Loading...
HomeMy WebLinkAboutBoulder Contracting - FY17 Bridge Deck Rpir and overlay #879-11/7/2016FORM OF CONTRACT CONTRACT FOR THE CONSTRUCTION OF F.Y. 2017 BRIDGE DECK REPAIR AND OVERLAY PROGRAM CITY OF WATERLOO, IOWA CONTRACT NO. 879 This contract made and entered into this t day of OoJtmbe 20.J_b, by and between the City of Waterloo, Iowa, a Municipal Corporation, (hereinafter referred to as City), and BOULDER CONTRACTING, LLC of Grundy Center, Iowa (hereinafter referred to as Contractor), WITNESSETH: PAR. 1 Contractor agrees to build and construct the FY 2017 BRIDGE DECK REPAIR AND OVERLAY PROGRAM (DIVISION I BASE BID + ALT A OPTION 1 + DIVISION II), Contract No. 879 and furnish all necessary tools, equipment, materials, and labor necessary to do all the work called for in the plans and specifications in a workmanshiplike manner and for the prices set forth in Contractor's proposal, which was accepted by the City, and which is understood and agreed to be a part of this contract. PAR. 2 It is understood and agreed that the resolution adopted by the City Council ordering the construction of the improvement, the Notice to Contractors as published, the Instruction to Bidders, the Form of Proposal, the Construction and Maintenance Bonds, the Council Proceedings relating to this matter, and the Plans and Specifications shall all be considered as forming a part of the contract the same as though they were each set out in said contract. PAR.3 The Contractor agrees to furnish at its own cost and expense, all necessary materials and labor for said work and to construct said improvements in a thorough, substantial, and workmanlike manner, and in strict accordance with the requirements of this contract, and of the plans and specifications made a part hereof by reference, and to the satisfaction and approval of the City and its engineer. FORM OF CONTRACT PAGE 1 OF 5 PAGES PAR. 4 The Contractor agrees to pertorm said work and install said mprovements on the terms set out in bid or proposal to the Gity which has been accepted by the City and which is by reference made a part of this contract. PAR. 5 PAR. 6 PAR. 7 PAR. 8 PAR. 9 The Contractor agrees to commence said work within ten (10) working days after receipt of "Notice to Proceed' and complete it on or betore October 20, 2017 unless an extension of time is granted in writing by the Council of the City. Should the Contractor fail to complete said improvements in strict accordance with the terms and conditions of this contract, or the plans and specifications therefor promptly by the date herein specitied, the Gity may pay such additional sums as it may be required to pay by reason of the tailure of said contractor and deduct any and alt such sums from any amount then due the Contractor. The Contractor agrees to comply with and obey all ordinances ot the Gity of Waterloo, lowa, relating to the obstruction ot streets and alleys, keeping open passage ways for water, traffic, and protecting any excavations in any street or alley, and maintaining proper and sufficient barricades with lights and signals during all hours ot darkness, to see that the backfilhng is properly done, and agrees to keep the City whole and detend any and alt suits that may be brought against the City by reason of any injuries that may be sustained by any person or property altegedly caused by the Contractor, or his agents, while work is done pursuant to this agreement. The Contractor agrees that in the event a law suit is brought against the Gity for damages allegedly sustained by reason ot any act, omission or negligence of the Contractor or its agents, or on account ot any injuries allegedly sustained by reason of any obstruction, hole, depression or barrier placed or dug by the detendant or ts agents, in the doing of the work herein contracted tor, that it will detend said suit and save the City harmless therein, and in case judgment is rendered against the City, the Contractor agrees to pay the same promptly. The Contractor agrees to carry public liability insurance in a