APPENDIX APPENDIX TABLE OF CONTENTS 1. Plans 2. Photographs of Existing Conditions APPENDIX PLAN SHEETS NI ai 0 ,,,,,,,,,,,,,,,,,,, .. ,,, , , _„, t . ,,,,, . „„ ; , _,,. ' -----, , ,., ., BASE BID m OFFICE AR m m?t,` a z, BA- BID ,4 ae b - -. FAA OF - LIM " ..-.,. , ALTERNATE BID 1 TICKET COUNTER AREA MANNINGTON CO MAIN TERMINAL MANNINGTON CO OFFICE AREAS MANNINGTON CO SCALE 1:20 TERMINAL BUILDING CARPET TERMINAL IMPROVEMENTS WATERLOO REGIONAL AIRPORT IDOT CSVI PROJECT NO.91190AL0200 IDOT CONTRACT NO.20601 60600098 .. if 4,00"/ SCALE 1:20 TERMINAL BUILDING EXISTING CARPET TERMINAL IMPROVEMENTS WATERLOO REGIONAL AIRPORT IDOT CSVI PROJECT NO.91190AL0200 IDOT CONTRACT NO.20601 60600098 APPENDIX PHOTOGRAPHS OF EXISTING CONDITIONS 1 1 0._ 4111101111111111111111111P- g 0. � '� y ' ..; ;:4,,:i''',.,::.":, AtiN-41.4147-'' I:1:! , . ':' '" . �' RCAD :-i C s ' ° .Ha. il` r m a dam„ "fir 1.1 3� a '"k r s i,:,...:.:,,,,-,',:i _:::o. , -. :\__. ., ,,. , ,i..... -- , inni . ,..,v . , .. ,:...-,1,7----- '", „ : iti,..- : . i .v-,,,_ ,:',,,,;,?„:. 11 • - MI --.,, - : ..i, ..;..: i v E s a.a,.` ' pF �sC.ut= am*e'' .,7-: "_`':.2,S_„;, ., t _ - ,-.. .. . .-. t� ,:-,, ». tea }tt — _ tot, _ ».*"'"--,--- 1 �.... 1 11171H , R`._aka _ * II. _ __ il, r 5 .„ I II .--:iitt ; -- ) _ q. ...L fit�S `.?&y A C- ,� ¢ .. , fly t 4 `Ts n: lr l/1, 4v �,y `$ � .y,rtFps ..z ,- gp" af.. , r rc ,•,,, w 5541105.-.1.43 ° : ,:..,,,,,,,,,,., ..,7,7',,,;,-`',',"1,,,,, ...m. } p r ,Xu t �t{{ ttE' - ya "�� f of m �_,s .:¢mz.< "rii-,:,,!,:::,,,,,, , ` ma r F sue, ;;: a �a ^ s «+ .F 4.it , 1iN4 1 +,n sr„,-, na. t""m'S 1,t Y . tf,t" '. } by pA j il `; 4i. �, B r M:* Tye ,b a ny ,i' d ., iii iir 3�SE€4 'd ii:iiiiiik; I. 2k ��„j`iiy{ f 5, Y b� £ 4�,5 3 0.'3Y ,y �10, li fe a` Zin q �� 14te. pa j riyY bi Z E 4 -4 a't ,..Y'YET` S"✓> t,, i'.'. 1m` §' 5" eft ash * ut a'R�10y .�r :,m ,.,•., • ``s..a` '''a?f••�k;.. 9�y y;spy y��y \ •#' 9 i U .:` ift I' ! a,- i" f' ,C .`g l' ,tom 4, l jj 'ieil 'yi Nil--,. ..,„,,, ,.. ,,,,.„, „„,„ :tit �. ,, 3'9V„K .F ilp ;F F�,,jj,,Y^' 'haa� �.q xf2"Wk£:�"�` ✓f '.t W 7{ ,, f,pr ^,. , a r X-aye t s 7 w P t 't`' z "', , L ffa 't aA'" 0, 14 W {n — �� '✓�� ;; " s;1; Az '` Yk t t nt �..-' &�' t,A -F' a 4'l`t .. a :.v x .a xx Yx ti...ter. , �., ,,:',4I-,414 G r g ;tfa- t p ���"� � ���;p1€.. ..� �-i a,.�'' ham �.a�i�k 7 a ' �� .,,-x �. �. �'��"�S�a.� g k , (D ll,-„-....,*;-2-' '.-4-.4IN-,.--V, ',...,:,-11,-;4: -...- , -,,- „, #$ cgs f } cc f... ..�..,>..a: ct �: .:.w :' s w r. km,;. .."`..wp+ ,,,.. Y. 1.1;1' Ilii L. r..