HomeMy WebLinkAboutCONTRACT RESOLUTION 2009-273 . 9-O0q — 073 Mayor
CITY OF WATERLOO, IOWA
WATERLOO LEISURE SERVICES COMMISSION
CONTRACT
for
2009 RIVERFRONT STADIUM
FIRST BASE PARTY DECK REPLACEMENT
This Contract made and entered into this 2nd day of April, 2009, by and between the City of Waterloo,
Iowa, a Municipal Corporation, hereinafter referred to as City, and Christone Concrete Inc. hereinafter
referred to as Contractor,
WITNESSETH:
Par. 1 The Contractor shall furnish all supervision, technical personnel, labor, materials, and
equipment to perform all work required for the 2009 Riverfront Stadium First Base Party Deck
Replacement, 850 Park Road, Waterloo, Iowa as described in the specifications and shown on the plans.
Par. 2 The Contract Documents shall consist of the following:
a. This Agreement e. General Conditions
b. Notice of Hearing f. Specifications
c. Instruction to Bidders g. Plans/Drawings
d. Signed copy of Bid
These documents form the Contract and are all fully a part of the Contract as if attached to this Contract or
repeated herein.
Par. 3 The Contractor agrees to commence the work within ten (10) days after the issuance of
"Notice to Proceed" and complete the work within the given time frame.
Par. 4 The Contractor agrees to comply with and obey all ordinances of the City of Waterloo,
Iowa, relating to the obstruction of streets and alleys, keeping open passageways for water, traffic and
protecting any excavation in any street or alley and maintaining proper and sufficient barricades with
lights and signals during all hours of darkness and agrees to see that the backfilling is properly done and
agrees to keep the City whole and defend any suits that may be brought against it by reason of any injuries
that may be sustained by any person on account of doing this work by the Contractor and any agents of the
Contractor.
Par. 5 The Contractor agrees that in case a suit is brought against the City for damages sustained
by reason of any act, omission or negligence of the Contractor or its agents or on account of any injuries
sustained by reason of any obstruction, hole, depression or barrier placed or dug by the defendant or its
agents in the doing of the work herein contracted for, that it will defend said suit and save the City
harmless therein and in case judgment is rendered against the City, the Contractor agrees to pay the same
promptly and agrees to carry public liability insurance in a solvent company in a sufficient amount to
protect the City and any and all persons who may use the project.
CONTRACT Page 1 of 2
Par. 6 The Contractor shall have no cause of action against the City on account of delays and
prosecution of work, but if the work is delayed by the City, the Contractor may have extra time for the
completion of the job as was lost by reason of the delay caused by the City.
Par. 7 The Contractor agrees to pay punctually all just claims of labor, material, men or
Subcontractors, who perform labor or furnish materials entering into this improvement. It is agreed that
the City need not pay the Contractor until all such claims are paid by the Contractor. It is agreed that the
City shall bear no liability for payments due for labor or materials under this contract.
Par. 8 In consideration of the full compliance on the part of the Contractor with all the provisions,
stipulations and conditions hereof, or contained in the various instruments made a part of this Contract by
reference, and upon completion and acceptance of the work, the City agrees to pay the Contractor:
TOTAL BID PRICE FOR THE 2009 RIVERFRONT STADIUM FIRST BASE PARTY DECK
REPLACEMENT, AS SPECIFIED:
FIFTY-SEVEN THOUSAND AND NO/100 dollars (S57,000.00)
City of Waterloo, Iowa,
� -� Timothy J. Hurley, Mayor
Mayor Printed Name and Title
Nancy Eckert, City Clerk
(- 1'.\(-"lt(4-0--City Clerk -6-1i2j--- Printed Name and Title
CONTRACTOR:
r `— ,4'__ by:
Name of Contractor Signature `� A,
Printed Name and Title
Approved by the City Council of the City of Waterloo, Iowa,this G day of a pr 1 d , 2009.
ATTEST:
City Clerk
1. Copy—Mayor 2.Copy—Contractor 3.Copy—Leisure Services
CONTRACT Page 2 of 2