solvent company in a sufficient amount to protect the City and those who use the streets of the City. The City shall have the right to appoint one or more construction reviewers who shall review the progress of the work in detail; also, to make any test or any material to be used in such work. No material FORM OF CONTRACT PAGE 2 OF 5 PAGES PAR. 10 PAR. 11 shafl be used in any work until the same has first been approved by the construction reviewer. Such construction reviewer shall have full authority to pass judgment upon all materials and upon the manner of dong the work, and their judgment on rejecting any materials, substance, or manner of work shall be firial unless it is revoked or modified by the City Engineer. Any materia, which has been rejected by the construction reviewer, shall be at once removed from the line of work and shall not be again taken thereon or paced with the material proposed to be used without the written consent of the City Engineer. The Contractor shali maintain no cause of action against the City on account of delays and prosecution of work, but it said work is delayed by the City, the Contractor shall have such extra time tor completion of the job as was Iost by reason of the delay caused by the City. PAR. 12 The Contractor agrees to pay punctually all just claims ot labor, material, men, or subcontractors who shail perform labor or furnish materials enterin into this improvement. It is agreed that the City need not pay the Contractor until all such claims are paid by the Contractor. It is agreed that the City shalt not be Iiable tor said labor, material, or men under this contract. PAR. 13 PAR. 14 The Contractor agrees to furnish the City, simultaneously with this contract, a bond on a form to be provided by the City in the amount provided by Iaw as stated in the Notice to Bidders, which shall be tor the benefit of the Gity, and any and aU persons injured by the breach of any of the terms ot this contract. Said bond shall be tiled with the Gity Clerk and shall be subject to the approval of the City Council, and is by reference made a part ot this contract. The Contractor agrees that should it abandon work under this contract or cease the prosecution thereof for a period of thirty (30) consecutive days without reasonable cause, and should it fail to proceed with said work within ten (10) days after a notice to continue or carry it on has been mai(ed to it at the address given herein by the City, or after such notice has been served on it, then the City may proceed to complete said work, using any material, tools, or machinery tound along said line of work, doing the work either by contract or as it may elect, and the Contractor and the sureties on its bond shall be Iiable to the Gity for the costs and expenses so paid out. Said costs shaH be retained by the City from any compensation due, or to become due the Contractor, and may be recovered by the City in an action upon Contractor's bond. FORM OF CONTRACT PAGE 3 OE 5 PAGES PAR. 15 PAR. 16 PAR. 17 PAR. 18 PAR. 19 PAR. 20 In consideration of the fuH compliance on the part of the Contractor wth all the provisions, stipulations, and conditions hereof, or contained in the various instruments made a part of this contract by reference, and upon completion and acceptance of said work, the City agrees to pay to the Contractor, in the manner set out in the Notice to Coritractors, the amount ot money due the Contractor for work performed and accepted, at the unit phces set out in the Contractors proposal, which has been accepted by the City. The total amount ot the contract, based on the Engineer's estimates of quantities and the Contractor's unit bid prices, and for which 100% surety bond is required is $1,424,426.57. After the completion ot said work, the Contractor agrees to remove all debris and clean up said streets, and to save the City harmless from any damage allegedly resulting from a failure to clean up and remove the debris or put the street back in a proper condition for travel. This contract is not divisible, but in the event ot a conflict between this contract and the various instruments incorporated by reference, this contract shall govern. Before the Contractor shall be entitled to receive final payment for work done under this contract, it shall execute and file a bond in the penal sum ot not Iess than 100% ot the total amount ot the contract, same to be known as Maintenance Bond,' and which bond must be approved by the City Council, and which bond is in addition to the bond given by the Contractor to guarantee the completion of the work. The Contractor shall maintain all work done hereunder in good order for the period of two (2) years from and after the date it is accepted by the Council of the Gity of Waterloo, Iowa. Said maintenance shalt be made without expense to the City or the abutting property. In the event of the failure or default of the Contractor to remedy any or aM defects appearing in said work within a period of two (2) years from the date ot its acceptance by said Council, and affer having been given ten (10) days notice SO to do by registered Ietter deposited in the United States Post Office in said town, addressed to said contractor at the address herein given, then the City may proceed to remedy such defects. The costs and expenses thereot to be recovered from the Contractor and the sureties on its maintenance bond by an action brought in any court of competent jurisdiction. FORM OF CONTRACT PAGE 4 OE 5 PAGES PAR. 21 The Contractor shall give notice to said City by registered letter directed to the Mayor or City Clerk/Auditor thereof not more than four (4) and not less than three (3) months prior to the expiration of the term during which the Contractor is required to maintain said improvements, in good repair by the terms of its Contract. The liability of the Contractor and of the sureties on its bond for maintenance of the said improvements shall continue until three (3) months after such notice has been given to the City, and, in any event, until two (2) years after the acceptance of the work. CITY OF WATERLOO, IOWA ayor BOULDER CONTRACTING, LLC Contractor BY: "Zi, I re ka t Title: Approved by the City Council of the City of Waterloo, Iowa, this day of aWM6-,,- 20 N. ATTEST: l��, City Clerk Waterloo, Iowa FORM OF CONTRACT PAGE 5 OF 5 PAGES PERFORMANCE BOND I:=*, I MNIT43--W SS1M KNOW ALL MEN BY THESE PRESENTS: That we, Boulder Contracting, LLC of Grundy Center IA (the "Principal"), and Nationwide Mutual Insurance Company Of Des Moines IA (the "Surety"), are held and firmly bound unto the City of Waterloo, Iowa (the "Obligee"), in the penal sum of one Million Four Hundred Twenty-four Thousand Four Hundred Twenty-six & 57110ODollars ($ 1,424,426.57---------------- ), lawful money of the United States, for the payment of said sum in connection with a contract (the "Contract") dated on or about t /-J / 16 for the purpose OfFY 2017 Bridge Deck Repair and Overlay Program (Division 1 Base Bid + Alt A Option 1 + Division II) Contract No. 879 The Contract is incorporated herein by reference as though fully set forth herein. Whenever the Principal shall be and is declared by the Obligee to be in default under the Contract, with the Obligee having performed its obligations in the Contract, then the Surety, acknowledging that time is of the essence, may promptly remedy the default, or shall promptly undertake to: 1. Complete the Contract in accordance with its terms and conditions; or 2. Obtain one or more bids for completing the Contract in accordance with its terms and conditions, and upon determination by the Surety of the lowest responsible bidder, or negotiated proposal, or, if the Obligee elects, upon determination by the Obligee and the Surety jointly of the lowest responsible bidder, or negotiated proposal, arrange for a contract between such party and the Obligee. The Surety will make available as work progresses sufficient funds to pay the cost of completion less the balance of the Contract price. The cost of completion includes responsibilities of the Principal for correction of defective work and completion of the Contract, the Obligee's legal and design professional costs resulting directly from the Principal's default, and liquidated damages or actual damages if no liquidated damages are specified in the Contract. The term "balance of the Contract price" means the total amount payable by the Obligee to the Principal under the Contract and any amendments thereto, less the amount properly paid by the Obligee to the Principal; or 3. Determine the amount for which it is liable to the Obligee and pay the Obligee that amount as soon as practicable. In the event this bond is enforced, Principal and Surety agree to indemnify Obligee and hold Obligee harmless from and against any and all costs of enforcement, including but not limited to reasonable attorneys' fees and expenses. Every Surety on this bond shall be deemed and held, any contract to the contrary notwithstanding, to consent to each and all of the following matters, without notice: Performance Bond Page 1 of 2 To any extension of time to the Contract in which to perform the Contract. 2. To any change in the plans, specifications, or Contract when such change does not involve an increase of more than twenty percent (20%) of the total Contract price, and shall then be released only as to such excess increase. 3. That no provision of this bond or of any other contract shall be valid which limits to less than one (1) year from the time of the acceptance of the work the right to sue on this bond for defect in workmanship or material not discovered or known to the Obligee at the time such work was accepted. If the Principal performs the Contract, then this bond shall be null and void; otherwise it shall remain in full force and effect. In no event shall the Surety's total obligation exceed the penal amount of this bond. Terms used herein shall include, as appropriate, the singular or plural number, or the masculine, feminine or neuter gender. IN WITNESS WHEREOF, the undersigned Principal and Surety have executed this Performance Bond as of � � /7 /l b a:11,41631=111 1=0=4 .11! By: h Title: Pots. SURETY By:J0 Title: Nancy D. Baltutat Attorney -in -Fact [attach Power of Attorney] NOTE: Date of BOND must not be prior to date of Contract. If CONTRACTOR is Partnership, all partners should execute BOND. If this project includes Federal Funds, the following applies to the payment bond: IMPORTANT: Surety companies executing bonds must appear on the Treasury Department's most current list (Circular 570 as amended) and be authorized to transact business in the State where the project is located. Performance Bond Page 2 of 2 PAYMENT BOND Bond Number BD743152 KNOW ALL MEN BY THESE PRESENTS: that Boulder Contracting LLC (Name of Contractor) 25789 N Avenue, Grundy Center IA 50638 (Address of Contractor) a Corporation hereinafter called Principal, (Corporation, Partnership or Individual) and, Nationwide Mutual Insurance Company (Name of Surety) 1100 Locust Street. Dept 2006, Des Moines IA 50391 (Address of Surety) hereinafter called Surety, are held and firmly bound unto City of Waterloo (Name of Owner) hereinafter called OWNER, in the penal sum of $1,424,426.57 Dollars,($ $1,424,426.57 ) in lawful money of the United States, for the payment of which sum well and truly to be made, we bind ourselves, successors, and assigns, jointly and severally, firmly by these presents. THE CONDITION OF THIS OBLIGATION is such that whereas, the Principal entered into a certain contract with the OWNER, dated the 1+1-\ day of M6oeI,n6e✓ 20ji, a copy of which is hereto attached and made a part hereof for the construction of: FY 2017 Bridge Deck Repair and Overlay Program (Division I Base Bid + Alt A Option 1 + Division II) NOW, THEREFORE, if the Principal shall promptly make payment to all persons, firms, SUBCONTRACTORS, and corporations furnishing materials for or performing labor in the prosecution of the WORK provided for in such contract, and any authorized extension or modification thereof, including all amounts due for materials, lubricants, oil, gasoline, coal and coke, repairs on machinery, equipment and tools, consumed or used in connection with the construction of such WORK, and all insurance premiums on said WORK, and for all labor, performed in such WORK whether by SUBCONTRACTOR or otherwise, then this obligation shall be void; otherwise to remain in full force and effect. PROVIDED, FURTHER, that the said Surety for value received hereby stipulates and agrees that no change, extension of time, alteration or addition to the terms of the contract or to the WORK to be performed thereunder or the SPECIFICATIONS accompanying the same shall in any wise affect its obligation on this BOND, and it does hereby waive notice of any such change, extension of time, alteration or addition to the terms of the contract or to the WORK or to the SPECIFICATIONS. PROVIDED, FURTHER, that no final settlement between the OWNER and the CONTRACTOR shall abridge the right of any beneficiary hereunder, whose claim may be unsatisfied. IN WITNESS HEREOF, this instrument is executed in 3 counterparts, each one of � (number) which shall be deemed an original, this the day of o�K,► 20 tU /d\i9*�M (Principal) Secretary (SEAL) Witness as to Principal Boulder Contracting LLC Principal By �� (S) 25789 N Avenue, Grundy Center IA 50638 (Address) (Address) Nationwide Mutual Insurance Company Surety ATTEST: By rn"�fid:' t arney-in- act Nancy D. Baltutat 4200 University Avenue #200 Witness as to Surety (Address) 4200 University Avenue #200 West Des Moines IA 50266 (Address) West Des Moines IA 50266 NOTE: Date of BOND must not be prior to date of Contract. If CONTRACTOR is Partnership, all partners should execute BOND. If this project includes Federal Funds, the following applies to the payment bond: IMPORTANT: Surety companies executing bonds must appear on the Treasury Department's most current list (Circular 570 as amended) and be authorized to transact business in the State where the project is located. KNOW ALL MLN BY IMESE PRE$ENTS THAT: Nationwlde Mutoal lnsurance Cornpany, an Chio corporation Farmland Mutuat tnsurance Company, an towa corparatlon Nationwide Agrbuslnoss Insurance Company, an lowa corporatlon Power of Attorney AMCO lnsurance Company, an lowa corporallon Allled Property and Casualty Insuranco Conipany, an lowa corporatlon Depositors lnsurance Cornpany, an lowa corporation hereinatter referred to sevoraily as the tompany and collectively as the Companies, each doas hereby make, consijtule and appolnt: CREC T. LAMAIR PATRIC}( K DUFF CHRIST�Pt-IER 9. SEIBIWIJNG MARIC E. KEAIItNES JEFFREY 8. BAKER JOSEPI-I II1VIN SCJ-IMIT NANCY 0. I3ALTLYFA1' .JILL SHAFFttt WEST DES MQINES ]A eaoh ln thelr lndividual capacity itstrue and lawfu! attorney n facl wthtulI power and authorilyto stgn seat and execute on its behall any and alibonds and undettaksngs and oIhsrobtiatory instruments of sirnilar nature, In penatties not exoeeding the surn ot ThREE MILLION AND NO/100 DOLLARS S 3,000,000.00 and to bind the Company thereby, as tully and to the sarne extent as if such instrurnents were signed by lhe duly authorized offiQers 01 lhe Company; and alt acts ot sald Altornay pursuant to the authority given are hereby ratified and oonlirmed. Thls power of attorney is made and executed pursuant to and by authority of the toltowing resolttion duly adopted by the board 0! dlreotors of the Company: rnESOLVED, that the president, or any vlce presldent be, and each hereby Is, authortzed and ornpowered to appoint attorneys-ln-fact 01 Ihe Company, and to authorize them 10 exenure and deliver on behalf of the Company any and alt bonds, forms, applications, mernorandums, undertakings, recognizances, transfers, oontracts 0! indennity, poticies, contracts guaranteeirig the fidelity ot persons holding posltions of publlo orprivate trust, and ather wrlllngs obligatory in naturethatlhe bustness of the Cornpany may requlre; and to rnodify or revoke, with er without cause, any suoh appolntrnentor authority; provided, however, thatthe authority granted hereby shall in no way tirnit the authority ot ather duty authorlzed agents to slgn and countorslgn any 0! said doouments on behal! of the Gonipany: PESOLVEO FURTHER, thal such anorneys-in-tact shalt have lult power and authorityto eitecute and deliver any and alt such documents and to bind the Conipany sub)eotto the ternis and tiniitations of the power of atiorney issued 10 thern, and to aftixthe seal of the Companythereto; provlded, however, lhat said seal shall not be necessary for the validity of any suoh doouments." This power ot attorney Is signed and sealed under and by the following bylaws duly adopted by the board 0! directors 0! the Conipany. Execution of lnstruments. Any vloe president, any assistant secretary or any assistant treasurer shall have the power and authority to stgn or attest alt approved dosunients, instruments, contracts, orotherpapers tn connectionwith the operalion of the businese of the conipany in addition to the chalrrnan of the board, the chlef exeoutive officer, president, Ireasurer 0! secretary; provlded, however, the slgnature of anyot thern may be printed, engraved, or stamped on anyapproved docurnent, contract, lnstrumsnt, ar other papers of the Conipany. IN WtTNESS WHEREOF, the Conipany has caused this instrument to be sealed andduty attested by lhe slgnature of its ofticer the jdayof February, 2014. 4? ,JsEAL}J ACKNOWLEDGMENT $TATE QF IQWA, COIJNTY OF POLK: ss '"' OnthlsfldayofEebruarv 2014 betoremeoamelheabove narnedofticerfor thecompanlesaforesaid •.SEAL:.j ,SEAL: rne personatly known to be tho otfioer described in and who executed the preoeding instrurnenl, and he $ $ *\ .4 aoknowledged the exeoution otthe same, and being by rne dulysworn, deposes and says, that he isthe offioer ofthe Companies aforesald, thatthe seals aftlxed hereto are the corporateseats ot satd Gonipanles, and the sald corporate seals and his signature were duly af!lxed and subscribod to said lnstrument bylhe authorityand direction of said Compantes. '� SwyAfflz 1.T er 4 Noiarlalstal—lowa 1 Con,rnI,Lon Nurnbr S2785 Notarv Pubilo ‚ V My Comrnl.sslonExplrcsMarch,24,2017 . y ommiss on xp res cERTIrICATE March 24, 2017 Robert W Horner itt, Secretaty of the Cornpanles, do hereby certify that the foregolng Is a full, true and correct copy af lhe orlglnat power of attorney tssued by the Company;that the resotution lncluded therein isa true and correcttranscrlptfrom the rninutes of the neetings ot the boardsof directorsand the sarne has notbeen revoked or arnended in any rnanner that said Terrance Wittiams was on the date af the execution of the foregotng power ot attorney the duly etected oftrcer ot the Companies and the corporate seats and his signature as otficer were duly afttxed and subscrlbed 10 the said instrurnent bythe authori4'of said board otdirectors; andthe foregolng power of attorney 5 stilt intuit force and etfect. tN WITNESS WHEREOF, t have hereunto subscribed my nanoe as Secretary, and affixed the corporate seats of said Companles this day terrance Wllttarns, President and Chiet Operating Ofticer of Nationwide Agribustness tnsurance Gonipany and Farniland Mutual tnsurance Cornpany; and Vipe Prestdenl ot Nationwlde Mutual tnsuranoe Cornpany, AMCO tnsurance Conipany, Allied Property and Casualty lnsurance Cornpany, and Depositors tnsurance Cornpany of 2016 This Power of Attorney Expires tzjI0/16 I3DJ 1(034)(X) 01779 Secret .7 ® ACORD CERTIFUCATE OF LIABILITY INSURANCE 0MM/0D/ 10/24/2016 THIS CERTIFICATE IS ISSUEO AS A MATTER OF INFORMATION ONLY AND CONEERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: 11 the certlficate holder is an ADDITIONAL INSURED, the policy(ies) must bo endorsed. If SUBROGATION 15 WAIVED, subject to the terms and conditions of the policy, certaln policles nlay require an endorsernent. A statement on this certificate does not confer rights to the certilicate bolder in lieu of such endorsement(s). PRODUCER LMC Insurance & Risk Management, Inc. 4200 University Ave., Suite 200 West Dos Moines IA 50266-5945 GOHTACT NAME: Beth Wicknian PHONE FAX INC. No Fxn:S1S-237-01 12 INC No):51 5-244-9535 E-MAIL AODRESS:beth wickman@lmcins.com INSURER(S} AFFOROING COVERAGE NAIC 1/ INSURERA:BITCO General Insurance Corooration INSURERS: 20095 INSIJRED BOULCON-01 Boulder Contracting, LLC 25789 N Ave Grundy Center IA 50638 INSURERC: CLP 3638333 INSURER D: 6/1/2017 INSURER 0: $ 1,000,000 INSURER 1': 5300,000 COVERAGES CERTIFICATE NUMBER: 2040640383 REVISION NUMBER: THIS 8 TO CERTIFY TI -IAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLIGY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION 01' ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WFIICH TFIIS CERTIFICATE MAY BE ISSUED Ok MAY PERTAIN, THE IN8URANCE AFFORDFD BY THE POLICIES DESCRIBED I-IEREIN 18 SUBJECT TO ALL THE TERMS, EXCLUSIONS AND GONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR LTR TYPEOFINSURANCE AODL INSR 5000 tWO POLICYNUMBER POLICY EFF (MM(ODJYYYY) POLICY EXP IMMJD0)YYYfl LIMITS A GENERAL LIARILITV COMMERCIAL GENERAL LIABILITY Y CLP 3638333 6/1/2016 6/1/2017 EACH OCCURRENCE $ 1,000,000 DAMAGE TO RENTED PREMISES lEs occurence) 5300,000 CLAIMS -MADE X QCCUR MEB EXP (Any ane person) 510,000 PERSONAL & ABV INJURY 51,000,000 CENEI1L AGGRECATE 52.000,000 GEN'L AGOREGATE PCLICY X LIMIT APPUES Wi: PER: LOC PR000CTS - COMP/OP ACC 52.000,000 $ A AUTOMOBILE X LIABILITY ANY AUTO IIIREO AUTOS - %ygguLEo NON-OWI4EO AUTOS CAP 3638334 6/1/2016 6(1/2017 COMSINEBSINCLE LIMIT 000 000 BOOILY INJURY (Per person) $ BODILY INJURY (Per accidenl) $ PROPERTY BAMAGE (Per actIdenI) $ A X UMSRELLALIAB EXCESS LIAB x OCCUR CLAIMS -MADE CUP2BI1OY7 6/1/2016 6/1/2017 EACIIOCCURRENCE 54,000,000 AGGREGATE 54,000,000 0E0 RETENTOI'I$IO,OOO $ A WORKERS COMPENSATION ANDEMPLOYERSLIABILITY VIN ANY PR0PRIET0IPARTNEMEXECUTIVE OFF CERIMEMOER EXCL000D? (Mo datory in NH) 0 yes, describe under OESCRIPTION OE OPERATIONS below N 5 A WC 3638335 6/1/2016 6/1(2017 X WG STATU- OTH- TORYLIMITS P0 E.L, EACI-I ACCIDENT 5500,000 E.L, DISEASE EA EMPLOYEE $500,000 81, DISEASE - POLIGY LIMIT $500,000 DESCRIPTION OF OPERATIONS / LOCATIONS /VEHICLES (AIIach A0000 101, AddlIionaI Remarks Schedul 0 more space is required) Project: F.Y. 2017 Bridge Deck Repair and Overlay Program, c±ty of Waterloo, IA ContraCt #: 879 City of Waterloo ±5 an Additional Irisured - Contractors, Managers Or Lessors of Premises, State or Governrnental Agency Or Political subdivisions - perniits or authorizations, Engirieers, Architects Or Surveyors - prinnary and non-contributory when reguired in a contract - with respects to the Gerneral Liability policy per form GL3086 (09/11) CERTIFICATE HOLDER CANCELLATION Cfty of Waterloo 620 Mulborry St. Carnege Annex, Suite 202 Waterloo IA 50703 SHOULO ANY 01' THE ABOVE OESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE TFIEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE P0LICY PR0VISIONS. AUTIIORIZEO REPRESENTATIVE ACORD 25(2010/05) © 1988-2010 ACORD CORPORATION. All rights reserved. The ACORD narne and logo are registered marks of ACORD Item Coversheet CITY OF WATERLOO Council Co,nmunication Page 1 of 1 Resolution approving award of contract to Boulder Contracting, LLC, of Grundy Center, Iowa in the amount of $1,424,42657; and approving the bonds and Certifieate oflnsurance for the FY. 2017 Bridge Deck Repair and Overlay Program (Division 1 Base Bid + Alternate A Opuon 1 + Division 11), Contract No. 879 -.. authorize Mayor and City Clerk to execute said documents. City Council Meetin 1/7/2016 rrepai'ed: 11/1/201 SIJBJECT: Submitted by: Source ofFunds: Resolution approving award of contract to Boulder Contractin, LLC. of Grundy Center Iowa in the amount of $1,424 42657 and approving the bonds and Certificatc of Insurance for the F.Y. 2017 Bridge Deck Repair and Overlay Program (Division 1 Base Bid + Altemate A Option 1 + Division ID Conlract No, 879 and autborize Mayor and Citv Clerk to execute said documents. Subniitted By: Dennis Gentz, PB. Assistant City Engineer Division 1: Road Use Tax Funds. Division 2: Flood Control funds ( G. 0. Bonds) http://waterloo.novusagenda.comlAgendaWeb/Coversheet.aspx?ItemID=67 11 11/1/2016